Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
Home
My WebLink
About
C2024-228 - 11/12/2024 - Approved
ES CONTRACT DOCUMENTS FOR DESIGN AND CONSTRUCTION OF Industrial Park Roadway Improvements Project PROJECT NUMBER 23104 0 ›-1 Ci to tat Ertl 3 Nal iiimortra ii. �.•N�� 11W. r oiIP0R /2 00 0100 TABLE OF CONTENTS Division / Section Title Division 00 Contracting Requirements 00 52 26 Design -Build Agreement (Lump Sum) 00 61 14 Performance Bond (DB) 00 61 17 Payment Bond (DB) 00 72 OODB General Conditions — Design -Build (LS) Exhibit A Design Criteria Package END OF SECTION Table of Contents Industrial Park Roadway Improvements (23104) 000100-1 Rev 6/2021 gs A� U® CERTIFICATE OF LIABILITY INSURANCE DATE(MMrDD/YYYY) 11/18/2024 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder Is an ADDITIONAL INSURED, the policy(les) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder In lieu of such endorsement(s). PRODUCER Upshaw Insurance Agency, Inc. 801 S. Fillmore, Suite 300�r�o Amarillo TX 79101 CONTACT NAME' Lauren Lane PHONE FAX Extl: 806-468-0400 (Arc. No): 806-468-0450 ADDRESS: laurenf((upshaw-insurance.com INSURERIS)AFFORD ING COVERAGE NAJC 0 INSURER A: United Fire and Casualty Co. 13021 INSURED MAKOCON-01 Mako Contracting LLC 3636 S. Alameda, Suite B153 Corpus Christi TX 78411 INSURER B: INSURERC: INSURER D: INSURER E: INSURER F : COVERAGES CERTIFICATE NUMBER:312377468 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. IN8R LTR TYPE OF INSURANCE ADDL !NM SUUR WWI POLICY NUMBER POLICY EFF (MM/DD/YYYY) PILICY EXP (MMmDIYYY`f1 LIMITS A X COMMERCIAL GENERAL UABILITY 85326132 6/23/2024 6/23/2025 EACH OCCURRENCE S 1,000,000 CLAIMS -MADE n OCCUR DAMAGETO RENTED PREMMISES (Ea occurrence) S 500,000 MED EXP (Any ono person) S 10,000 PERSONAL 8 AOV INJURY S 1,000,000 GEM -AGGREGATE LIMIT APPLIES PER: POLICY [ X I jEC LOC OTHER: GENERAL AGGREGATE S 2,000,000 PRODUCTS - COMP/OP AGG 5 2,000,000 S A AUTOMOBILE X X LIABILITY ANY AUTO OWNED AUTOS ONLY HIRED y _ SCHEDULED AUTOS NON -OWNED AUTOS ONLY 85326132 6/23/2024 8232025 COMBINED stNGLE L(MIT (Ea accident) s 1,000,000 BODILY INJURY (Per person) S BODILY INJURY (Per occident) S PROPERTY DAMAGE (Par accident) S S A X UMBRELLA LIAO EXCESS LIAB X OCCUR CLAIMS -MADE 85326132 6/23/2024 8232025 EACHOCCURRENCE 52,000,000 AGGREGATE S 2,000,000 DEO RETENTIONS S A WORKERS COMPENSATION AND EMPLOYERS' LIABILITY Y / N ANYPROPRIETOR/PARTNER/EXECUTIVE OFFICER/MEMBEREXCLUDED? (Mandatory In NH) It yyeea, describe under DESCRIPTION OF OPERATIONS below N IA 85326132 6/23/2024 823/2025 X STATUTE I ERH E.L. EACH ACCIDENT S 1,000,000 E.L DISEASE • EA EMPLOYEE S 1,000,000 E.L. DISEASE • POLICY LIMIT S 1,000,000 A A Equipment Floater Properly 85326132 85326132 6/23/2024 6/23/2024 8232025 823/2025 DESCRIPTION OF OPERATIONS / LOCATIONS 1 VEHICLES (ACORD 101, Additional Remarks Seteduls, may be attached If more space Is requtrad) Endts shown apply only If there is a written contract between the named Insured & certificate holder that requires such coverage. GL,AU: Policies Include a blanket additional insured endt (GL per attached CG7208 07/17 including ongoing & completed operations and CG2001 12/19 primary & non-contributory). GL, WC & AU: Policies include a blanket waiver of subrogation endt. UMB: Follows form on underlying additional Insureds Including primary & non-contributory and waivers of subrogation; underlying policies include GL & AU. 30 days Notice of Cancellation applies except 10 days for non -pay. Project name and number: Industrial Park Roadway Improvements Project No. 23104 CERTIFICATE HOLDER CANCELLATION City of Corpus Christi, Texas 1201 Leopard Street Corpus Christi TX 78401 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPR SENTATIVE ACORD 25 (2016/03) ©1988.2015 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD COMMERCIAL GENERAL LIABILITY CG20011219 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. PRIMARY AND NONCONTRIBUTORY - OTHER INSURANCE CONDITION This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART LIQUOR LIABILITY COVERAGE PART PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE PART The following is added to the Other Insurance Condition and supersedes any provision to the contrary: Primary And Noncontributory Insurance This insurance is primary to and will not seek contribution from any other insurance available to an additional insured under your policy provided that: (1) The additional insured is a Named Insured under such other insurance; and CG 20 011219 (2) You have agreed in writing in a contract or agreement that this insurance would be primary and would not seek contribution from any other insurance available to the additional insured. © Insurance Services Office, Inc., 2018 Page 1 of 1 CG 72 08 07 17 C. SUPPLEMENTARY PAYMENTS — COVERAGES A AND B is amended: 1. To read SUPPLEMENTARY PAYMENTS 2. Bail Bonds Item 1.b. is amended as follows: b. Up to $1,000 for cost of bail bonds required because of accidents or traffic law violations arising out of the use of any vehicle to which the Bodily Injury Liability Coverage applies. We do not have to furnish these bonds. 3. Loss of Earnings Item 1.d. is amended as follows: d. All reasonable expenses incurred by the insured at our request to assist us in the investigation or defense of the claim or "suit", including actual loss of earnings up to $500 a day because of time off from work. 4. The following language is added to Item 1. However, we shall have none of the duties set forth above when thls insurance applies only for Voluntary Property Damage Coverage and/or Care, Custody or Control Property Damage Coverage and we have paid the Limit of Liability or the Aggregate Limit for these coverages. SECTION II - WHO IS AN INSURED A. The following change is made: Extended Reporting Requirements Item 3.a. is deleted and replaced by the following : a. Coverage under this provision is afforded only until the 180th day after you acquire or form the organization or the end of the policy period, whichever is earlier. B. The following provisions are added: 4. BROAD FORM NAMED INSURED Item 1.f. is added as follows: f. Any legally incorporated entity of which you own more than 50 percent of the voting stock during the policy period only if there is no other similar insurance available to that entity. However: (1) Coverage A does not apply to "bodily injury" or "property damage" that occurred before you acquired more than 50 percent of the voting stock; and (2) Coverage B does not apply to "personal and advertising injury" arising out of an offense committed before you acquired more than 50 percent of the voting stock. 5. Additional Insured — Owners, Lessees or Contractors -Automatic Status When Required in Construction or Service Agreement With You — Including Upstream Parties a. Any person or organization for whom you are performing operations when you and such person or organization have agreed in writing in a contract or agreement that such person or organization be added as an additional insured on your policy; b. Any other person or organization you are required to add as an additional insured under the contract or agreement described in Paragraph a. above. Such person(s) or organization(s) is an additional insured only with respect to liability for "bodily injury", "property damage" or "personal and advertising injury" which may be imputed to that person or organization directly arising out of: 1. Your acts or omissions; or 2. The acts or omissions of those acting on your behalf; In the performance of your ongoing operations for the additional insured. However, the insurance afforded to such additional insured: 1. Only applies to the extent permitted by law; and CG 72 08 07 17 Includes copyrighted material of Insurance Services Office, Inc., with its permission. Page 5 of 14 CG 72 08 07 17 2. Will not be broader than that which you are required by the contract or agreement to provide for such additional insured. c. With respect to the insurance afforded to these additional insureds, the following additional exclusions apply: This insurance does not apply to: 1. "Bodily injury", "property damage" or "personal and advertising injury" arising out of the rendering of, or the failure to render, any professional architectural, engineering or surveying services, including: a. The preparing, approving, or failing to prepare or approve, maps, shop drawings, opinions, reports, surveys, field orders, change orders or drawings and specifications; or b. Supervisory, inspection, architectural or engineering activities. This exclusion applies even if the claims against any insured allege negligence or other wrongdoing in the supervision, hiring, employment, training or monitoring of others by that insured, if the "occurrence" which caused the "bodily injury" or "property damage", or the offense which caused the "personal and advertising injury", involved the rendering of or the failure to render any professional architectural, engineering or surveying services. 2. "Bodily injury" or "property damage" occurring after: a. All work, including materials, parts or equipment furnished in connection with such work, on the project (other than service, maintenance or repairs) to be performed by or on behalf of the additional insured(s) at the location of the covered operations has been completed; or b. That portion of "your work" out of which the injury or damage arises has been put to its intended use by any person or organization other than another contractor or subcontractor engaged in performing operations for a principal as a part of the same project. 