Loading...
HomeMy WebLinkAboutC2023-086 - 5/9/2023 - Approved DocuSign Envelope ID:71FE69C2-3B81-4095-AFFD-5B86994835DB ©� H SERVICE AGREEMENT NO. 4848 v MASTER SERVICE AGREEMENT FOR PROFESSIONAL SERVICES N852Eo General Civil Projects in Engineering Services Department This Agreement is between the City of Corpus Christi, a Texas home rule municipal corporation, P.O. Box 9277, Corpus Christi, Nueces County, Texas 78469-9277 (City) acting through its duly authorized City Manager or designee and HDR ENGINEERING, INC., 555 N. Carancahua, Suite 1600, Corpus Christi, Texas 78401 (Consultant). TABLE OF CONTENTS ARTICLE NO. TITLE PAGE ARTICLE I PROJECT TASK ORDER.....................................................................................2 ARTICLE II COMPENSATION.................................................................................................3 ARTICLE III QUALITY CONTROL PLAN..................................................................................4 ARTICLE IV INSURANCE REQUIREMENTS...........................................................................4 ARTICLE V INDEMNIFICATION ..............................................................................................4 ARTICLE VI TERM; RENEWALS; TIMES FOR RENDERING SERVICE.................................5 ARTICLE VII TERMINATION OF AGREEMENT .......................................................................5 ARTICLE VIII RIGHT OF REVIEW AND AUDIT .........................................................................6 ARTICLE IX OWNER REMEDIES ............................................................................................6 ARTICLE X CONSULTANT REMEDIES..................................................................................7 ARTICLE XI CLAIMS AND DISPUTE RESOLUTION ...............................................................7 ARTICLE XII MISCELLANEOUS PROVISIONS ........................................................................9 EXHIBITS Pagel Rev. 22-11 DocuSign Envelope ID:71FE69C2-3B81-4095-AFFD-5B86994835DB ARTICLE I — PROJECT TASK ORDER 1.1 This Agreement shall apply to as many tasks as City and Consultant agree will be performed under the terms and conditions of this Agreement. Each task Consultant performs for City hereunder shall be designated a Task Order. No Task Order shall be binding or enforceable unless and until it has been properly executed by both City and Consultant. The general scope for these Task Orders is outlined in Exhibit A. More specific scopes of work will be issued for pricing when a task order is needed. Task Orders shall become a supplemental agreement to this Agreement. 1.2 The Consultant shall provide its Scope of Services, to be included in each Task Order. The Scope of Services shall include all associated services required for Consultant to provide such Services, pursuant to this Agreement, and any and all Services which would normally be required by law or common due diligence in accordance with the standard of care defined in Article XII of this Agreement. Consultant will perform the Services in accordance with the approved Scope of Services and with Consultant's response to the Request for Qualifications related to this project, which response is incorporated by reference into this Agreement as if set out here in its entirety. 1.3 Under this Agreement, Consultant will provide services on a Task Order basis for a range of services related to assisting Engineering Services with professional engineering, architecture and construction services related to execution of Capital Improvements Programs. All work will be subject to authorization from City. A detailed Scope of Services and fee estimate will be developed for each task prior to execution of work. 1.4 Consultant shall follow City Codes and Standards effective at the time of the execution of individual Task Orders. At review milestones, the Consultant and City will review the progress of the plans to ensure that City Codes and Standards are followed unless specifically and explicitly excluded from doing so in the approved Task Order. A request made by either party to deviate from City standards after the contract is executed must be in writing. 1.5 Consultant must perform tasks and submit deliverables as detailed in each approved Task Order. 1.6 Consultant must provide all labor, equipment and transportation necessary to complete all services agreed to in a timely manner throughout the term of the Agreement. Persons retained by Consultant to perform work pursuant to this Agreement shall be employees or subconsultants of Consultant. Consultant must provide City with a list of all subconsultants that includes the services performed by the subconsultant and the percentage of work performed by the subconsultant. Changes in Consultant's team that provides services under this Agreement must be agreed to by the City in writing. 1.7 Consultant must not begin work on any Task Order authorized under this Agreement until they are briefed on the scope of the Project and are issued the fully executed Task Order to proceed. 1.8 For design services, Consultant agrees to render the professional services necessary for the advancement of the Project through Final Completion of the Construction Contract. Consultant acknowledges and accepts its responsibilities, as defined and described in the City's General Conditions for Construction Contracts, an excerpt of which is attached as Exhibit D to this Agreement. 1.9 For projects that require subsurface utility investigation: 1.9.1 The Consultant agrees to prepare and submit to the City a signed and sealed report identifying all utilities within the project area at the Quality Level specified in the Task Order. It is assumed that all utilities will be identified using Quality Level A exploratory excavation unless stated otherwise. Page 2 Rev. 22-11 DocuSign Envelope ID:71FE69C2-3B81-4095-AFFD-5B86994835DB 1.9.2 Utilities that should be identified include, but are not limited to, City-owned utilities, local franchises, electric companies, communication companies, private pipeline companies and V party owners/operators. 1.10 For project with potential utility conflicts: 1.10.1 The Consultant agrees to coordinate the verification and resolution of all potential utility conflicts. 1.10.2 The Consultant agrees to prepare and submit a monthly Utility Coordination Matrix to the City. ARTICLE II —COMPENSATION 2.1 The Compensation for all services included in this Agreement by Task Orders shall not exceed $1,000,000.00. 2.2 The Consultant's fee for each Task Order will be on a lump sum or time and materials (T&M) basis with a negotiated not-to-exceed amount. The fees will not exceed those identified and will be full and total compensation for all services outlined in each Task Order, and for all expenses incurred in performing these services. 2.3 Consultant shall price Task Orders in accordance with Exhibit B, Rate Schedule, subject to approval by the City. 2.4 Monthly invoices will be submitted in accordance with the Payment Request as shown in Exhibit C. Each invoice will include the Consultant's estimate of the proportion of the contracted services completed at the time of billing. For work performed on a T&M Basis, the invoice shall include documentation that shows who worked on the Project, the number of hours that each individual worked, the applicable rates from the Rate Schedule and any reimbursable expenses associated with the work. City will make prompt monthly payments in response to Consultant's monthly invoices in compliance with the Texas Prompt Payment Act. 2.5.1 Principals may only bill at the hourly rate of Principals when acting in that capacity. Principals acting in the capacity of staff must bill at staff rates. The Consultant shall provide documentation with each payment request that clearly indicates how that individual's time is allocated and the justification for that allocation. 2.5 In the event of any dispute(s) between the Parties regarding the amount properly compensable for any Task Order or as final compensation or regarding any amount that may be withheld by City, Consultant shall be required to make a claim pursuant to and in accordance with the terms of this Agreement and follow the procedures provided herein for the resolution of such dispute. In the event Consultant does not initiate and follow the claims procedures provided in this Agreement in a timely manner and as required by the terms thereof, any such claim shall be waived. 2.6 Request of final compensation by Consultant shall constitute a waiver of claims except those previously made in writing and identified by Consultant as unsettled at the time of final Payment Request. 