6. Additional Insured — Products Completed Operations Coverage — Including Upstream Parties a. Any person or organization for whom you are performing operations when you and such person or organization have agreed in writing in a contract or agreement that such person or organization be added as an additional insured on your policy; and b. Any other person or organization you are required to add as an additional insured under the contract or agreement described in Paragraph a. above. Such person(s) or organization(s) is an additional insured only with respect to liability for "bodily injury", "property damage" or "personal and advertising injury" which may be imputed to that person or organization directly arising out of "your work" specified in the "written contract" and included in the "products -completed operations hazard". However: (1) The insurance afforded to such additional insureds only applies to the extent permitted by law; (2) If coverage provided to the additional insured is required by a contract or agreement, the insurance afforded to such additional insured will not be broader than that which you are required by the contract or agreement to provide for such additional insured. (3) Such coverage will not apply subsequent to the first to occur of the following: I. The expiration of the period of time required by the "written contract"; or II. The expiration of any applicable statute of limitations or statute of repose with respect to claims arising out of "your work". c. With respect to the insurance afforded to any additional insured under this endorsement, the following additional exclusionary language shall apply: This insurance does not apply to "bodily injury" or "property damage" arising out of the rendering of, or the failure to render, any professional architecture, engineering or surveying services, including: (1) The preparing, approving, or failing to prepare or approve, maps, shop drawings, opinions, reports, surveys, field orders, change orders or drawings and specifications; or (2) Supervisory, inspection, architectural or engineering activities. CG 72 08 07 17 Includes copyrighted material of Insurance Services Office, Inc., with its permission. Page 6 of 14 CG72080717 7. Additional Insured — Vendors a. Any person(s) or organization(s) (referred to throughout this additional coverage as vendor), but only with respect to "bodily injury" or "property damage", which may be imputed to that person(s) or organization(s) arising out of "your products" shown with the Schedule which are distributed or sold in the regular course of the vendor's business is an insured. However: (1) The insurance afforded to such vendor only applies to the extent permitted by law; and (2) If coverage provided to the vendor is required by a contract or agreement, the insurance afforded to such vendor will not be broader than that which you are required by the contract or agreement to provide for such vendor. b. With respect to the insurance afforded to these vendors, the following additional exclusions apply: (1) This insurance afforded the vendor does not apply to: (a) "Bodily injury" or "property damage" for which the vendor is obligated to pay damages by reason of the assumption of liability in a contract or agreement. This exclusion does not apply to liability for damages that the vendor would have in the absence of the contract or agreement; (b) Any express warranty unauthorized by you; (c) Any physical or chemical change in the product made intentionally by the vendor, (d) Repackaging, except when unpacked solely for the purpose of inspection, demonstration, testing, or the substitution of parts under instructions from the manufacturer, and then repackaged in the original container. (e) Any failure to make such inspections, adjustments, tests or servicing as the vendor has agreed to make or normally undertakes to make in the usual course of business, in connection with the distribution or sale of products. Demonstration, installation, servicing or repair operations, except such operations performed at the vendor's premises in connection with the sale of the product. Products which, after distribution or sale by you, have been labeled or relabeled or used as a container, part or ingredient of any other thing or substance by or for the vendor. (h) "Bodily injury" or "property damage" arising out of the sole negligence of the vendor for its own acts or omissions or those of its employees or anyone else acting on its behalf. However, this exclusion does not apply to: i. The exceptions contained in Sub -paragraphs d. or f.; or II. Such inspections, adjustments, tests or servicing as the vendor has agreed to make or normally undertakes to make in the usual course of business, in connection with the distribution or sale of the products. (2) This insurance does not apply to any insured person or organization, from whom you have acquired such products, or any ingredient, part or container, entering into, accompanying or containing such products. 8. Additional Insured — Lessor of Leased Equipment — Automatic Status When Required in Lease Agreement With You a. Any person(s) or organization(s) from whom you lease equipment when you and such person(s) or organization(s) have agreed in writing in a contract or agreement that such person(s) or organization(s) be added as an additional insured on your policy. Such person(s) or organization(s) is an insured only with respect to your liability for "bodily injury", "property damage" or "personal and advertising injury" directly arising out of the maintenance, operation or use of equipment leased to you, which may be imputed to such person or organization as the lessor of equipment. However, the insurance afforded to such additional insured: (1) Only applies to the extent permitted by law; and (2) Will not be broader than that which you are required by the contract or agreement to provide for such additional insured. (f) (0) CG 72 08 07 17 Includes copyrighted material of Insurance Services Office, Inc., with its permission. Page 7 of 14 CG 72 08 07 17 A person's or organization's status as an additional insured under this endorsement ends when their contract or agreement with you for such leased equipment ends. b. With respect to the insurance afforded to these additional insureds, this Insurance does not apply to any "occurrence" which takes place after the equipment lease expires. 9. Additional Insured — Managers or Lessors of Premises a. Any person(s) or organization(s), but only with respect to liability arising out of the ownership, maintenance or use of that part of the premises leased to you and subject to the following additional exclusions: This insurance does not apply to: (1) Any "occurrence" which takes place after you cease to be a tenant in that premises. (2) Structural alterations, new construction or demolition operations performed by or on behalf of the person(s) or organization(s) shown in the Schedule. However: (1) The insurance afforded to such additional insured only applies to the extent permitted by law; and (2) If coverage provided to the additional insured is required by a contract or agreement, the Insurance afforded to such additional insured will not be broader than that which you are required by the contract or agreement to provide for such additional insured. 10. Additional Insured — Engineers, Architects or Surveyors Not Engaged by the Named Insured a. Any architects, engineers or surveyors who are not engaged by you are insureds, but only with respect to liability for "bodily injury" or "property damage" or "personal and advertising injury" which may be imputed to that architect, engineer or surveyor arising out of: (1) Your acts or omissions; or (2) Your acts or omissions of those acting on your behalf; in the performance of your ongoing operations performed by you or on your behalf. But only if such architects, engineers or surveyors, while not engaged by you, are contractually required to be added as an additional insured to your policy. However, the insurance afforded to such additional insured: (1) Only applies to the extent permitted by law; and (2) Will not be broader than that which you are required by the additional insured. With respect to the insurance afforded to these additional insureds, the following additional exclusion applies: This insurance does not apply to "bodily injury", "property damage" or "personal and advertising injury" arising out of the rendering of or failure to render any professional services, including: (1) The preparing, approving, or failing to prepare or approve, maps, drawings, opinions, reports, surveys, change orders, designs or specifications; or (2) Supervisory, inspection or engineering services. This exclusion applies even if the claims against any insured allege negligence or other wrongdoing in the supervision, hiring, employment, training or monitoring of others by that insured, if the "occurrence" which caused the "bodily injury" or "property damage", or the offense which caused the "personal and advertising injury", involved the rendering of or the failure to render any professional services. 11. Additional Insured — State or Governmental Agency or Subdivision or Political Subdivision — Permits or Authorizations Any state or governmental agency or subdivision or political subdivision is an insured, subject to the following provisions: b. contract or agreement to provide for such CG 72 08 07 17 Includes copyrighted material of Insurance Services Office, Inc., with its permission. Page 8 of 14 CG 72 08 07 17 a. This insurance applies only with respect to operations performed by you or on your behalf for which the state or governmental agency or subdivision or political subdivision has issued a permit or authorization. However: (1) The Insurance afforded to such additional insured only applies to the extent permitted by law; and (2) If coverage provided to the additional insured is required by a contract or agreement, the insurance afforded to such additional insured will not be broader than that which you are required by the contract or agreement to provide for such additional insured. b. This insurance does not apply to: (1) "Bodily injury", "property damage" or "personal and advertising injury" arising out of operations performed for the federal government, state or municipality; or (2) "Bodily injury" or "property damage" included within the "products -completed operations hazard". 12. Additional Insured Consolidated Insurance Program (Wrap -Up) Off -Premises Operations Only — Owners, Lessees or Contractors a. Any persons or organizations for whom you are performing operations, for which you have elected to seek coverage under a Consolidated Insurance Program, when you and such person or organization have agreed in writing in a contract or agreement that such person or organization be added as an additional insured on your policy as an insured. Such person or organization is an additional insured only with respect to your liability which may be imputed to that person or organization directly arising out of your ongoing operations performed for that person or organization at a premises other than any project or location that is designated as covered under a Consolidated Insurance Program. A person's or organization's status as an insured under this endorsement ends when your operations for that insured are completed. b. With respect to the insurance afforded to these additional insureds, the following additional exclusion applies, This insurance does not apply to: "Bodily injury", "property damage", or "personal and advertising injury" arising out of the rendering of, or failure to render, any professional architectural, engineering or surveying services, including: (1) The preparing, approving, or failing to prepare or approve, maps, shop drawings, opinions, reports, surveys, field orders, change orders or drawings and specifications; and (2) Supervisory, inspection, architectural or engineering activities. 13. Additional Insured — Employee Injury to Another Employee With respect to your "employees" who occupy positions which are supervisory in nature: Paragraph 2.a.(1) of SECTION II — WHO IS AN INSURED is amended to read: a. "Bodily injury" or "personal and advertising injury": (1) To you, to your partners or members (if you are a partnership or joint venture), or to your members (if you are a limited liability company); (2) For which there is any obligation to share damages with or repay someone else who must pay damages because of the injury described in paragraph (1)(a) above; or Arising out of his or her providing or failing to provide professional healthcare services. Paragraph 3.a. is deleted. (3) For the purpose of this Item 12 only, a position is deemed to be supervisory in nature if that person performs principle work which is substantially different from that of his or her subordinates and has authority to hire, direct, discipline or discharge. CG 72 08 07 17 Includes copyrighted material of Insurance Services Office, Inc., with its permission. Page 9 of 14 00 52 25 DESIGN/BUILD AGREEMENT (LUMP SUM) This Agreement, for the Project awarded on November 12, 2024, is between the City of Corpus Christi (Owner) and Mako Contracting, LLC (Design/Builder). Owner and Design/Builder agree as follows: ARTICLE 1— WORK 1.01 Design/Builder shall perform all design and construction services, and provide all material, equipment, tools and labor necessary to complete Work as specified or indicated in the Contract Documents. The Work is generally described as: Industrial Park Roadway Improvements Project No. 23104 ARTICLE 2 — OWNER'S AUTHORIZED REPRESENTATIVE 2.01 The Owner's Authorized Representative for this Project is: Joseph Johnson Assistant Director of Engineering Services — Construction Management 4917 Holly Road Corpus Christi, TX 78411 361-826-3691 JosephJ2@cctexas.com ARTICLE 3 — DESIGN SERVICES 3.01 Design/Builder shall perform all Design Services described in, contemplated by, inferable from, or necessary or desirable to achieve the objectives stated in the Design Criteria Package and the Contract, including all Design Services necessary for the Project to be properly constructed by Design/Builder and used, operated and maintained by Owner in accordance with all applicable guidelines, requirements and standards. The Design Criteria Package is included in the Request for Qualifications (RFQ) and is incorporated into this Contract by reference. The Design Services shall be performed within the time provided in the Schedule required by Article 4 of the General Conditions. 3.02 Design/Builder shall prepare, as necessary, surveys and topographic information including aerial photographs needed to establish line and grade of stormwater inlets, location of property lines and easements. Stormwater easements, both construction and permanent, shall be referenced to property lines by field surveys, and plans shall include the location of any improvement as it Design/Build Agreement LS Industrial Park Roadway Improvements (23104) 005225-1 Rev 5/2024 relates to property lines. Owner expressly does not warrant any information provided by it in connection with preparation of the above -mentioned information. 3.03 Design/Builder shall be responsible for performing subsurface utility investigations and identifying potential utility conflicts. Design/Builder shall prepare and submit to Owner prior to the 30% submittal a signed and sealed report identifying all utilities within the project area using Quality Level A exploratory excavation. Design/Builder agrees to coordinate the resolution of any utility conflicts and submit a monthly Utility Coordination Matrix to Owner. 3.04 Design/Builder shall be responsible for the professional quality, completeness, accuracy and coordination of Design Documents. Design/Builder shall provide Design Services that will result in an operationally cost-efficient and economical facility that meets all environmental and regulatory requirements as of the date hereof and uses the most appropriate available technology. Design/Builder shall provide for all quality control reviews required by sound professional architectural and engineering practices and by governmental authorities having jurisdiction over the Project. 3.05 Design/Builder shall design the Project to meet all applicable requirements of building control laws and regulations in relation to the design, construction, occupation and operation of the Project, including without limitation, environmental standards, fire and safety regulations, Americans with Disabilities Act (ADA) regulations, and requirements and compliance with other applicable standards and codes. 3.06 Design/Builder shall, without additional compensation, immediately correct any errors, omissions or deficiencies in its Design Services or Design Documents. ARTICLE 4 — PRELIMINARY DESIGN 4.01 Prior to the preparation of the preliminary design, Owner and Design/Builder shall meet as detailed in Article 2 of the General Conditions to discuss the requirements of the Project, including but not limited to, design, construction, budgetary or operational requirements, limitations and objectives. 4.02 No later than the date called for in the Design/Builder's Schedule, Design/Builder shall prepare and submit to the OAR a Preliminary Design for the Project. The Preliminary Design shall address all requirements of the Project and shall include, without limitation, the following: A. Preliminary drawings that illustrate each of the basic components of the Project, including the size, scale, location, dimensions and character of each structure; B. Preliminary drawings that illustrate each exterior view of the Project; C. Preliminary drawings that illustrate a site plan for each functional area of the Project and dimensions thereof; D. Preliminary drawings and specifications illustrating and describing the architectural, electrical, mechanical, structural and manufacturing systems of the Project; E. Written description of the materials and equipment to be incorporated into the Project and the location of same; and Design/Build Agreement LS Industrial Park Roadway Improvements (23104) 005225-2 Rev 5/2024 F. Any other documents or things required to illustrate, describe or depict the Preliminary Design and the conformity of same with the requirements of the Design Criteria Package and this Contract. 4.03 Design/Builder shall review the Preliminary Design with the OAR and shall incorporate any changes ordered by the OAR in regard to the Preliminary Design or the requirements of the Project. ARTICLE 5 — CONSTRUCTION DOCUMENTS 5.01 No later than the date called for in the Design/Builder's Schedule, Design/Builder shall prepare and submit to the OAR the Construction Documents that detail the complete design for the Project. 5.02 The Construction Documents shall include all design documents that describe with specificity all elements, details, components, materials and other information necessary for the complete construction of the Project and rendering the Project fully operational for its intended purposes, including satisfaction of all testing, permitting, qualifications, certifications, validations and obtaining regulatory approvals by all applicable regulatory authorities required to complete the Project and all its components operational and functionally and legally usable for their intended purpose. ARTICLE 6 — CONTRACT TIMES 6.01 Contract Times A. The Work is required to be substantially completed within 365 days after the date when the Contract Times commence to run as provided in the Notice to Proceed and is to be completed and ready for final payment in accordance with Article 17 of the General Conditions within 395 days after the date when the Contract Times commence to run. B. Performance of the Work is required as shown in Paragraph 7.02 of the General Conditions. 6.02 Liquidated Damages A. Owner and Design/Builder recognize that time limits for specified Milestones, Substantial Completion, and completion and readiness for Final Payment as stated in the Contract Documents are of the essence of the Contract. Owner and Design/Builder recognize that the Owner will suffer financial loss if the Work is not completed within the times specified in Paragraph 6.01 and as adjusted in accordance with Paragraph 11.05 of the General Conditions. Owner and Design/Builder also recognize the delays, expense, and difficulties involved in proving in a legal or arbitration proceeding the actual loss suffered by Owner if the Work is not completed on time. Accordingly, instead of requiring any such proof, Owner and Design/Builder agree that as liquidated damages for delay (but not as a penalty): 1. Substantial Completion: Design/Builder shall pay Owner $1000.00 for each day that expires after the time specified in Paragraph 6.01 for Substantial Completion until the Work is substantially complete. 2. Completion of the Remaining Work: Design/Builder agrees to pay Owner $400.00 for each day that expires after the time specified in Paragraph 6.01 for completion and Design/Build Agreement LS Industrial Park Roadway Improvements (23104) 005225-3 Rev 5/2024 readiness for final payment until the Work is completed and ready for final payment in accordance with Paragraph 17.16 of the General Conditions. 3. Liquidated damages for failing to timely attain Substantial Completion and Final Completion are not additive and will not be imposed concurrently. 4. The Owner will determine whether the Work has been completed within the Contract Times. ARTICLE 7 — CONTRACT PRICE 7.01 Owner will pay Design/Builder for completion of the Work in accordance with the Contract Documents the sum of $7,827,277.00. ARTICLE 8 — PAYMENT PROCEDURES 8.01 Submit Applications for Payment in accordance with Article 17 of the General Conditions. Applications for Payment will be processed by the OAR as provided in the General Conditions. 8.02 Progress Payments; Retainage: A. The Owner will make progress payments on or about the 25th day of each month during performance of the Work. Payment is based on Work completed in accordance with the Schedule of Values established as provided in the General Conditions. B. Progress payments equal to the full amount of the total earned value to date for completed Work minus the retainage listed below and properly stored materials will be made prior to Substantial Completion. 