2.7 Any fee payable under this Agreement is subject to the availability of funds. The Consultant may be directed to suspend work pending receipt and appropriation of funds. The right to suspend work under this provision does not relieve the City of its obligation to make payments in accordance with section 2.5 above for services provided up to the date of suspension. Page 3 Rev. 22-11 DocuSign Envelope ID:71FE69C2-3B81-4095-AFFD-5B86994835DB ARTICLE III —QUALITY CONTROL PLAN 3.1 The Consultant agrees to perform quality assurance-quality control/constructability reviews (QCP Review). The City reserves the right to retain a separate consultant to perform additional QCP services for the City. 3.2 The Consultant will perform QCP Reviews at intervals during the project to ensure deliverables satisfy applicable industry quality standards and meet the requirements of the project scope. Based on the findings of the QCP Review, the Consultant must reconcile the project scope and Opinion of Probable Cost (OPC) as needed. 3.3 Documents that do not meet City standards in effect at the time of the execution of a related Task Order may be rejected. If documents are found not to be in compliance with this Agreement, Consultant will not be compensated for having to resubmit documents. ARTICLE IV— INSURANCE REQUIREMENTS 4.1 Consultant must not commence work under this Agreement until all required insurance has been obtained, and such insurance has been approved by the City. Consultant must not allow any subcontractor to commence work until all similar insurance required of any subcontractor has been obtained. 4.2 Insurance Requirements are shown in EXHIBIT D. ARTICLE V- INDEMNIFICATION Consultant shall fully indemnify and hold harmless the City of Corpus Christi and its officials, officers, agents, employees, excluding the engineer or architect or that person's agent, employee or subconsultant, over which the City exercises control ("Indemnitee") from and against any and all claims, damages, liabilities or costs, including reasonable attorney fees and court costs, to the extent that the damage is caused by or results from an act of negligence, intentional tort, intellectual property infringement or failure to pay a subcontractor or supplier committed by Consultant or its agent, Consultant under contract or another entity over which Consultant exercises control while in the exercise of rights or performance of the duties under this agreement. This indemnification does not apply to any liability resulting from the negligent acts or omissions of the City or its employees, to the extent of such negligence. Consultant shall defend Indemnitee, with counsel satisfactory to the City Attorney, from and against any and all claims, damages, liabilities or costs, including reasonable attorney fees and court costs, included in the indemnification above if the claim is not based wholly or partly on the negligence of, fault of or breach of contract by Indemnitee. If a claim is based wholly or partly on the negligence of, fault of or breach of contract by Indemnitee, the Consultant shall reimburse the City's reasonable attorney's fees in proportion to the Consultant's liability. Consultant must advise City in writing within 24 hours of any claim or demand against City or Consultant known to Consultant related to or arising out of Consultant's activities under this Agreement. Page 4 Rev. 22-11 DocuSign Envelope ID:71FE69C2-3B81-4095-AFFD-5B86994835DB ARTICLE VI —TERM; RENEWALS; TIMES FOR RENDERING SERVICE 6.1 This Agreement shall be effective upon the signature of the City Manager or designee (Effective Date). 6.2 This Agreement shall be applicable to Task Orders issued hereunder from the Effective Date of the Agreement until Task Orders are complete. 6.3 The term of this Agreement shall be for a period of one year beginning on the Effective Date, unless extended by authority of the City Manager or designee. The Agreement may be renewed for up to one renewal option upon mutual agreement of the parties to be evidenced in writing prior to the expiration of the prior term. Any renewals shall be at the same terms and conditions, plus any approved changes. 6.4 The times for performing services or providing deliverables will be stated in each Task Order. If no times are so stated, Consultant will perform services and provide deliverables within a reasonable time. ARTICLE VII - TERMINATION OF AGREEMENT 7.1 By Consultant: 7.1.1 The City reserves the right to suspend this Agreement at the end of any phase for the convenience of the City by issuing a written and signed Notice of Suspension. The Consultant may terminate this Agreement for convenience in the event such suspension extends for a period beyond 120 calendar days by delivering a Notice of Termination to the City. 7.1.2 The Consultant must follow the Termination Procedure outlined in this Agreement. 7.2 By City: 7.2.1 The City may terminate this agreement for convenience upon seven days written notice to the Consultant at the address of record. 7.2.2 The City may terminate this agreement for cause upon ten days written notice to the Consultant. If Consultant begins, within three days of receipt of such notice, to correct its failure and proceeds to diligently cure such failure within the ten days, the agreement will not terminate. If the Consultant again fails to perform under this agreement, the City may terminate the agreement for cause upon seven days written notice to the Consultant with no additional cure period. If the City terminates for cause, the City may reject any and all proposals submitted by Consultant for up to two years. 7.3 Termination Procedure 7.3.1 Upon receipt of a Notice of Termination and prior to the effective date of termination, unless the notice otherwise directs or Consultant takes action to cure a failure to perform under the cure period, Consultant shall immediately begin the phase-out and discontinuance of all services in connection with the performance of this Agreement. Within 30 calendar days after receipt of the Notice of Termination, unless Consultant has successfully cured a failure to perform, Consultant shall submit a statement showing in detail the services performed under this Agreement prior to the effective date of termination. City retains the option to grant an extension to the time period for submittal of such statement. 7.3.2 Consultant shall submit all completed and/or partially completed work under this Agreement, including but not limited to specifications, designs, plans and exhibits. Consultant shall mark partially completed work as "Draft" and does not guarantee the accuracy or reliability of partially completed work submitted in accordance with this Article. Page 5 Rev. 22-11 DocuSign Envelope ID:71FE69C2-3B81-4095-AFFD-5B86994835DB 7.3.3 Upon receipt of documents described in the Termination Procedure and absent any reason why City may be compelled to withhold fees, Consultant will be compensated for its services based upon a Time & Materials calculation or Consultant and City's estimate of the proportion of the total services actually completed at the time of termination. There will be no compensation for anticipated profits on services not completed. 7.3.4 Consultant acknowledges that City is a public entity and has a duty to document the expenditure of public funds. The failure of Consultant to comply with the submittal of the statement and documents, as required above, shall constitute a waiver by Consultant of any and all rights or claims to payment for services performed under this Agreement. ARTICLE VIII — RIGHT OF REVIEW AND AUDIT 8.1 Consultant grants City, or its designees, the right to audit, examine or inspect, at City's election, all of Consultant's records relating to the performance of the Work under this Agreement, during the term of this Agreement and retention period herein. The audit, examination or inspection may be performed by a City designee, which may include its internal auditors or an outside representative engaged by City. Consultant agrees to retain its records for a minimum of four years following termination of the Agreement, unless there is an ongoing dispute under this Agreement, then such retention period shall extend until final resolution of the dispute. 8.2 "Consultant's records" include any and all information, materials and data of every kind and character generated as a result of the Work under this Agreement. Examples include billings, books, general ledger, cost ledgers, invoices, production sheets, documents, correspondence, meeting notes, subscriptions, agreements, purchase orders, leases, contracts, commitments, arrangements, notes, daily diaries, reports, drawings, receipts, vouchers, memoranda, time sheets, payroll records, policies, procedures, federal and state tax filings for issue in questions and any and all other agreements, sources of information and matters that may, in City's judgment, have any bearing on or pertain to any matters, rights, duties or obligations under or covered by any Agreement Documents. 8.3 City agrees that it shall exercise the right to audit, examine or inspect Consultant's records only during City's regular business hours. Upon reasonable prior notice, Consultant agrees to allow City's designee access to all of Consultant's records, Consultant's facilities and Consultant's current or former employees, deemed necessary by City or its designee(s), to perform such audit, inspection or examination. Consultant also agrees to provide adequate and appropriate work space necessary to City or its designees to conduct such audits, inspections or examinations. 