1. The standard retainage is 5 percent. C. Payment will be made for the amount determined per Paragraph 8.02.B, less the total of payments previously made and less set -offs determined in accordance with Article 17 of the General Conditions. 8.03 Owner will pay the remainder of the Contract Price as recommended by OAR in accordance with Article 17 of the General Conditions upon final completion and acceptance of the Work. ARTICLE 9 — INTEREST ON OVERDUE PAYMENTS AND RETAINAGE 9.01 The Owner is not obligated to pay interest on overdue payments except as required by Texas Government Code Chapter 2251. Invoices must comply with Article 17 of the General Conditions. 9.02 Except as specified in Article 8, the Owner is not obligated to pay interest on moneys not paid except as provided in Texas Government Code Chapter 2252. ARTICLE 10 — DESIGN/BUILDER'S REPRESENTATIONS 10.01 The Design/Builder makes the following representations: A. The Design/Builder has visited the Site and become familiar with and is satisfied as to the general, local, and Site conditions that may affect cost, progress, and performance of the Work. Design/Build Agreement LS Industrial Park Roadway Improvements (23104) 005225-4 Rev 5/2024 B. The Design/Builder is familiar with Laws and Regulations that may affect cost, progress, and performance of the Work. C. The Design/Builder has carefully studied the following Site -related reports, if any: 1. Geotechnical Data Reports regarding subsurface conditions at or adjacent to the Site; 2. Drawings of physical conditions relating to existing surface or subsurface structures at the Site; 3. Underground Facilities referenced in reports and drawings; 4. Reports and drawings relating to Hazardous Environmental Conditions at or adjacent to the Site; and 5. Technical Data related to each of these reports and drawings. D. The Design/Builder has considered the: 1. Information known to Design/Builder; 2. Information commonly known to designers and contractors doing business in the locality of the Site; 3. Information and observations obtained from visits to the Site; and 4. Design Criteria Package included in the RFQ/RFP, including the scope of work/design criteria. E. The Design/Builder has considered the items identified in the Contract Documents with respect to the effect of such information, observations, and documents on: 1. The cost, progress, and performance of the Work; 2. The means, methods, techniques, sequences, and procedures of construction to be employed by Design/Builder; and 3. Design/Builder's safety precautions and programs. F. Design/Builder has given the OAR written notice of all conflicts or ambiguities that Design/Builder has discovered in the Contract Documents, and the written resolution provided by the OAR is acceptable to the Design/Builder. G. Design/Builder's entry into this Contract constitutes an incontrovertible representation by Design/Builder that without exception all prices in the Agreement are premised upon performing and furnishing the Work required by the Contract Documents. H. DESIGN/BUILDER SHALL INDEMNIFY, DEFEND AND HOLD HARMLESS THE OWNER'S INDEMNITEES IN ACCORDANCE WITH PARAGRAPH 7.14 OF THE GENERAL CONDITIONS. ARTICLE 11— ACCOUNTING RECORDS 11.01 Accounting Record Availability: The Design/Builder shall keep such full and detailed accounts of materials incorporated and labor and equipment utilized for the Work consistent with the requirements of Paragraph 15.01 of the General Conditions and as may be necessary for proper financial management under this Agreement. Subject to prior written notice, the Owner shall be afforded reasonable access during normal business hours to all of the Design/Builder's records, books, correspondence, instructions, drawings, receipts, vouchers, memoranda, and similar data Design/Build Agreement LS Industrial Park Roadway Improvements (23104) 005225-5 Rev 5/2024 relating to the cost of the Work and the Design/Builder's fee. The Design/Builder shall preserve all such documents for a period of 3 years after the final payment by the Owner. ARTICLE 12 — CONTRACT DOCUMENTS AND ORDER OF PRECEDENCE 12.01 Contents: A. The Contract Documents consist of the following, and in the event of any conflict, discrepancy or inconsistency among any of the Contract Documents that make up this contract, the documents take precedence in the following order: 1. Change Orders and Contract Amendments 2. Documents listed in the Table of Contents (Design/Build Agreement and General Conditions) 3. Exhibit B — Design Criteria Package 4. Design and Construction Documents prepared by Design/Builder B. There are no Contract Documents other than those listed above in this Article. C. The Contract Documents may only be amended, modified, or supplemented as provided in Article 11 of the General Conditions. Signature Page Follows Design/Build Agreement LS Industrial Park Roadway Improvements (23104) 005225-6 Rev 5/2024 ARTICLE 13 — CONTRACT DOCUMENT SIGNATURES ATTEST Rebecca fffteic a Rebecca Huerta City Secretary APPROVED AS TO LEGAL FORM: Assistant City Attorney ATTEST (IF CORPORATION) (Seal Below) Note: Attach copy of authorization to sign if person signing for DESIGN/BUILDER is not President, Vice President, Chief Executive Officer, or Chief Financial Officer CITY OF CORPUS CHRISTI 52/1:44,-e Jeff H. Edmonds, P.E. Director of Engineering Services Res.033510 AUTHORIZED BY COUNCIL 1 1/1 2/2024 RH/SB DESIGN/BUILDER Mako Contracting LLC By: Title: 1526 Holly Rd Address Corpus Christi TX 78417 City (361) 561-6256 Phone GG@makocontracting.com State Zip Fax EMail END OF SECTION Design/Build Agreement LS Industrial Park Roadway Improvements (23104) 005225-7 Rev 5/2024 City of Corpus Christi RFP 5619 Design Build Industrial Park Roadway Improvements, Project No. 23104 DESIGN BUILD PRICE PROPOSAL BID ALTERNATE CONCRETE PAVEMENT QTY UNIT DESCRIPTION UNIT PRICE AMOUNT 1 LS Design Build Services 57 687,277 00 $7,687,277.00 1 LS Insurances 520,000.00 520,000.00 1 AL Performance and Payment Bonds 5120,000.00 S120,000.00 TOTAL 57,827,277.00 The above price is inclusive of all costs necessary and as described in the Technical Proposal. Mako Contracting, LLC to meet the requirements outlined in this RFQ/RFP Company z_ 10-4-24 A orized Representative Date OPCC SUMMARY CONCRETE ALTERNATE DESIGN 5974,400.00 SUBTOTAL PARTA - GENERAL $ 429,928,00 SUBTOTAL PART B - STREET Irv1PROVEMENTS $ 2,481,352.00 SUBTOTAL PART C.-ADA IMPROVEMENTS $ 194,096.00 SUBTOTAL PART D - DRAINAGE IMPROVEMENTS $ 1,452,608,00 SUBTOTAL PART E - WATER I MPROVEMENTS 5 1,309,485.00 SUBTOTAL PART F - WASTEWATER IMPROVEMENTS 5 947,008,00 SUBTOTAL PART G - GAS IMPROVEMENTS $ 38,400.00 TOTAL PROJECT OPCC S 7,827,277.00 PRICING FORM Project 23104 - Industrial Park Roadway Imps MAK CONTRACTING PPAPE-DAWSON IEN INEERS Gabriel Goodman Mako Contracting, LLC 1526 Holly Rd Corpus Christi, Tx 78417 gg@makocontracting.com (361) 561-6256 October 7, 2024 Clarissa Johnson City of Corpus Christi- Finance & Procurement 1201 Leopard St, 1st Floor Corpus Christi, Tx 78401 clarissaj@cctexas.com Dear Mrs. Johnson, Mako Contracting, LLC is pleased to submit a proposal for "RFP 5619 Design Build Industrial Park Roadway Improvements." It is our intent to provide a high quality Design Build Project experience to the City of Corpus Christi. Gabriel Goodman will be the sole person authorized to obligate the construction contract for the Mako/Pape Dawson Team. The Mako/Pape Dawson Team acknowledges receipt of all addendums to this RFP, specifically Addendums 1, 2, 3, & the memo to respondents dated 9-6-2024. Gabriel Goodman MAK FA 1 PAPE-DAWSON ENGINEERS CONTRACTING TABLE OF CONTENTS PRELIMINARY ENGINEERING 3-5 PROJECT APPROACH .6 ANTICIPATED PROBLEMS 7-9 CONCEPTUAL ENGINEERING DESIGN 10 GEOTECHNICAL RECOMMENDATIONS 11-12 PROJECT SCHEDULE 13-49 PROJECT LAYOUT 50-53 Is4A AK CONTRACT GNG PAPE-DAWSON F ENGINEERS Preliminary Engineering The preliminary engineering for the industrial park area has been presented in drawings by Hanson, Inc as part of the documentation provided by the city to the respondents of the RFQ. We have reviewed the documents provided as well as several other available resources we found applicable to the project. The document review was the first step in determining the city's desired scope of work for the project. The next step in our preliminary engineering process was to define project constraints, then progress into conceptual design of the various improvements. Our preliminary engineering approach is broken down by category below and further detailed in our strip maps. Conceptual Design General Scope: • All improvements are based on the Performance Specification Guidelines for the subject project and Infrastructure Design Manual (I DM) unless noted otherwise in these documents. • Pavement o Includes full depth pavement repair for all pavement within the defined scope. o Includes removal and replacement of all curb and gutter o Includes removal and replacement of driveways as required to make tie ins to existing facilities. o Geometry designed to Local Street Standard o The Geotechnical report previously prepared by Terracon for the area was reviewed and found non -compliant with the performance specifications provided by the City for this project. o An amendment to Terracon's Geotechnical report was performed and provided to the Mako design build team. This report provides pavement recommendations for 5 pavement sections to address the requested performance specifications. ■ The strip maps detail two of these sections. o An alternative to keep/utilize the existing concrete pavement was discussed and eliminated due to cost. o The geometry will be designed to the Local Street Standard and AASHTO standards as applicable. • Signage and Pavement Markings o MUTCD and City of Corpus Christi standards will be utilized for all proposed pavement markings, signage, and traffic buttons. o All sign bases will be replaced with triangular slip bases within the right of way where triangular sign bases do not already exist. • Traffic Control o Traffic Control will be full -closure of streets where work is occurring to allow for the expedited construction schedule. o Will utilize flaggers, temporary buttons, and or temporary signs during construction to provide guidance to travelers. • Water o Water mains upsized to 10" to meet minimum fire flow requirements for commercial/light industrial development. o Layout to approximately match Hanson's recommendations. 3IPage Is4A AK CONTRACT NG PAPE-DAWSON F ENGINEERS • Wastewater o Wastewater mains sized to 8" minimum o Mains to be installed as an offset main, shown in pavement for the purposes of this response, but may be relocated to greenspace if practical. o Mains will be designed to the city's criteria (IDM), unless the system is constrained at each end, in which case, the mains will be designed to the maximum practical slope. In the case that mains cannot meet the city's slopes, we will coordinate our approach with city personnel and meet TCEQ slopes if possible. • Gas o To be designed and installed by city with contractor responsible for trenching and backfill o Assumes removal and replacement in place, or equivalent installation. o Hanson's exhibits utilized to identify quantities. • Stormwater o Multiple Stormwater approaches were reviewed and discussed. Due to the configuration of the RFQ, the most cost-effective option was selected. • Redirecting the flow to Rodd Field was recommended earlier in the pursuit; however, it was not selected due to the weight of cost on the RFQ scoring criteria. o Downstream improvements are required in the future to lower downstream tailwater elevations. • The design includes mains which are larger than downstream mains in two locations. The final drainage design will review whether a restrictor plate is required or if the increase in storage and size of downstream mains will eliminate downstream impacts effectively. o The sizes of the stormwater mains were determined using software tools commonly used for storm sewer design and are based on typical hydraulic gradient slopes and flow rates for systems in the City of Corpus Christi. o Future CCTV or other review may allow the elimination of certain mains from the project scope. o Final design will address the 5-year, 25-year, and 100-year design storms and include tailwater assumptions. • Other o Fences identified for removal and replacement in Hanson's strip maps are included in the project scope. o Numerous Performance Specifications that are listed in the RFQ and memo to respondents are not specifically identified above. Those performance specifications were considered in the preliminary design and will be considered as the project progresses to final design. o Public involvement is included as the standard two public meetings and associated exhibits. o A third public exhibit deliverable may be provided upon request once all planned improvements are accepted and permitted. Documents Review included, but not limited to: • RFQ related strip maps produced by Hanson Inc and provided by the City. • Terracon's 2022 Geotechnical Report for Industrial Park Area Streets. • Amendment to Terracon's 2022 Geotechnical Report for Industrial Park Area Streets (Attached) 4IPage MAK IPAPE-DAWSON ENGINEERS CONTRACT] NG • City of Corpus Christi GIS viewer • City of Corpus Christi Infrastructure Design Manual • City of Corpus Christi "Green Books" maps • Rodd Field Road — Yorktown to Adler plan documents • Yorktown Boulevard - Cimmaron to Rodd Field Road plan documents • City of Corpus Christi Stormwater Master Plan The project as described has been preliminarily engineered and reviewed, including our efforts performing alternative analysis and refinements, conflict review, and QA/QC on each utility design individually. 5IPage Is4A AK CONTRACT GNG PAPE-DAWSON F ENGINEERS Project Approach The project approach includes the following elements which are critical to the cost and/or schedule of the project: • Phased approach, multiple phases may be performed simultaneously, subject to revision by the design team as the project progresses. o Phase 1 — ■ Surveying, subsurface utility explorations, CCTV and design of Doberman Street improvements (utilities and street reconstruction) commences • Plan submission and approval for Doberman Street o Phase 2 — ■ Construction commences on Doberman Street • Surveying, subsurface utility explorations, CCTV substantially complete for full project scope • Design of Pyrenees Street improvements (utilities and street reconstruction) Commences • Plan submission and approval for Pyrenees Street o Phase 3 — ■ Construction commences on Pyrenees Street • Design of Bay Drive improvements (utilities and street reconstruction) commences • Plan submission and approval for Bay Drive o Phase 4 — ■ Construction commences on Bay Drive • Any remaining Accessible designs completed o Phase 5 — ■ Doberman Street construction completed • Pyrenees Street construction completed • Bay Drive construction completed o Phase 6 — ■ Final walk-through and punch list items identified • Punch list items addressed o Phase 7 — ■ Project close-out procedures and documentation completed o Additional Phasing notes: • Accessible ramp design or other work outside of the limits of the pavement may follow design phases and be delivered after completion and approval of street and infrastructure design. • Assumptions o City review timeline will be one week. o Plan documents will be approved on the first submittal. o Additional days will be credited to match the time taken for review timeline and if plan revisions are required after initial submission o Plans will be submitted in phases and portions of the work will be approved in a sequence which matches the planned phasing. o The city will accept phased approvals to expedite portions of the project. o The city will provide all inspections at their cost. 6IPage Is4A AK CONTRACT GNG PAPE-DAWSON P ENGINEERS Anticipated Problems Design -build projects come with specific challenges. The anticipation of potential issues can help mitigate risks, reduce delays, and ensure successful project delivery. Here are some of the most common issues that might occur during the construction of design -build projects, based on past team experiences and industry practices: 1. Unforeseen Site Conditions: • Issue: Unexpected subsurface conditions such as poor soil quality, groundwater, or undocumented utilities can be encountered during excavation or foundation work. • Impact: These issues may lead to design modifications, such as adjusting construction methods or redesigning drainage systems, resulting in project delays and cost overruns. • Solution: Conducting thorough geotechnical surveys and soil testing during the early design phase and developing contingency plans for dealing with unexpected conditions. 2. Utility Conflicts and Relocations: • Issue: Conflicts with existing utilities (e.g., water, gas, telecommunications) can significantly impact the construction schedule, especially when utility relocation is needed and the process is delayed or complicated. • Impact: This can result in prolonged construction phases and higher costs as teams wait for utility adjustments to be completed. • Solution: Early coordination with utility providers, detailed utility mapping, and proactive resolution of utility conflicts through coordination and detailed phasing. 3. Phasing and Traffic Management: • Issue: Improperly planned traffic control plans (TCPs) and phasing can cause significant disruption to public traffic, making it difficult for the contractor to maintain safe working conditions and smooth traffic flow. • Impact: Poorly implemented phasing can lead to unsafe conditions for workers and the public, as well as delays if traffic control changes need to be redone or adjusted. • Solution: A well -developed and adaptable phasing plan should be integrated into the project early, and regular revisions and evaluations of traffic control during construction are necessary 7IPage Is4A AK CONTRACT GNG PAFE-DAWSON F ENGINEERS 4. Stakeholder Coordination and Public Opposition • Issue: Coordination with multiple stakeholders, including local governments, businesses, and residents, can lead to challenges, especially if there is opposition to project elements like lane closures, detours, or noise during construction. • Impact: Delays can occur if changes need to be made to accommodate public concerns or if there is strong opposition from key stakeholders. • Solution: Early and continuous stakeholder engagement, including public meetings, door-to-door outreach can prevent issues from escalating. 5. Material Shortages and Supply Chain Issues: • Issue: Global supply chain disruptions, material shortages, or the late delivery of key materials such as steel, concrete, or specialized equipment can cause significant delays. • Impact: This can halt progress on critical elements of the project and increase costs as contractors wait for materials or are forced to source from more expensive suppliers. • Solution: Pre -ordering critical materials, maintaining close relationships with suppliers, and considering alternative materials or construction techniques can help mitigate this risk. • Example: Mako construction maintains a weekly lime delivery slot to mitigate the typically sporadic availability of lime. 6. Changes in Design Requirements or Scope: • Issue: Scope creep or changes in design requirements by stakeholders or owners after construction begins can result in significant rework or adjustments. • Impact: This can lead to additional costs, rework, and delays if construction must halt to accommodate new design requirements. • Solution: Establishing clear project goals and scope at the beginning of the project, alongside robust change management procedures, can minimize the impact of scope changes during construction. • Example: A project scope review meeting will be requested as soon as the Mako/Pape- Dawson team is selected to review project assumptions, processes, design goals, and cost goals. 7. Weather -Related Delays: • Issue: Unanticipated severe weather, such as heavy rain, storms, or extreme heat, can delay construction, especially during critical phases like concrete pouring or road paving. • Impact: Weather delays can disrupt construction schedules and cause water damage or erosion on active construction sites. 8IPage Is4A AK CONTRACT GNG PAPE-DAWSON P ENGINEERS • Solution: Flexibility in the construction schedule to account for weather delays and proper site management, including erosion control, can help mitigate weather -related risks. 8. Delays in Agency Reviews: • Issue: Delays in reviews or approvals from agencies, such as environmental regulators, permitting bodies, or municipal authorities, can slow down project progress. Delays in receiving approvals for environmental impacts, permits, design reviews, or safety assessments can stall the project. • Impact: Agency delays can lead to a bottleneck, affecting timelines, increasing costs, and putting project milestones at risk. • Solution: Early and proactive coordination with all involved agencies, submitting complete and compliant documentation, and maintaining regular communication to monitor approval timelines can help mitigate review delays. 