8.4 Consultant shall include this audit clause in any subcontractor, supplier or vendor contract. ARTICLE IX—OWNER REMEDIES 9.1 The City and Consultant agree that in the event the City suffers actual damages, the City may elect to pursue its actual damages and any other remedy allowed by law. This includes but is not limited to: 9.1.1 Failure of the Consultant to make adequate progress and endanger timely and successful completion of the Project, which includes failure of subconsultants to meet contractual obligations; 9.1.2 Failure of the Consultant to design in compliance with the laws of the City, State and/or federal governments, such that subsequent compliance costs exceed expenditures that would have been involved had services been properly executed by the Consultant. 9.1.3 Losses are incurred because of defects, errors and omissions in the design, working drawings, Page 6 Rev. 22-11 DocuSign Envelope ID:71FE69C2-3B81-4095-AFFD-5B86994835DB specifications or other documents prepared by the Consultant to the extent that the financial losses are greater than the City would have originally paid had there not been defects, errors and omissions in the documents. 9.3 When the City incurs non-value added work costs for change orders due to design errors or omissions, the City will send the Consultant a letter that includes: (1) Summary of facts with supporting documentation; (2) Instructions for Consultant to revise design documents, if appropriate, at Consultant's expense; (3) Calculation of non-value added work costs incurred by the City; and (4) Deadline for Consultant's response. 9.4 The Consultant may be required to revise bid documents and re-advertise the Project at the Consultant's sole cost if, in the City's judgment, the Consultant generates excessive addenda, either in terms of the nature of the revision or the actual number of changes due to the Consultant's errors or omissions. 9.5 The City may withhold or nullify the whole or part of any payment as detailed in Article II. ARTICLE X—CONSULTANT REMEDIES 10.1 If Consultant is delayed due to uncontrollable circumstances, such as strikes, riots, acts of God, national emergency, acts of the public enemy, governmental restrictions, laws or regulations or any other causes beyond Consultant's and City's reasonable control, an extension of the Project schedule in an amount equal to the time lost due to such delay shall be Consultant's sole and exclusive remedy. The revised schedule should be approved in writing with a documented reason for granting the extension. 10.2 If Consultant requests a remedy for a condition not specified above, Consultant must file a Claim as provided in this Agreement. ARTICLE XI —CLAIMS AND DISPUTE RESOLUTION 11.1 Filing of Claims 11.1.1 Claims arising from the circumstances identified in this Agreement or other occurrences or events, shall be made by Written Notice delivered by the party making the Claim to the other party within 21 calendar days after the start of the occurrence or event giving rise to the Claim and stating the general nature of the Claim. 11.1.2 Every Claim of Consultant, whether for additional compensation, additional time or other relief, shall be signed and sworn to by a person authorized to bind the Consultant by his/her signature, verifying the truth and accuracy of the Claim. 11.1.3 The responsibility to substantiate a claim rests with the party making the Claim. 11.1.4 Within 30 calendar days of receipt of notice and supporting documentation, City will meet to discuss the request, after which an offer of settlement or a notification of no settlement offer will be sent to Consultant. If Consultant is not satisfied with the proposal presented, Consultant will have 30 calendar days in which to (i) submit additional supporting data requested by the City, (ii) modify the initial request for remedy or (iii) request Alternative Dispute Resolution. 11.1.5 Pending final resolution of a claim, except as otherwise agreed in writing, Consultant shall proceed diligently with performance of the Agreement and City shall continue to make payments in Page 7 Rev. 22-11 DocuSign Envelope ID:71FE69C2-3B81-4095-AFFD-5B86994835DB accordance with this Agreement. 11.2 Alternative Dispute Resolution 11.2.1 All negotiations pursuant to this clause are confidential and shall be treated as compromise and settlement negotiations for purposes of applicable rules of evidence. 11.2.2 Before invoking mediation, the Parties agree that they shall first try to resolve any dispute arising out of or related to this Agreement through discussions directly between those senior management representatives within their respective organizations who have overall managerial responsibility for similar projects. This step shall be a condition precedent to the use of mediation. If the parties' senior management representatives cannot resolve the dispute within 30 calendar days after a Party delivers a written notice of such dispute,then the Parties shall proceed with the mediation process contained herein. 11.2.3 Mediation 11.2.3.1 In the event that City or Consultant shall contend that the other has committed a material breach of this Agreement, the Party alleging such breach shall, as a condition precedent to filing any lawsuit, request mediation of the dispute. 11.2.3.2 Request for mediation shall be in writing, and shall request that the mediation commence no less than 30 or more than 90 calendar days following the date of the request, except upon agreement of both parties. 11.2.3.3 In the event City and Consultant are unable to agree to a date for the mediation or to the identity of the mediator or mediators within 30 calendar days of the request for mediation, all conditions precedent in this Article shall be deemed to have occurred. 11.2.3.4 The parties shall share the mediator's fee. Venue for any mediation or lawsuit arising under this Agreement shall be Nueces County, Texas. Any agreement reached in mediation shall be enforceable as a settlement agreement in any court having jurisdiction thereof. No provision of this Agreement shall waive any immunity or defense. No provision of this Agreement is a consent to suit. 11.3 In calculating the amount of any Claim or any measure of damages for breach of contract, the following standards shall apply both to claims by Consultant and to claims by City: 11.3.1 In no event shall either Party be liable, whether in contract or tort or otherwise, to the other Party for loss of profits, delay damages or for any special incidental or consequential loss or damage of any nature arising at any time or from any cause whatsoever; 11.3.2 Damages are limited to extra costs specifically shown to have been directly caused by a proven wrong for which the other Party is claimed to be responsible. 11.4 In case of litigation between the parties, Consultant and City agree that neither party shall be responsible for payment of attorney's fees pursuant to any law or other provision for payment of attorneys' fees. Both Parties expressly waive any claim to attorney's fees should litigation result from any dispute in this Agreement. 11.5 In case of litigation between the parties, Consultant and City agree that they have knowingly waived and do hereby waive the right to trial by jury and have instead agreed, in the event of any litigation arising out of or connected to this Agreement, to proceed with a trial before the court, unless both parties Page 8 Rev. 22-11 DocuSign Envelope ID:71FE69C2-3B81-4095-AFFD-5B86994835DB subsequently agree otherwise in writing. 11.6 No Waiver of Governmental Immunity. This Agreement is to perform a governmental function solely for the public benefit. Nothing in this Agreement shall be construed to waive City's governmental immunity from lawsuit, which immunity is expressly retained to the extent it is not clearly and unambiguously waived by state law. ARTICLE XII — MISCELLANEOUS PROVISIONS 12.1 Assignability. Neither party will assign, transfer or delegate any of its obligations or duties under this Agreement to any other person and/or party without the prior written consent of the other party, except for routine duties delegated to personnel of the Consultant staff. This includes subcontracts entered into for services under this Agreement. If the Consultant is a partnership or joint venture, then in the event of the termination of the partnership or joint venture, this contract will inure to the individual benefit of such partner or partners as the City may designate. No part of the Consultant fee may be assigned in advance of receipt by the Consultant without written consent of the City. The City will not pay the fees of expert or technical assistance and consultants unless such employment, including the rate of compensation, has been approved in writing by the City. 12.2 Ownership of Documents. Consultant agrees that upon payment, City shall exclusively own any and all information in whatsoever form and character produced and/or maintained in accordance with, pursuant to or as a result of this Agreement, including contract documents (plans and specifications), drawings and submittal data. Consultant may make a copy for its files. Any reuse, without specific written verification or adaptation by Consultant, shall be a City's sole risk and without liability or legal exposure to Consultant. The City agrees that any modification of the plans will be evidenced on the plans and be signed and sealed by a professional engineer prior to re-use of modified plans. 