9. Downstream Capacity of Stormwater Infrastructure: • Issue: The storm drainage design included in the design build project is the most economical option based on review of multiple scenarios. The approach for the proposed storm sewer is to design a system which has the future capacity to deliver a 5- year, 25-year, and 100-year design storm per the City's design guidelines. The design will include pipes which are larger than the downstream mains. Downstream improvements which are outside the current scope of the project are required to meet the City's standards. The final design may include restrictor plate(s) to mitigate downstream impacts. • Impact: The system will be designed as required, but the system will not meet drainage goals until downstream improvements are constructed. • Solution: Coordinate as soon as practical to identify a final stormwater solution which meets the budget and project goals. A practical solution which requires minor downstream improvements was identified by the Mako/Pape-Dawson team but could not be budgeted in this phase due to the weight of cost proposal on the team selection. 9IPage Is4A AK CONTRACT GNG PAPE-DAWSON F ENGINEERS Conceptual Engineering Conceptual engineering for design -build projects is an early phase that establishes the foundation for the project's scope, cost, schedule, and technical feasibility. It serves as a preliminary design that addresses key elements of the project and helps inform the design -build process by identifying major constraints, risks, and potential solutions. Conceptual engineering helps in providing an initial vision of the project, enabling owners and stakeholders to move forward with more detailed design and construction efforts. Deliverables of Conceptual Engineering: 1. Preliminary Project Plan: A high-level plan that includes the project scope, objectives, constraints, and timeline. This has been laid out in the previous responses to the RFQ as well as the Preliminary Engineering section of this document and the conceptual design drawings. 2. Conceptual Design Drawings: Initial layouts for roads, utilities, drainage and other critical infrastructure (included in the attached strip map). 3. Preliminary Cost Estimate and Schedule: A price proposal and schedule in included in this submittal. 4. Risk Assessment and Mitigation Strategy: Identification of major risks and proposed solutions (stated in previous section). 5. Stakeholder Engagement Plan: A roadmap for ongoing communication with stakeholders, including public involvement strategies (will be developed with preliminary engineering stage after project kick-off). 1. Public Meeting- the team anticipates up to 2 public meetings to engage the surrounding stakeholders and will include the standard exhibit deliverables at each meeting 2. The team will also provide a strip map for the city's typical public webpage and/or a hard copy exhibit for display at Engineering Services or other public facility. Conceptual engineering in design -build projects sets the stage for a successful project by defining key design parameters, identifying risks, coordinating early with stakeholders, and laying out a high-level strategy for design and construction. This phase ensures that as the project progresses into detailed design and construction, there is a clear understanding of project constraints and a roadmap for delivering the project within scope, on time, and on budget. 10IPage Terracon Project Memorandum 3606 WOW Road Corpus Christi, Texas 78413 P (361) 420-6000 Terracon.com TBPE F3272 To: Mr. Stephen Skrobarczyk, P.E. With: Pape Dawson Engineers co.... OF '.:1 y Date: September 30, 2024 - Re: Revised Pavement Section for 1 M ESALS *,. *• � Project: COCC Industrial Park Roadway Improvements -4 4 GREGORYPSTIEBEN Terracon Project No. CD235003 ,I.'�1.•xtz.5Grs5ER6 From: Carlos Cotilla h��ONALEN_•- Reviewed: Gregory P. Stieben, P.E. This memorandum includes the pavement section for 1 M ESALS requested by Mr. Stephen Skrobarczyk, P.E., with Pape Dawson Engineers, via an email dated September 20, 2024. Per the request, we have used 18-Kip ESAL of 1 M with reliability level R-80 for pavement design. If this needs to be adjusted, Terracon should be contacted to review and revise our recommendation as appropriate. 4.3.4 Pavement Thickness Design Recommendations Asphalt pavement design recommendations for the provided traffic loading category are outlined in the following table for the three streets. The recommendations for pavement thickness are based on the borings drilled near the road alignment and the City of Corpus Christi IDM (2022). Any deviations below subsurface from the encountered soil conditions in borings during the construction need to be notified to Terracon and design recommendations may need to be modified. FLEXIBLE PAVEMENT SYSTEMS —1 M ESALs Components Option 1 Option 2 Option 3 Hot Mix Asphaltic Concrete (Type D), inches 4.0 2.0 3.0 Hot Mix Asphaltic Concrete (Type B), inches -- 2.5 --- Granular Base Material, inches 11.0 13.0 14.0 Lime Stabilized Clay --- --- 12.0 Lime/Cement Stabilized Clay Subgrade, inches 12.0 8.0 --- Required Structural Number 4.18 Actual Structural Number 4.26 4.29 4.24 1. One course of Seal Coat; MC-30 type Prime Coat; and Tack Coat should be applied following the specifications of TxDOT 306/316 and TxDOT 310. 2. Microcracking must be employed in the lime/cement treated subgrade ahead of applying the Seal Coat. Explore with us erracon We have included an option below for using Tensar NX750 triaxial geogrid with the flexible pavement system. The pavement design was prepared using the Tensar Plus software developed by Tensar. The pavement design criteria presented for the flexible pavements was used in this alternative design. Additionally, these pavement sections were designed for use with only Tensar NX750 triaxial geogrid. No other geogrids have been considered. Components: FLEXIBLE PAVEMENT SYSTEM Thickness (inches) Type D Surface Course HMAC 2.5 Flexible Base (Crushed Limestone) 10.0 Tensar NX750 triaxial geogrid Yes Lime Treated Subgrade 8.0 Required Structural Number 4.18 Actual Structural Number 4.19 • Note that a base material layer is necessary to establish interlocking with the geogrid. Components: RIGID PAVEMENT SYSTEM Thickness (inches) Reinforced Concrete Lime Treated Subgrade 7.5 8.0 Explore with us 2 Task Inactive Summary 11 [I External Tasks Split , a Manual Task 1 I External Milestone O Milestone ♦ Duration -only Deadline Summary ll Manual Summary Rollup ii Progress Project Summary o o Manual Summary il Manual Progress Inactive Task Start -only C Inactive Milestone Finish -only 51 Page 1 v) >^ r0 -0 c-I N 4-, —to u 1 co in > Cr) V Q O CL 0 H v) >^ v, (o >4 -6 l6 Ln -0 N I. (0 > ` O C Q O fl- Q U L L 0 N �, C +J O U U -O 'O N N te a+ - yJ a)@CC, +, L O E Q (o SD X 7 W In 1 M1• > (0 -0 c-I >4 (0 -0 c-I L) c (6 E 0 0 0 .� u ate, i U c-1 v) (0 d Traffic Control Plan Implementation 1 day Thu 3/20/25 Thu 3/20/25 4 Swppp Installation 1 day Fri 3/21/25 Fri 3/21/25 7 Site Demolition 3 days Mon 3/24/25 Wed 3/26/25 8 Storm Sewer Installation 15 days Thu 3/27/25 Wed 4/16/25 9 Waterline installation 7 days Thu 4/17/25 Fri 4/25/25 10 v) v) v) vL � >- ? >4 r0 (0 (o CO -0 -0 -6 -0 N M N L.(1 C 0 0 C C1 O0 (0 O +' tia c N ra O c 0- +� 'O O v N CO L (n a)-0N -0 U' J v) OA N co co E vL cn N J O v) vL >4 >4 (0 (0 -0 -0 Ln c-I Y (0 cn L cu (o .4 O A on (o f0 i U }' ro V N c O 0 >4 >4 >4 (1 l0 CO ZS ZS -0 c-I O U) C Q .I_ O O c Ey QJ V CL c ++ _ bA (� C i -0 Q u O Q CO cnill v.) N (0 >. CL eta N vL (o c O • — 7 0 E ro Z V 0) 4 cu N } in O (o N O 0 ao ' Ci w ut - d Project: RFP 5619 Project Sched Date: Fri 10/4/24 0 1 0 NJ M Lfl l0 r- W 61 0 cN- ,- ,- .- .— ,- .— .— C7. N N N N Install Sanitary Sewer 16 days Wed 6/11/25 Wed 7/2/25 30 Install Storm Sewer and Structures 20 days Thu 7/3/25 Wed 7/30/25 31 Waterline installation 7 days Thu 7/31/25 Fri 8/8/25 32 Subgrade Preparation 3 days Mon 8/11/25 Wed 8/13/25 33 Task Inactive Summary 11 [I External Tasks Split 0 a Manual Task 1 I External Milestone O Milestone ♦ Duration -only Deadline Summary ll Manual Summary Rollup ii Progress Project Summary o o Manual Summary il Manual Progress Inactive Task Start -only C Inactive Milestone Finish -only 51 N N CD as Project: RFP 5619 Project Sched Date: Fri 10/4/24 0 M N d- NJ in N l0 NJ N co N 61 N O M M N M M M M in M LD M N- M CO M 61 M O t N V M V V Install Sanitary Sewer 15 days Mon 9/22/25 Fri 10/10/25 52 Install Storm Sewer and Structures 15 days Mon 10/13/25Fri 10/31/25 53 Waterline installation 10 days Mon 11/3/25 Fri 11/14/25 54 Subgrade Preparation 3 days Mon 11/17/25Wed 11/19/25 55 Lime Stabilization 3 days Thu 11/20/25 Mon 11/24/25 56 Geogrid Installation 8 days Tue 11/25/25 Thu 12/4/25 57 Task ■ Inactive Summary 0 P External Tasks I Split Manual Task . I External Milestone O Milestone ♦ Duration -only '--, Deadline Summary ll Manual Summary Rollup ii Progress Project Summary 0 ` 0 Manual Summary il Manual Progress Inactive Task Start -only C Inactive Milestone Finish -only 51 Page 3 r lO Project: RFP 5619 Project Sched Date: Fri 10/4/24 0 is) V LO V N. co Ol V O u Lll N Lfl M L!1 Ul Ln Lfl LO L(l N- 1.11 CO In C l Lfl O LO VD N lfl M lfl lfl ul LO CD LO Jan 5, '25 sIMl1lwl Page 4 V) LL I- N Predecessors External Tasks 1111111.111 External Milestone Deadline Progress Manual Progress C 51 N IL Start Duration Task Name Project: RFP 5619 Project Sched Date: Fri 10/4/24 1— 2 co Lo 0 LL lf1 I- Page 6 N Lci 2 N o 1.1 LL H N a 1.1 N Feb 2, '25 SIMITIWITIFIS Task Inactive Summary 1.1 [I Split . , , , Manual Task Milestone ♦ Duration -only I_- Summary ll Manual Summary Rollup Project Summary 0 Manual Summary ii Inactive Task Start -only C Inactive Milestone Finish -only 51 Jan 26, '25 SIMITIWITIFIS Jan 19, '25 SIMITIWITIFIS Jan 12, '25 SIMITIWITIFIS Project: RFP 5619 Project Sched Date: Fri 10/4/24 N LL External Tasks Inactive Summary i < • External Milestone 1 Manual Task • @ H v▪ eLi 2 in Manual Progress Manual Summary Project Summary Inactive Task Inactive Milestone LL lf1 I— N 2 cu LL if) LL H rfi a CU LL N Feb 2, '25 SIMITIWITIFIS ummary ask 1111111.111 only ummary Rollup ummary ly 11 CO Jan 26, '25 SIMITIWITIFIS (75 CL Jan 19, '25 SIMITIWITIFIS Jan 12, '25 SIMITIWITIFIS Project: RFP 5619 Project Sched Date: Fri 10/4/24 LL Apr 6, '25 SIMITI Task Inactive Summary 11 [I External Tasks Split , , , Manual Task 1111111.111 External Milestone Milestone ♦ Duration -only liCI IAC Deadline Summary ll Manual Summary Rollup Progress Project Summary 0 Manual Summary il Manual Progress Inactive Task Start -only C Inactive Milestone Finish -only 51 Page 10 Mar 30, '25 SIMITIWITIFIS Mar 23, '25 SIMITIWITIFIS Mar 16, '25 SIMITIWITIFIS Mar 9, '25 SIMITIWITIFIS Mar 2, '25 SIMITIWITIFIS Project: RFP 5619 Project Sched Date: Fri 10/4/24 Feb 23, '25 SIMITIWITIFIS External Tasks Inactive Summary i < External Milestone 1 Manual Task N c o m E a/ E H VI 2 in Manual Progress Manual Summary Project Summary Inactive Task Inactive Milestone Apr 6, '25 SIMITI Task Inactive Summary 11 [I External Tasks Split , , , Manual Task 1111111.111 External Milestone Milestone ♦ Duration -only liCI IAC Deadline Summary ll Manual Summary Rollup Progress Project Summary 0 Manual Summary il Manual Progress Inactive Task Start -only C Inactive Milestone Finish -only 51 Page 12 Mar 30, '25 SIMITIWITIFIS Mar 23, '25 SIMITIWITIFIS Mar 16, '25 SIMITIWITIFIS Mar 9, '25 SIMITIWITIFIS Mar 2, '25 SIMITIWITIFIS Project: RFP 5619 Project Sched Date: Fri 10/4/24 Feb 23, '25 SHAH IWITIFIS May18, '25 SMTWTF Page 14 LL N ~ T- N N N LL lf) ~ DIlup 1-1 51 N v 2 m Apr 27, '25 SIMITIWITIFIS Apr 20, '25 SHAH IWITIFIS Apr 13, '25 SIMITIWITIFIS Project: RFP 5619 Project Sched Date: Fri 10/4/24 LL External Tasks Inactive Summary i < • External Milestone 1 Manual Task c c o m E a) E H VI 2 in Manual Progress Manual Summary Project Summary Inactive Task Inactive Milestone LL Page 16 N 1-11 ~ oci 2 ra N LL N ~ 7 N N N LL lf) ~ 111E 1-1 51 N v 2 >, m 2 Apr 27, '25 SIMITIWITIFIS Apr 20, '25 SHAH IWITIFIS Apr 13, '25 SIMITIWITIFIS Project: RFP 5619 Project Sched Date: Fri 10/4/24 LL 2 ICC V) External Tasks Inactive Summary 1 External Milestone Manual Task 4 0 O 0 N C O m E a) E H V/ 2 in Manual Progress Manual Summary Project Summary Inactive Task Inactive Milestone N Page 18 C In N LL I1 N rn 2 N C C In Jun 22, '25 SIMITIWITIFI5 Inactive Summary 1.1 [I External Tasks Manual Task 1111111.111 External Milestone ♦ Duration -only I_- Deadline Manual Summary Rollup Progress 0 �9 Manual Summary Manual Progress Start -only C Finish -only 11 Jun 15, '25 SIMITIWITIFIS Jun 8, '25 SIMITIWITIFIS In LL I- N C Project: RFP 5619 Project Sched Date: Fri 10/4/24 7 In May 25, '25 s�IMITIwITIFI5 N 2 N 2 N External Tasks Inactive Summary i External Milestone 1 Manual Task 4 co?' H V) 2 VeL Manual Progress Manual Summary Project Summary Inactive Task Inactive Milestone N Page 20 C In N LL 1.11 N rn 2 N C C In Jun 22, '25 SIMITIWITIFI5 Inactive Summary 1.1 [I External Tasks Manual Task 1111111.111 External Milestone ♦ Duration -only I_- Deadline Manual Summary Rollup Progress 0 �9 Manual Summary Manual Progress Start -only C Finish -only 11 Jun 15, '25 SIMITIWITIFIS Jun 8, '25 SIMITIWITIFIS In LL I— N C Project: RFP 5619 Project Sched Date: Fri 10/4/24 7 In May 25, '25 SIMITIWITIFIS to External Tasks Inactive Summary 1 External Milestone Manual Task 4 O 0 Q 7 0 3 2 c O m E a) E H VI 2 in Manual Progress Manual Summary Project Summary Inactive Task Inactive Milestone Aug17, '25 SI M I T I W I T Page 22 LL Lfl H N o 2 Ui N Aug3, '25 SI M I T I W I T I F S Inactive Summary 1.1 [I ExternE Manual Task 1111111.111 Extern :one ♦ Duration -only I_I I Deadlii iary ll Manual Summary Rollup Progre :t Summary 0 Manual Summary il Manua ✓e Task Start -only C ✓e Milestone Finish -only 51 Jul 27, '25 SIMITIWITIFIS Jul 20, '25 SIMITIWITIFIS N LL H Project: RFP 5619 Project Sched Date: Fri 10/4/24 Lil N cc fry G 7 L/) N LL H External Tasks Inactive Summary < • External Milestone 1 Manual Task • @ H v▪ eLi 2 V) Manual Progress Manual Summary Project Summary Inactive Task Inactive Milestone Aug17, '25 SI M I T I W I T Page 24 LL In H N o 2 Ui Q N Aug3, '25 SI M I T I W I T I F S Inactive Summary 1.1 [I ExternE Manual Task 1111111.111 Extern :one ♦ Duration -only I_I I Deadlii iary ll Manual Summary Rollup Progre :t Summary 0 Manual Summary il Manua ✓e Task Start -only C ie Milestone Finish -only 51 Jul 27, '25 SIMITIWITIFIS Jul 20, '25 SIMITIWITIFIS N LL H Project: RFP 5619 Project Sched Date: Fri 10/4/24 Lil N cc fry G 7 V) N LL H External Tasks Inactive Summary 1 External Milestone Manual Task 4 O 0 Q 7 0 3 2 c O m E ▪ a) E N H • VI 2 in Manual Progress Manual Summary Project Summary Inactive Task Inactive Milestone Task Inactive Summary 11 [I External Tasks Split , , , Manual Task 1111111.111 External Milestone Milestone ♦ Duration -only liCI IAC Deadline Summary ll Manual Summary Rollup Progress Project Summary 0 Manual Summary il Manual Progress Inactive Task Start -only C Inactive Milestone Finish -only 51 Page 26 LL VI I- C/1 2 N Q N Sep 21, '25 SIMITIWITIFIS Sep 14, '25 SIMITIWITIFIS LL I - IN IN r Q n LL H -0 H N c M c U) Q N Aug24, '25 SIMITIWITIFIS Project: RFP 5619 Project Sched Date: Fri 10/4/24 N LL External Tasks Inactive Summary i External Milestone 1 Manual Task 4 N @ eL H V) 2 V) Manual Progress Manual Summary Project Summary Inactive Task Inactive Milestone Task Inactive Summary 11 [I External Tasks Split , , , Manual Task 1111111.111 External Milestone Milestone ♦ Duration -only liCI IAC Deadline Summary ll Manual Summary Rollup Progress Project Summary 0 Manual Summary il Manual Progress Inactive Task Start -only C Inactive Milestone Finish -only 51 Page 28 LL VI I- N 2 N Q N Sep 21, '25 SIMITIWITIFIS Sep 14, '25 SIMITIWITIFIS N LL H N r Q n N LL H -0 H N c M c U) Q N Aug24, '25 SIMITIWITIFIS Project: RFP 5619 Project Sched Date: Fri 10/4/24 N LL External Tasks Inactive Summary 1 External Milestone Manual Task 4 O 0 Q 7 0 3 2 c O m E ▪ a) E N H • VI 2 in Manual Progress Manual Summary Project Summary Inactive Task Inactive Milestone Ix) 1- N 2 O N Z Task Inactive Summary 11 [1 External Tasks Split , , , Manual Task 1111111.111 External Milestone Milestone ♦ Duration -only liCI IAC Deadline Summary ll Manual Summary Rollup Progress Project Summary 0 Manual Summary il Manual Progress Inactive Task Start -only C Inactive Milestone Finish -only 51 Page 30 Nov 9, '25 SIMITIWITIFIS N LL In N 2 O N Z Oct 26, '25 SIMITIWITIFIS Oct 19, '25 SIMITIWITIFIS LL Ln H Project: RFP 5619 Project Sched Date: Fri 10/4/24 N N 2 V N N LL H In N 1.1-,1- N 2 O Page 32 Z N Nov 9, '25 SIMITIWITIFS N LL Ln Task Inactive Summary 1.1 [I Split . , , , Manual Task 1111111.111 Milestone ♦ Duration -only I_- Summary ll Manual Summary Rollup Project Summary 0 Manual Summary ii Inactive Task Start -only C Inactive Milestone Finish -only 51 N 2 O Z N Oct 26, '25 SIMITIWITIFS Oct 19, '25 SIMITIWITIF5 LL Ln H Project: RFP 5619 Project Sched Date: Fri 10/4/24 N N 2 V N N LL 1- In N External Tasks Inactive Summary 1 External Milestone Manual Task 4 O 0 Q 7 0 3 2 c O m E a) E H VI 2 in Manual Progress Manual Summary Project Summary Inactive Task Inactive Milestone Dec 28, '25 SIMITIWITIFIS Task Inactive Summary 11 [I External Tasks Split , , , Manual Task 1111111.111 External Milestone Milestone ♦ Duration -only liCI IAC Deadline Summary ll Manual Summary Rollup Progress Project Summary 0 Manual Summary il Manual Progress Inactive Task Start -only C Inactive Milestone Finish -only 51 Page 34 Dec 21, '25 SHAH IWITIFIS Dec 14, '25 SIMITIWITIFIS Dec 7, '25 SIMITIWITIFIS Nov 30, '25 SIMITIWITIFIS Nov 23, '25 SIMITIWITIFIS Project: RFP 5619 Project Sched Date: Fri 10/4/24 V) LL I- External Tasks Inactive Summary i External Milestone 1 Manual Task • @ H v▪ eLi 2 in Manual Progress Manual Summary Project Summary Inactive Task Inactive Milestone Dec 28, '25 SIMITIWITIFIS Task Inactive Summary 11 [I External Tasks Split , , , Manual Task 1111111.111 External Milestone Milestone ♦ Duration -only liCI IAC Deadline Summary ll Manual Summary Rollup Progress Project Summary 0 Manual Summary il Manual Progress Inactive Task Start -only C Inactive Milestone Finish -only 51 Page 36 Dec 21, '25 SHAH IWITIFIS Dec 14, '25 SIMITIWITIFIS Dec 7, '25 SIMITIWITIFIS Nov 30, '25 SIMITIWITIFIS Nov 23, '25 SIMITIWITIFIS Project: RFP 5619 Project Sched Date: Fri 10/4/24 V) LL I- FB �u w .ow.®.o,..po eu�SVX31 �'aw.eana I151aNJ SIIdNOJ /. .1.11, Ana rvoh3 13]H 3 33NVtlAd � o g ,w asv. SINDIND„oe,NIAVAov0ereva-xe na N S .. .� 3 3 O �aa c� rc 19 a a re o 0 04 0.414 _ u \,. .., ea Ave1 / �` 4s I 116 1 W _ 11 111 11 I'i pm. Eil 1 I "" Po- a. ®®.a. Ell, 1a 46.7 DIP 1 1 111 N, L oa®e _ J, g p SVX31 11.31211-13 sndacD J. ,LID 12133NieN3 NOSMIR7-3d1rd 3AIEJCI 1111H 01 301d0 AVEI 133H1S NVI11,13800 1VS0dOldd aiine NI0IS30 S1N3WRAOHMAYMOVOU )PAW lVluisnaNi 5 -5 5 cc c55 ad, NO11.0.0 REMOVE AND REPLACE GAS REMOVE AND REPLACE POWER POLE ADA IMPROVEMENT 0 STORM MAIN STORM MANHOLE WASTE WATER MAIN WASTE WATER MANHOLE SANITARY CLEAN OUT MO, z WATER DEFLECTION 0000 000 aNO rdao I. All., " " ,o xo, -7 7 --- \ A 1 f it F 0! il oeo 1 EL E ann3x I oboe 4 � ar 1 46 I 1 O Ill . rc rc o 0 rc rc r. 46. e e e 1 _ TP 00 61 14 PERFORMANCE BOND (DB) Design -Builder as Principal Name: MAKO Contracting, LLC Mailing address (principal place of business): 1526 Holly Road Corpus Christi, TX 78417 BOND NO. 101286748 Owner Name: City of Corpus Christi, Texas Mailing address (principal place of business): Engineering Services 1201 Leopard Street, 3`d Floor Corpus Christi, Texas 78401 Contract Project name and number: Industrial Park Roadway Improvements Project No. 23104 Award Date of the Contract: 11-12-2024 Contract Price: $7,827,277.00 Bond Date of Bond: November 12, 2024 (Date of Bond cannot be earlier than Award Date of the Contract) Performance Bond (DB) Industrial Park Roadway Improvements (23104) Surety Name: Merchants Bonding Company (Mutual) Mailing address (principal place of business): PO Box 14498 Des Moines, IA 50306 Physical address (principal place of business): 6700 Westown Pkwy West Des Moines, IA 50266 Surety is a corporation organized and existing under the laws of the state of: Iowa By submitting this Bond, Surety affirms its authority to do business in the State of Texas and its license to execute bonds in the State of Texas. Telephone (main number): (800) 678-8171 Telephone (for notice of claim): (800) 678-8171 Local Agent for Surety Name: Upshaw Insurance Agency, Inc. Address: PO Box 1299, Amarillo. TX 79105 Telephone:(806) 468-0400 E-Mail Address: Coryb@upshaw-insurance.com The address of the surety company to which any notice of claim should be sent may be obtained from the Texas Dept. of Insurance by calling the following toll free number: 1-800-252-3439 006114-1 Rev 5/2024 Surety and Design -Builder, intending to be legally bound and obligated to Owner do each cause this Performance Bond to be duly executed on its behalf by its authorized officer, agent or representative. The Principal and Surety bind themselves, and