12.3 Standard of Care. Services provided by Consultant under this Agreement shall be performed with the professional skill and care ordinarily provided by competent engineers or architects practicing under the same or similar circumstances and professional license; and performed as expeditiously as is prudent considering the ordinary professional skill and care of a competent engineer or architect. 12.4 Licensing. Consultant shall be represented by personnel with appropriate licensure, registration and/or certification(s) at meetings of any official nature concerning the Project, including scope meetings, review meetings, pre-bid meetings and preconstruction meetings. 12.5 Independent Contractor. The relationship between the City and Consultant under this Agreement shall be that of independent contractor. City may explain to Consultant the City's goals and objectives in regard to the services to be performed by Consultant, but the City shall not direct Consultant on how or in what manner these goals and objectives are to be met. 12.6 Entire Agreement. This Agreement, including Task Orders, represents the entire and integrated Agreement between City and Consultant and supersedes all prior negotiations, representations or agreements, either oral or written. This Agreement may be amended only by written instrument signed by both the City and Consultant. 12.7 No Third Party Beneficiaries. Nothing in this Agreement can be construed to create rights in any entity other than the City and Consultant. Neither the City nor Consultant intends to create third party beneficiaries by entering into this Agreement. Page 9 Rev. 22-11 DocuSign Envelope ID:71FE69C2-3B81-4095-AFFD-5B86994835DB 12.8 Disclosure of Interest. Consultant agrees to comply with City of Corpus Christi Ordinance No. 17112 and complete the Disclosure of Interests form as part of this contract. 12.9 Certificate of Interested Parties. Consultant agrees to comply with Texas Government Code section 2252.908 and complete Form 1295 Certificate of Interested Parties as part of this agreement. Form 1295 must be electronically filed with the Texas Ethics Commission at https://www.ethics.state.tx.us/whatsnew/elf—info—forml295.htm. The form must then be printed, signed and filed with the City. For more information, please review the Texas Ethics Commission Rules at httgs://www.ethics.state.tx.us/legal/ch46.htmi. 12.10 Conflict of Interest. Consultant agrees to comply with Chapter 176 of the Texas Local Government Code and file Form CIQ with the City Secretary's Office, if required. For more information and to determine if you need to file a Form CIQ, please review the information on the City Secretary's website at http://www.cctexas.com/government/city-secretary/conflict-disclosure/index 12.11 Provisions Required by Law. Each applicable provision and clause required by law to be inserted into the Agreement shall be deemed to be enacted herein, and the Agreement shall be read and enforced as though each were physically included herein. 12.12 Public Information. The requirements of Subchapter J, Chapter 552, Government Code, may apply to this contract and the Consultant agrees that the contract can be terminated if the Consultant knowingly or intentionally fails to comply with a requirement of that subchapter. 12.13 Controlling Law. This Agreement is governed by the laws of the State of Texas without regard to its conflicts of laws. Venue for legal proceedings lies exclusively in Nueces County, Texas. 12.14 Severability. If, for any reason, any one or more Articles and/or paragraphs of this Agreement are held invalid or unenforceable, such invalidity or unenforceability shall not affect, impair or invalidate the remaining Articles and/or paragraphs of this Agreement but shall be confined in its effect to the specific Article, sentences, clauses or parts of this Agreement held invalid or unenforceable, and the invalidity or unenforceability of any Article, sentence, clause or parts of this Agreement, in any one or more instance, shall not affect or prejudice in any way the validity of this Agreement in any other instance. 12.15 Conflict Resolution Between Documents. Consultant hereby agrees and acknowledges if anything contained in any documents prepared by Consultant and included herein is in conflict with Articles I - XII of this Agreement (Articles) and/or an approved Task Order, the Articles and/or the Task Order shall take precedence and control to resolve said conflict. 12.16 Title VI Assurance. The Consultant shall prohibit discrimination in employment based upon race, color, religion, national origin, gender, disability or age. Page 10 Rev. 22-11 DocuSign Envelope ID:71FE69C2-3B81-4095-AFFD-5B86994835DB CITY OF CORPUS CHRISTI HDR ENGINEERING, INC. DocuSigned by: DDacuSignee'd44by: 5/30/2023 �tWU� Wtb�t 5/24/2023 J ff 9TRon s P.E. (Date) [Davi .Weston (Date) Director of Engineering Services Vice President, Gulf Coast Area Manager 555 N. Carancahua, Suite 1600 Corpus Christi, Texas 78401 (361) 342-5428 Office david.weston@hdrinc.com APPROVED AS TO LEGAL FORM L usignte``a``by: iN�,CCU�t.AtJ�, 5/25/2023 Assistant City Attorney (Date) for City Attorney M2023-067 AUTHORIZED ATTEST 5/9/2023 DocuSignedby: BY COUNCIL 4 � 7 �. 6/1/2023 -a ;QP91;94Q44P Rebecca Huerta, City Secretary Er-;/s ? Page 11 Rev. 22-11 DocuSign Envelope ID:71FE69C2-3B81-4095-AFFD-5B86994835DB 0 EXHIBIT A SCOPE OF SERVICES +NCPRFORatkO The consultant shall assist the City in a wide range of issues including, but not limited to, site investigations, analysis with recommendations for developing project scopes, cost estimating, design and constructability peer review, cost and schedule controls, design management, and support services as required by the City. Master Services Agreement DocuSign Envelope ID:71FE69C2-3B81-4095-AFFD-5B86994835DB Consultant Rate Sheet (Confidential) Exhibit B Page 1 of 1 mes)nEm¥ope ID:2FS9C 33e1-aGFF 55kmkg5DB / 5 [ E + + + + + + + 2 E o 0 0 0 0 0 0 • B �\ 7 o 0 0 0 _ � m 0 Sb / E U Q g � � LU 2 LU 2 W @ U � / 0 R R 61) 61) R R k 2 C 0 0 0 % k 0 2 Z E 2 r 2 z -j § � � � O 2 2 2 k 0 W � 2 LU � § U « 2 2 2 CC2 2 Z § L) X LO � � � % � � LuZ q � 2 � � q O 2 d d ® S a O / 2 k k k k E LJ � 2 ' @ - - - - W 2 § .' 2 0 a. � a � � 3 � Z � 2 @ O � � � � � � b U 2 k J q � k k k C \ k C 7 CL z k Q U k 4- 2 $ 0 U) $ / $ ILL m _ 2 E ILL o $ m LL m 00 0 k (j) d o ./ = m ■ 4 cn 0 ® / 0 0 @ 2 0 � = 7 g � Im k � k z � k m < DocuSign Envelope ID:71FE69C2-3B81-4095-AFFD-5B86994835DB EXHIBIT D Insurance Requirements Pre-Design, Design and General Consulting Contracts 1.1 Consultant must not commence work under this agreement until all required insurance has been obtained and such insurance has been approved by the City. Consultant must not allow any subcontractor to commence work until all similar insurance required of any subcontractor has been obtained. 1.2 Consultant must furnish to the Director of Engineering Services with the signed agreement a copy of Certificates of Insurance (COI) with applicable policy endorsements showing the following minimum coverage by an insurance company(s) acceptable to the City's Risk Manager. A waiver of subrogation is required on all applicable policies. Endorsements must be provided with COI. Project name and or number must be listed in Description Box of COI. TYPE OF INSURANCE MINIMUM INSURANCE COVERAGE 30-written day notice of cancellation, Bodily Injury and Property Damage required on all certificates or by Per occurrence - aggregate applicable policy endorsements PROFESSIONAL LIABILITY $1,000,000 Per Claim (Errors and Omissions) If claims made policy, retro date must be prior to inception of agreement, have 3-year reporting period provisions or be maintained for 3 years after project completion. 1.3 In the event of accidents of any kind related to this agreement, Consultant must furnish the City with copies of all reports of any accidents within 10 days of the accident. 1.4 Consultant shall obtain and maintain in full force and effect for the duration of this Contract, and any extension hereof, at Consultant's sole expense, insurance coverage written on an occurrence basis, with the exception of professional liability, which may be on a per claims made basis, by companies authorized and admitted to do business in the State of Texas and with an A.M. Best's rating of no less than A- VII. Consultant is required to provide City with renewal Certificates. 1 Rev 12/20 DocuSign Envelope ID:71FE69C2-3B81-4095-AFFD-5B86994835DB 1.5 Consultant is required to submit a copy of the replacement certificate of insurance to City at the address provided below within 10 days of the requested change. Consultant shall pay any costs incurred resulting from said changes. All notices under this Article shall be given to City at the following address: City of Corpus Christi Attn: Engineering Services P.O. Box 9277 Corpus Christi, TX 78469-9277 1.6 Consultant agrees that with respect to the above required insurance, all insurance policies are to contain or be endorsed to contain the following required provisions: 1.6.1 Provide thirty (30) calendar days advance written notice directly to City of any suspension, cancellation or non-renewal of coverage, and not less than ten (10) calendar days advance written notice for nonpayment of premium. 1.7 Within five (5) calendar days of a suspension, cancellation or non-renewal of coverage, Consultant shall provide a replacement Certificate of Insurance and applicable endorsements to City. City shall have the option to suspend Consultant's performance should there be a lapse in coverage at any time during this contract. Failure to provide and to maintain the required insurance shall constitute a material breach of this contract. 1.8 In addition to any other remedies the City may have upon Consultant's failure to provide and maintain any insurance or policy endorsements to the extent and within the time herein required, the City shall have the right to order Consultant to remove the exhibit hereunder, and/or withhold any payment(s) if any, which become due to Consultant hereunder until Consultant demonstrates compliance with the requirements hereof. 1.9 Nothing herein contained shall be construed as limiting in any way the extent to which Consultant may be held responsible for payments of damages to persons or property resulting from Consultant's or its subcontractor's performance of the work covered under this agreement. 1.10 It is agreed that Consultant's insurance shall be deemed primary and non- contributory with respect to any insurance or self-insurance carried by the City of Corpus Christi for liability arising out of operations under this agreement. 1.11 It is understood and agreed that the insurance required is in addition to and separate from any other obligation contained in this agreement. 2 Rev 12/20 DocuSign Envelope ID:71FE69C2-3B81-4095-AFFD-5B86994835DB SUPPLIER NUMBER TO BE ASSIGNED BY CITE PURCHASING DIVISION City of' CITY OF CORPUS CHRISTI Corpus DISCLOSURE OF INTEREST Christi City of Corpus Christi Ordinance 17112, as amended,requires all persons or firms seeking to do business with the City to provide the following information. Every question must be answered. If the question is not applicable, answer with "NA". See reverse side for Filing Requirements, Certifications and definitions. COMPANY NAME: HDR Engineering, Inc. P.O.BOX: STREET ADDRESS: 555 N Carancahua St. Ste1600 CITY: Corpus Christi ZIP: 78401 FIRM IS: 1. Corporation ® 2. Partnership ❑ 3. Sole Owner E]4. Association 5. Other DISCLOSURE QUESTIONS If additional space is necessary please use the reverse si ` de of this page or attach separate sheet. 1. State the names of each employee" of the City of Corpus Christi having an "ownership interest" constituting 3% or more of the ownership in the above named"firm." -Name Job Title and City Department(if known) N/A 2. State the names of each "official" of the City of Corpus Christi having an "ownership interest" constituting 3% or more of the ownership in the above named"firm." -Name Title N/A 3. State the names of each "board member" of the City of Corpus Christi having an "ownership interest" constituting 3% or more of the ownership in the above named"firm." _Name Board, Commission or Committee N/A 4. State the names of each employee or officer of a "consultant" for the City of Corpus Christi who worked on any matter related to the subject of this contract and has an "ownership interest" constituting 3%or more of the ownership in the above named"firm." Name Consultant N/A DocuSign Envelope ID:71FE69C2-3B81-4095-AFFD-5B86994835DB FILING REQUIREMENTS If a person who requests official action on a matter knows that the requested action will confer an economic benefit on any City official or employee that is distinguishable from the effect that the action will have on members of the public in general or a substantial segment thereof,you shall disclose that fact in a signed writing to the City official, employee or body that has been requested to act in the matter, unless the interest of the City official or employee in the matter is apparent. The disclosure shall also be made in a signed writing filed with the City Secretary. [Ethics Ordinance Section 2-349 (d)] CERTIFICATION I certify that all information provided is true and correct as of the date of this statement, that I have not knowingly withheld disclosure of any information requested; and that supplemental statements will be promptly submitted to the City of Corpus Christi, Texas as changes occur. Certifying Person: David C Weston Title: Vice President (Type or Print) Signature of Certifying % Date: Person: " 5/17/2023 DEFINITIONS a. `Board member." A member of any board, commission, or committee appointed by the City Council of the City of Corpus Christi, Texas. b. "Economic benefit". An action that is likely to affect an economic interest if it is likely to have an effect on that interest that is distinguishable from its effect on members of the public in general or a substantial segment thereof. c. "Employee." Any person employed by the City of Corpus Christi, Texas either on a full or part- time basis,but not as an independent contractor. d. "Firm." Any entity operated for economic gain, whether professional,industrial or commercial, and whether established to produce or deal with a product or service, including but not limited to, entities operated in the form of sole proprietorship, as self-employed person, partnership, corporation, joint stock company, joint venture, receivership or trust, and entities which for purposes of taxation are treated as non-profit organizations. e. "Official." The Mayor, members of the City Council, City Manager, Deputy City Manager, Assistant City Managers, Department and Division Heads, and Municipal Court Judges of the City of Corpus Christi, Texas. f. "Ownership Interest." Legal or equitable interest, whether actually or constructively held, in a firm, including when such interest is held through an agent, trust, estate, or holding entity. "Constructively held" refers to holdings or control established through voting trusts, proxies, or special terms of venture or partnership agreements." g. "Consultant."Any person or firm, such as engineers and architects, hired by the City of Corpus Christi for the purpose of professional consultation and recommendation. DocuSign Envelope ID:71FE69C2-3B81-4095-AFFD-5B86994835DB Page 1 of 2 A CERTIFICATE OF LIABILITY INSURANCE 705/12/2023 (M THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies)must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT Willis Towers Watson Certificate Center NAME: Willis Towers Watson Midwest, Inc. c/o 26 Century Blvd PHONE 1-877-945-7378 FAX 1-888-467-2378 A/C No Ext): A/C,No): E-MAIL P.O. Box 305191 ADDRESS: certificates@willis.com Nashville, TN 372305191 USA INSURER(S)AFFORDING COVERAGE NAIC# INSURERA: Liberty Mutual Fire Insurance Company 23035 INSURED INSURER B: Ohio Casualty Insurance Company 24074 HDR Engineering, Inc. 1917 South 67th Street INSURERC: Liberty Insurance Corporation 42404 Omaha, NE 68106 INSURER D: INSURER E: INSURER F: COVERAGES CERTIFICATE NUMBER: W28959872 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR TYPE OF INSURANCE ADDL SUBR POLICY EFF POLICY EXP LIMITS LTR INSD WVD POLICY NUMBER MMIDD/YYY MMIDD/YYY X COMMERCIAL GENERAL LIABILITY EACH OCCURRENCE $ 2,000,000 � OCCUR PREMISES DAMAGE TORENTED CLAIMS-MADE PREMISES Ea occurrence $ 1,000,000 A X Contractual Liability MED EXP(Any one person) $ 10,000 Y Y TB2-641-444950-032 06/01/2022 06/01/2023 PERSONAL&ADV INJURY $ 2,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $ 4,000,000 POLICY PRO- X LOC PRODUCTS-COMP/OP AGG $ 4,000,000 OTHER: $ AUTOMOBILE LIABILITY COMBINED SINGLE LIMIT $ 2,000,000 Ea accident X ANY AUTO BODILY INJURY(Per person) $ A OWNED SCHEDULED Y Y AS2-641-444950-042 06/01/2022 06/01/2023 BODILY INJURY(Per accident) $ AUTOS ONLY AUTOS HIRED NON-OWNED PROPERTY DAMAGE $ AUTOS ONLY AUTOS ONLY Per accident B UMBRELLA LIAB X OCCUR EACH OCCURRENCE $ 5,000,000 X EXCESS LIAB CLAIMS-MADE Y Y EUO(23)57919363 06/01/2022 06/01/2023 AGGREGATE $ 5,000,000 DED X RETENTION$ 0 $ WORKERS COMPENSATION X PER OTH- AND EMPLOYERS'LIABILITY STATUTE ER C ANYPROPRIETOR/PARTNER/EXECUTIVE Y/N E.L.EACH ACCIDENT $ 1,000,000 OFFICER/MEMBER EXCLUDED? No NIA Y WA7-64D-444950-012 06/01/2022 06/01/2023 1,000,000 (Mandatory in NH) E.L.DISEASE-EA EMPLOYEE $ If yes,describe under 1,000,000 DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $ DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES (ACORD 101,Additional Remarks Schedule,maybe attached if more space is required) Certificate Holder is named as Additional Insured on General Liability, Automobile Liability and Umbrella/Excess Liability on a Primary, Non-contributory basis where required by written contract. Waiver of Subrogation applies on General Liability, Automobile Liability, Umbrella/Excess Liability and Workers Compensation where required by written contract and as permitted by law. Umbrella/Excess policy is follow form over General Liability, Auto Liability and Employers Liability. CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. City of Corpus Christi AUTHORIZED REPRESENTATIVE Attn: Procurement PO Box 9277 144166 (�u Corpus Christi, TX 78469-9277 1� ©1988-2016 ACORD CORPORATION. All rights reserved. ACORD 25(2016/03) The ACORD name and logo are registered marks of ACORD SR ID: 24139110 BATCH: 2973599 DocuSign Envelope ID:71FE69C2-3B81-4095-AFFD-5B86994835DB AGENCY CUSTOMER ID: LOC#: ACoR" ADDITIONAL REMARKS SCHEDULE Page 2 Of 2 AGENCY NAMED INSURED Willis Towers Watson Midwest, Inc. HDR Engineering, Inc. 1917 South 67th Street POLICY NUMBER Omaha, NE 68106 See Page 1 CARRIER NAIC CODE See Page 1 See Page 1 EFFECTIVE DATE: See Page 1 ADDITIONAL REMARKS THIS ADDITIONAL REMARKS FORM IS A SCHEDULE TO ACORD FORM, FORM NUMBER: 25 FORM TITLE: Certificate of Liability Insurance Project: RFQ4413 - COCC General Civil MSA & Traffic Improvements MSA. Additional Insured: The City and its officers, officials, employees and elected representatives. Waiver of Subrogation: The City. ACORD 101 (2008/01) ©2008 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD SR ID: 24139110 BATCH: 2973599 CERT: W28959872 DocuSign Envelope ID:71FE69C2-3B81-4095-AFFD-5B86994835DB Policy Number. TI32-641-444950-032 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. DESIGNATED LOCATION(S) GENERAL AGGREGATE LIMIT This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Designated Location(s): All locations owned by or rented to the Named Insured Information required to complete this Schedule, if not shown above, will be shown in the Declarations. A. For all sums which the insured becomes legally b. Claims made or"suits" brought; or obligated to pay as damages caused by "occur- c. Persons or organizations making claims or rences" under Section I —Coverage A, and for all bringing "suits". medical expenses caused by accidents under Section I — Coverage C, which can be attributed 3. Any payments made under Coverage A for only to operations at a single designated "loca- damages or under Coverage C for medical tion"shown in the Schedule above: expenses shall reduce the Designated Loca- tion General Aggregate Limit for that desig- 1. A separate Designated Location General Hated "location". Such payments shall not re- Aggregate Limit applies each designated duce the General Aggregate Limit shown in "location", and that limit t is equal to the the the Declarations nor shall they reduce any amount the General Aggregate Limit other Designated Location General Aggre- gate Limit for any other designated "location" 2. The Designated Location General Aggregate shown in the Schedule above. Limit is the most we will pay for the sum of all 4. The limits shown in the Declarations for Each damages under Coverage A, except damag- Occurrence, Damage To Premises Rented To es because of "bodily injury" or "property g You and Medical Expense continue to apply. damage" included in the "products-completed However, instead of being subject to the operations hazard", and for medical expenses General Aggregate Limit shown in the Decla- under Coverage C regardless of the number rations, such limits will be subject to the appli- of: cable Designated Location General Aggre- a. Insureds; gate Limit. CG 25 04 05 09 © Insurance Services Office, Inc., 2008 Page 1 of 2 DocuSign Envelope ID:71FE69C2-3B81-4095-AFFD-5B86994835DB B. For all sums which the insured becomes legally C. When coverage for liability arising out of the obligated to pay as damages caused by 'occur- "products-completed operations hazard" is pro- rences" under Section I —Coverage A, and for all vided, any payments for damages because of medical expenses caused by accidents under "bodily injury" or "property damage" included in Section I — Coverage C, which cannot be at- the "products-completed operations hazard" will tributed only to operations at a single designated reduce the Products-completed Operations Ag- "location"shown in the Schedule above: gregate Limit, and not reduce the General Ag- 1. Any payments made under Coverage A for gregate Limit nor the Designated Location Gen- damages or under Coverage C for medical eral Aggregate Limit. expenses shall reduce the amount available D. For the purposes of this endorsement, the Defi- under the General Aggregate Limit or the nitions Section is amended by the addition of Products-completed Operations Aggregate the following definition: Limit, whichever is applicable; and "Location" means premises involving the same or 2. Such payments shall not reduce any Desig- connecting lots, or premises whose connection is nated Location General Aggregate Limit. interrupted only by a street, roadway, waterway or right-of-way of a railroad. E. The provisions of Section III — Limits Of Insur- ance not otherwise modified by this endorsement shall continue to apply as stipulated. Page 2 of 2 © Insurance Services Office, Inc., 2008 CG 25 04 05 09 DocuSign Envelope ID:71FE69C2-3B81-4095-AFFD-5B86994835DB Policy Number. TI32-641-444950-032 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. DESIGNATED CONSTRUCTION PROJECT(S) GENERAL AGGREGATE LIMIT This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Designated Construction Project(s): All construction projects not located at premises owned, leased or rented by a Named Insured Information required to complete this Schedule, if not shown above, will be shown in the Declarations. A. For all sums which the insured becomes legally 3. Any payments made under Coverage A for obligated to pay as damages caused by 'occur- damages or under Coverage C for medical rences" under Section I —Coverage A, and for all expenses shall reduce the Designated Con- medical expenses caused by accidents under struction Project General Aggregate Limit for Section I — Coverage C, which can be attributed that designated construction project. Such only to ongoing operations at a single designated payments shall not reduce the General Ag- construction project shown in the Schedule gregate Limit shown in the Declarations nor above: shall they reduce any other Designated Con- 1. A separate Designated Construction Project struction Project General Aggregate Limit for General Aggregate Limit applies to each des- any other designated construction project ignated construction project, and that limit is shown in the Schedule above. equal to the amount of the General Aggregate 4. The limits shown in the Declarations for Each Limit shown in the Declarations. Occurrence, Damage To Premises Rented To 2. The Designated Construction Project General You and Medical Expense continue to apply. Aggregate Limit is the most we will pay for the However, instead of being subject to the sum of all damages under Coverage A, ex- General Aggregate Limit shown in the Decla- cept damages because of "bodily injury" or rations, such limits will be subject to the appli- "property damage" included in the "products- cable Designated Construction Project Gen- completed operations hazard", and for medi- eral Aggregate Limit. cal expenses under Coverage C regardless of the number of: a. Insureds; b. Claims made or"suits" brought; or c. Persons or organizations making claims or bringing "suits". CG 25 03 05 09 © Insurance Services Office, Inc., 2008 Page 1 of 2 ❑ DocuSign Envelope ID:71FE69C2-3B81-4095-AFFD-5B86994835DB B. For all sums which the insured becomes legally C. When coverage for liability arising out of the obligated to pay as damages caused by 'occur- "products-completed operations hazard" is pro- rences" under Section I —Coverage A, and for all vided, any payments for damages because of medical expenses caused by accidents under "bodily injury" or "property damage" included in Section I — Coverage C, which cannot be at- the "products-completed operations hazard" will tributed only to ongoing operations at a single reduce the Products-completed Operations Ag- designated construction project shown in the gregate Limit, and not reduce the General Ag- Schedule above: gregate Limit nor the Designated Construction 1. Any payments made under Coverage A for Project General Aggregate Limit. damages or under Coverage C for medical D. If the applicable designated construction project expenses shall reduce the amount available has been abandoned, delayed, or abandoned under the General Aggregate Limit or the and then restarted, or if the authorized contract- Products-completed Operations Aggregate ing parties deviate from plans, blueprints, de- Limit, whichever is applicable; and signs, specifications or timetables, the project will 2. Such payments shall not reduce any Desig- still be deemed to be the same construction pro- nated Construction Project General Aggre- ject. gate Limit. E. The provisions of Section III — Limits Of Insur- ance not otherwise modified by this endorsement shall continue to apply as stipulated. Page 2 of 2 © Insurance Services Office, Inc., 2008 CG 25 03 05 09 DocuSign Envelope ID:71FE69C2-3B81-4095-AFFD-5B86994835DB POLICY NUMBER: TB2-641-444950- COMMERCIAL GENERAL LIABILITY 032 CG 20 10 12 19 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED - OWNERS, LESSEES OR CONTRACTORS - SCHEDULED PERSON OR ORGANIZATION This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART A Section II — Who Is An Insured is amended to 1. All work, including materials, parts or include as an additional insured the person(s) or equipment furnished in connection with such organization(s) shown in the Schedule, but only with work, on the project (other than service, respect to liability for "bodily injury", "property maintenance or repairs) to be performed by or damage" or "personal and advertising injury" on behalf of the additional insured(s) at the caused, in whole or in part,by: location of the covered operations has been 1. Your acts or omissions; or completed; or 2. The acts or omissions of those acting on your 2. That portion of "your work" out of which the behalf; injury or damage arises has been put to its in the performance of your ongoing operations for intended use by any person or organization the additional insured(s) at the location(s) other than another contractor or subcontractor designated above. engaged in performing operations for a principal as a part of the same project. However: C. With respect to the insurance afforded to these 1. The insurance afforded to such additional additional insureds, the following is added to insured only applies to the extent permitted by Section III — Limits Of Insurance: law; and If coverage provided to the additional insured is 2. If coverage provided to the additional insured is required by a contract or agreement, the most we required by a contract or agreement, the will pay on behalf of the additional insured is the insurance afforded to such additional insured will amount of insurance: not be broader than that which you are required 1. Required by the contract or agreement; or by the contract or agreement to provide for such additional insured. 2. Available under the applicable limits of B. With respect to the insurance afforded to these insurance; additional insureds, the following additional whichever is less. exclusions apply: This endorsement shall not increase the This insurance does not apply to "bodily injury" or applicable limits of insurance. "property damage"occurring after: SCHEDULE Name Of Additional Insured Person(s) Location(s) Of Covered Operations Or Organization(s): Any person or organization with whom you have agreed All locations as required by a written contract or through written contract, agreement or permit to provide agreement entered into prior to an'occurrence"or additional insured coverage offense Information required to complete this Schedule, if not shown above, will be shown in the Declarations. CG 20 10 12 19 © Insurance Services Office, Inc., 2018 Page 1 of 1 DocuSign Envelope ID:71FE69C2-3B81-4095-AFFD-5B86994835DB POLICY NUMBER: TB2-641-444950- COMMERCIAL GENERAL LIABILITY 032 CG 20 37 12 19 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED - OWNERS, LESSEES OR CONTRACTORS - COMPLETED OPERATIONS This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE PART A Section II — Who Is An Insured is amended to B. With respect to the insurance afforded to these include as an additional insured the person(s) or additional insureds, the following is added to organization(s) shown in the Schedule, but only Section III —Limits Of Insurance: with respect to liability for "bodily injury" or If coverage provided to the additional insured is "property damage" caused, in whole or in part, by required by a contract or agreement, the most we "your work" at the location designated and will pay on behalf of the additional insured is the described in the Schedule of this endorsement amount of insurance: performed for that additional insured and included in the"products-completed operations hazard". 1. Required by the contract or agreement;or However: 2. Available under the applicable limits of 1. The insurance afforded to such additional insurance; insured only applies to the extent permitted by whichever is less. law; and This endorsement shall not increase the applicable 2. If coverage provided to the additional insured is limits of insurance. required by a contract or agreement, the insurance afforded to such additional insured will not be broader than that which you are required by the contract or agreement to provide for such additional insured. SCHEDULE Name Of Additional Insured Person(s) OrOrganization(s): Location And Description Of Completed Operations Any person or organization to whom or to which you are Any location where you have agreed,through written, required to provide additional insured status in a written contract, agreement,or permit,to provide additional contract, agreement or permit except where such insured coverage for completed operations contact or agreement is prohibited. Information required to complete this Schedule, if not shown above, will be shown in the Declarations. CG 20 37 12 19 © Insurance Services Office, Inc., 2018 Page 1 of 1 DocuSign Envelope ID:71FE69C2-3B81-4095-AFFD-5B86994835DB Policy Number TB2-641-444950-032 Issued by Liberty Mutual Fire Insurance Company THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. PRIMARY AND NONCONTRIBUTORY- OTHER INSURANCE CONDITION This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE PART The following is added to Section IV-Conditions 4. Other Insurance and supersedes any provision to the contrary: Primary And Noncontributory Insurance This insurance is primary to and will not seek contribution from any other insurance available to an additional insured under your policy provided that: (1) The additional insured is a Named Insured under such other insurance; and (2) You have agreed prior to a loss, that this insurance would be primary and would not seek contribution from any other insurance available to the additional insured. (3) This insurance is excess over any other insurance available to the additional insured for which it is also covered as an additional insured by attachment of an endorsement to another policy providing coverage for the same 'occurrence", claim or"suit". LD 24 153 08 16 ©2016 Liberty Mutual Insurance Page 1 of 1 Includes copyrighted material of Insurance Services Office, Inc., with its permission. DocuSign Envelope ID:71FE69C2-3B81-4095-AFFD-5B86994835DB POLICY NUMBER: AS2-641-444950-042 COMMERCIAL AUTO CA 20 48 10 13 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. DESIGNATED INSURED FOR COVERED AUTOS LIABILITY COVERAGE This endorsement modifies insurance provided under the following: AUTO DEALERS COVERAGE FORM BUSINESS AUTO COVERAGE FORM MOTOR CARRIER COVERAGE FORM With respect to coverage provided by this endorsement, the provisions of the Coverage Form apply unless modified by this endorsement. This endorsement identifies person(s) or organization(s)who are "insureds" for Covered Autos Liability Coverage under the Who Is An Insured provision of the Coverage Form. This endorsement does not alter coverage provided in the Coverage Form. SCHEDULE Name Of Person(s) Or Organization(s): As required by written contract Information required to complete this Schedule, if not shown above, will be shown in the Declarations. Each person or organization shown in the Schedule is an "insured" for Covered Autos Liability Coverage, but only to the extent that person or organization qualifies as an "insured" under the Who Is An Insured provision contained in Paragraph A.1. of Section II — Covered Autos Liability Coverage in the Business Auto and Motor Carrier Coverage Forms and Paragraph D.2. of Section I — Covered Autos Coverages of the Auto Dealers Coverage Form. CA 20 48 10 13 © Insurance Services Office, Inc., 2011 Page 1 of 1 DocuSign Envelope ID:71FE69C2-3B81-4095-AFFD-5B86994835DB Policy Number:AS2-641-444950-042 Issued by: Liberty Mutual Fire Insurance Company THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. DESIGNATED INSURED - NONCONTRIBUTING This endorsement modifies insurance provided under the following: BUSINESS AUTO COVERAGE FORM GARAGE COVERAGE FORM MOTOR CARRIERS COVERAGE FORM TRUCKERS COVERAGE FORM With respect to coverage provided by this endorsement, the provisions of the Coverage Form apply unless modified by this endorsement. This endorsement identifies person(s) or organization(s)who are"insureds" under the Who Is An Insured Provision of the Coverage Form. This endorsement does not alter coverage provided in the Coverage form. Schedule Name of Person(s) or Organizations(s): Any person or organization where the Named Insured has agreed by written contract to include such person or organization Regarding Designated Contract or Project: Any Each person or organization shown in the Schedule of this endorsement is an"insured"for Liability Coverage,but only to the extent that person or organization qualifies as an "insured" under the Who Is An Insured Provision contained in Section II of the Coverage Form. The following is added to the Other Insurance Condition: If you have agreed in a written agreement that this policy will be primary and without right of contribution from any insurance in force for an Additional Insured for liability arising out of your operations, and the agreement was executed prior to the "bodily injury" or "property damage", then this insurance will be primary and we will not seek contribution from such insurance. AC 84 23 0811 C 2010, Liberty Mutual Group of Companies. All rights reserved. Page 1 of 1 Includes copyrighted material of Insurance Services Office,Inc., with its permission. DocuSign Envelope ID:71FE69C2-3B81-4095-AFFD-5B86994835DB POLICY NUMBER: T 2-641-444950-032 COMMERCIAL GENERAL LIABILITY CG 24 04 12 19 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US (WAIVER OF SUBROGATION) This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART ELECTRONIC DATA LIABILITY COVERAGE PART LIQUOR LIABILITY COVERAGE PART POLLUTION LIABILITY COVERAGE PART DESIGNATED SITES POLLUTION LIABILITY LIMITED COVERAGE PART DESIGNATED SITES PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE PART RAILROAD PROTECTIVE LIABILITY COVERAGE PART UNDERGROUND STORAGE TANK POLICY DESIGNATED TANKS SCHEDULE Name Of Person(s) Or Organization(s): As required by written contract or agreement. Information required to complete this Schedule, if not shown above, will be shown in the Declarations. The following is added to Paragraph 8. Transfer Of Rights Of Recovery Against Others To Us of Section IV—Conditions: We waive any right of recovery against the person(s) or organization(s) shown in the Schedule above because of payments we make under this Coverage Part. Such waiver by us applies only to the extent that the insured has waived its right of recovery against such person(s) or organization(s) prior to loss. This endorsement applies only to the person(s) or organization(s) shown in the Schedule above. CG 24 04 12 19 © Insurance Services Office, Inc., 2018 Page 1 of 1 DocuSign Envelope ID:71FE69C2-3B81-4095-AFFD-5B86994835DB POLICY NUMBER: AS2-641-444950-042 COMMERCIAL AUTO CA 04 44 10 13 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US (WAIVER OF SUBROGATION) This endorsement modifies insurance provided under the following: AUTO DEALERS COVERAGE FORM BUSINESS AUTO COVERAGE FORM MOTOR CARRIER COVERAGE FORM With respect to coverage provided by this endorsement, the provisions of the Coverage Form apply unless modified by the endorsement. SCHEDULE Name(s) Of Person(s) Or Organization(s): Any person or organization for whom you perform work under a written contract of the contract requires you to obtain this agreement from us but only if the contract is executed prior to the injury or damage occurring. Information required to complete this Schedule, if not shown above, will be shown in the Declarations. The Transfer Of Rights Of Recovery Against Others To Us condition does not apply to the person(s) or organization(s) shown in the Schedule, but only to the extent that subrogation is waived prior to the "accident" or the "loss" under a c ontract with that person or organization. CA 04 44 10 13 © Insurance Services Office, Inc., 2011 Page 1 of 1 DocuSign Envelope ID:71FE69C2-3B81-4095-AFFD-5B86994835DB WAIVER OF OUR RIGHT TO RECOVER FROM OTHERS ENDORSEMENT We have the right to recover our payments from anyone liable for an injury covered by this policy. We will not enforce our right against the person or organization named in the Schedule. (This agreement applies only to the extent that you perform work under a written contract that requires you to obtain this agreement from us.) This agreement shall not operate directly or indirectly to benefit anyone not named in the Schedule. Schedule Where required by contract or written agreement prior to loss. Issued by:Liberty Insurance Corporation For attachment to Policy No WA7-64D-444950-012 Effective Date 06/01/2022 Premium Issued to:HDR Engineering, Inc. WC 00 03 13 © 1983 National Council on Compensation Insurance, Inc. Page 1 of 1 Ed. 4/1/1984 DocuSign Envelope ID:71FE69C2-3B81-4095-AFFD-5B86994835DB Policy Number TB2-641-444950-032 Issued by Liberty Mutual Fire Insurance Company THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. NOTICE OF CANCELLATION OR MATERIAL REDUCTION IN COVERAGE TO THIRD PARTIES This endorsement modifies insurance provided under the following: BUSINESS AUTO COVERAGE PART MOTOR CARRIER COVERAGE PART GARAGE COVERAGE PART TRUCKERS COVERAGE PART EXCESS AUTOMOBILE LIABILITY INDEMNITY COVERAGE PART SELF-INSURED TRUCKER EXCESS LIABILITY COVERAGE PART COMMERCIAL GENERAL LIABILITY COVERAGE PART EXCESS COMMERCIAL GENERAL LIABILITY COVERAGE PART PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE PART LIQUOR LIABILITY COVERAGE PART COMMERCIAL LIABILITY— UMBRELLA COVERAGE FORM Schedule Name of Other Person(s)/ Email Address or mailing address: Number Days Notice: Organization(s): As required by written contract or As required by written contract or 30 written agreement written agreement A. If we cancel this policy for any reason other than nonpayment of premium, or make a material reduction in coverage, we will notify the persons or organizations shown in the Schedule above. We will send notice to the email or mailing address listed above at least 10 days, or the number of days listed above, if any, before the cancellation becomes effective. In no event does the notice to the third party exceed the notice to the first named insured. B. This advance notification of a pending cancellation or material reduction of coverage is intended as a courtesy only. Our failure to provide such advance notification will not extend the policy cancellation date nor negate cancellation of the policy. All other terms and conditions of this policy remain unchanged. LIM 99 04 03 14 ©2014 Liberty Mutual Insurance.All rights reserved. Page 1 of 1 Includes copyrighted material of Insurance Services Office, Inc., with its permission. DocuSign Envelope ID:71FE69C2-3B81-4095-AFFD-5B86994835DB Policy NumberAS2-641-444950-042 Issued by Liberty Mutual Fire Insurance Company THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. NOTICE OF CANCELLATION OR MATERIAL REDUCTION IN COVERAGE TO THIRD PARTIES This endorsement modifies insurance provided under the following: BUSINESS AUTO COVERAGE PART MOTOR CARRIER COVERAGE PART GARAGE COVERAGE PART TRUCKERS COVERAGE PART EXCESS AUTOMOBILE LIABILITY INDEMNITY COVERAGE PART SELF-INSURED TRUCKER EXCESS LIABILITY COVERAGE PART COMMERCIAL GENERAL LIABILITY COVERAGE PART EXCESS COMMERCIAL GENERAL LIABILITY COVERAGE PART PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE PART LIQUOR LIABILITY COVERAGE PART COMMERCIAL LIABILITY— UMBRELLA COVERAGE FORM Schedule Name of Other Person(s)/ Email Address or mailing address: Number Days Notice: Organization(s): As required by written contract 30 or written agreement A. If we cancel this policy for any reason other than nonpayment of premium, or make a material reduction in coverage, we will notify the persons or organizations shown in the Schedule above. We will send notice to the email or mailing address listed above at least 10 days, or the number of days listed above, if any, before the cancellation becomes effective. In no event does the notice to the third party exceed the notice to the first named insured. B. This advance notification of a pending cancellation or material reduction of coverage is intended as a courtesy only. Our failure to provide such advance notification will not extend the policy cancellation date nor negate cancellation of the policy. All other terms and conditions of this policy remain unchanged. LIM 99 04 03 14 ©2014 Liberty Mutual Insurance.All rights reserved. Page 1 of 1 Includes copyrighted material of Insurance Services Office, Inc., with its permission. DocuSign Envelope ID:71FE69C2-3B81-4095-AFFD-5B86994835DB NOTICE OF CANCELLATION TO THIRD PARTIES A. If we cancel this policy for any reason other than nonpayment of premium, we will notify the persons or organizations shown in the Schedule below. We will send notice to the email or mailing address listed below at least 10 days, or the number of days listed below, if any, before cancellation becomes effective. In no event does the notice to the third party exceed the notice to the first named insured. B. This advance notification of a pending cancellation of coverage is intended as a courtesy only. Our failure to provide such advance notification will not extend the policy cancellation date nor negate cancellation of the policy. Schedule Name of Other Person(s)/ Email Address or mailing address: Number Days Notice: Organization(s): As required by written 30 contract or agreement All other terms and conditions of this policy remain unchanged. Issued by Liberty Insurance Corporation For attachment to Policy No.WA7-641)444950-012 Effective Date 06/01/2022 Premium$ Issued to HDR Engineering,Inc. Endorsement No. WC 99 20 75 ©2016 Liberty Mutual Insurance Page 1 of 1 Ed.12/01/2016