their heirs, administrators, executors, successors and assigns, jointly and severally to this bond. The condition of this obligation is such that if the Design -Builder as Principal faithfully performs the Work through the Warranty Period required by the Contract Documents then this obligation shall be null and void; otherwise the obligation is to remain in full force and effect. The Contract Documents between Owner and Design -Builder is incorporated by reference into this Statutory Performance Bond, pursuant to Chapter 2253 of the Texas Government Code. Provisions of the bond shall be pursuant to the terms and provisions of Chapter 2253 and Chapter 2269 of the Texas Government Code, as amended, and al! liabilities on this bond shall be determined in accordance with the provisions of said Chapter to the same extent as if it were copied at length herein. If Design -Builder does not faithfully construct and complete said Work through the Warranty Period under its contract with Owner, and Owner invokes its controctual rights and declares Design -Builder in default, Surety shall promptly remedy the default, and at Owner's sole option, Surety shall: 1. Within a reasonable time (but not later than 30 days after Surety receives written notice of Design - Builder's default), with written notice to Owner, step into and assume the role, al! rights and all obligations of the defaulting Design -Builder under the Contract Documents. Upon assumption of this role, Surety directly shall contract with a Completion Design -Builder hired/engaged by Surety to complete the Work. The selection of the Completion Design -Builder must be approved in writing by Owner. Surety shall be responsible for any and al! costs incurred, up to the Bond Sum, to complete the Work; or 2. In the event Surety fails to contract with a Completion Design -Builder within 90 days of receipt of Owner's written notice of Default, Owner may, at Owner's sole discretion, select a Completion Design -Builder in accordance with Texas law to complete the Work. In this event, Surety shall pay Owner any and all costs, up to the Bond Sum, for Owner's selected Completion Design -Builder to complete the Work; or 3. At Owner's sole discretion, Surety shall pay Owner the estimated amount for Owner to execute a Project Completion Contract with a Completion Design -Builder, selected by Owner in accordance with Texas Law, solely to complete the Work. Surety shall pay Owner any and all costs, up to the Bond Sum, for Owner -selected Completion Design -Builder to complete the Work. Venue shall lie exclusively in Nueces County, Texas. Surety agrees to be bound by the mediation clause in Article 22 of the Contract Documents between Owner and Design -Builder, said Contract Documents incorporated by reference in this Bond. Performance Bond (DB) Industrial Park Roadway Improvements (23104) 006114-2 Rev 5/2024 Design -Builder as Princip Surety Merchatfs%Bonding Cornlpayty)(Mutual) Signature: Signature: Name: .. it (p,poA.(A Name. Title: ��C.S. 4/1- Title: Email Address: G600,40 Vacjbctrif)Pt Email Address: laurenf@upshaw-insurance.com C. (Attach Power of Attorney and place surety seal below) Lauren Lane Attorney -in -Fact END OF SECTION Performance Bond (DB) Industrial Park Roadway Improvements (23104) 006114.3 Rev 5/2024 Fl1A( 0 z • Jl r l E RC H A N T� BONDING COMPANY POWER OF ATTORNEY Know All Persons By These Presents, that MERCF (ANTS BONDING COMPANY (MUTUAL) and MERCHANTS NATIONAL BONDING, INC., both being corporations of the State of Iowa, dlb/a Merchants National Indemnity Company (in California only) (herein collectively called the "Companies") do hereby make, constitute and appoint, individually, Cory B Bentley; Lauren Lane; Robert 13 Bentley; Ronald McQueen l ludson; Stephanie Taylor their true and lawful Attorney(s)-in-Fact, to sign its name as surety(ies) and to execute, seal and acknowledge any and all bonds, undertakings, contracts and other written instruments in the nature thereof, on behalf of the Companies in their business of guaranteeing the fidelity of persons, guaranteeing the performance of contracts and executing or guaranteeing bonds and undertakings required or permitted in any actions or proceedings allowed by law. This Power-of-Attomey is granted and is signed and sealed by facsimile under and by authority of the following By -Laws adopted by the Board of Directors of Merchants Bonding Company (Mutual) on April 23, 2011 and amended August 14, 2015 and adopted by the Board of Directors of Merchants National Bonding, Inc., on October 16, 2015. "The President, Secretary, Treasurer, or any Assistant Treasurer or any Assistant Secretary or any Vice President shall have power and authority to appoint Attorneys -in -Fact, and to authorize them to execute on behalf of the Company, and attach the seal of the Company thereto, bonds and undertakings, recognizances, contracts of indemnity and other writings obligatory in the nature thereof." "The signature of any authorized officer and the seal of the Company may be affixed by facsimile or electronic transmission to any Power of Attorney or Certification thereof authorizing the execution and delivery of any bond, undertaking, recognizance, or other suretyship obligations of the Company, and such signature and seal when so used shall have the same force and effect as though manually fixed." In connection with obligations in favor of the Florida Department of Transportation only, it is agreed that the power and aut hority hereby given to the Attorney -in -Fact includes any and all consents for the release of retained percentages and/or final estimates on engineering and construction contracts required by the State of Florida Department of Transportation. It is fully understood that consenting to the State of Florida Department of Transportation making payment of the final estimate to the Contractor and/or its assignee, shall not relieve this surety company of any of its obligations under its bond. In connection with obligations in favor of the Kentucky Department of Highways only, it is agreed that the power and authority hereby given to the Attorney -in -Fact cannot be modified or revoked unless prior written personal notice of such intent has been given to the Commissioner - Department of Highways of the Commonwealth of Kentucky at least thirty (30) days prior to the modification or revocation. In Witness Whereof, the Companies have caused this instrument to be signed and sealed this 3rd day of February , 2024 ••PZ10Nq�•• ••�\• NG CO,,, •'�co 'RPORq•�o: •O?•'p.P0194• 1y. , 0 , 2003 :� : • •y - t 7=7/4, :<,_ 933 • • c By • d ••',�� •\1�� President STATE OF IOWA •7•� COUNTY OF DALLAS ss. On this 3rd day of February 2024 . before me appeared Larry Taylor, to me personally known, who being by me duly sworn did say that he is President of MERCHANTS BONDING COMPANY (MUTUAL) and MERCHANTS NATIONAL BONDING, INC.; and that the seals affixed to the foregoing instrument are the Corporate Seals of the Companies; and that the said instrument was signed and sealed in behalf of the Companies by authority of their respective 13oards of Directors. OAE @ogle,• sm Penni Miller A Commission Number 787952 • My Commission Expires January 20, 2027 (Expiration of notary's commission does not invalidate this instrument) I, William Warner, Jr., Secretary of MERCHANTS BONDING COMPANY (MUTUAL) and MERCIIAN'I'S NATIONAL BONDING, INC., do hereby. certify that the above and foregoing is a true and correct copy of the POWER -OF -ATTORNEY executed by said Companies, which is still in, full force and effect and has not been amended or revoked. MERCHANTS BONDING COMPANY (MUTUAL) MERCHANTS NATIONAL BONDING, INC. d/b/a MERCHANTS NATIONAL INDEMNITY COMPANY ` In Witness Whereof, I have hereunto set my hand and affixed the seal of the Companies on this 12 day of November , 2024 PO • o APUq y Z:2 -0- /:11.0: :12:_2 -0- CI':. �iy itt412%i v 2003 '�e� . y: 1933 o•.c' Secretary :d' Oz.. ac•. 00 61 17 PAYMENT BOND (DB) BOND NO.101286748 Design -Builder as Principal Name: MAKO Contracting, LLC Mailing address (principal place of business): 1526 Holly Road Corpus Christi, TX 78417 Owner Name: City of Corpus Christi, Texas Mailing address (principal place of business): Engineering Services 1201 Leopard Street Corpus Christi, Texas 78401 Contract Project name and number: Industrial Park Roadway Improvements Project No. 23104 Award Date of the Contract: 11-12-2024 Contract Price: $7,827,277.00 Bond Date of Bond: November 12, 2024 (Date of Bond cannot be earlier than Award Date of Contract) Surety Name: Merchants Bonding Company (Mutual) Mailing address (principal place of business): PO Box 14498 Des Moines, IA 50306 Physical address (principal place of business): 6700 Westown Pkwy West Des Moines, IA 50266 Surety is a corporation organized and existing under the laws of the state of: Iowa By submitting this Bond, Surety affirms its authority to do business in the State of Texas and its license to execute bonds in the State of Texas. Telephone (main number): (800) 678-8171 Telephone (for notice of claim): (800) 678-8171 Local Agent for Surety Name: Upshaw Insurance Agency, Inc. Address: PO Box 1299, Amarillo, TX 79105 Telephone: (806) 468-0400 E-Mail Address: Corybcr,upshaw-insurance.com The address of the surety company to which any notice of claim should be sent may be obtained from the Texas Dept. of Insurance by calling the following toll free number: 1-800-252-3439 Payment Bond (DB) Industrial Park Roadway Improvements (23104) 006117-1 Rev. 5/2024 Surety and Design -Builder, intending to be legally bound and obligated to Owner do each cause this Payment Bond to be duly executed on its behalf by its authorized officer, agent or representative. The Principal and Surety bind themselves, and their heirs, administrators, executors, successors and assigns, jointly and severally to this bond. The condition of this obligation is such that if the Design -Builder as Principal pays all claimants providing labor or materials to him or to a Subcontractor in the prosecution of the Work required by the Contract Documents then this obligation shall be null and void; otherwise the obligation is to remain in full force and effect. Provisions of the bond shall be pursuant to the terms and provisions of Chapter 2253 and Chapter 2269 of the Texas Government Code as amended and all nobilities on this bond shall be determined in accordance with the provisions of said Chapter to the same extent as if it were copied at length herein. Venue shall lie exclusively in Nueces County, Texas for any legal action. Design -Builder as Princi I Surety Merchants t ng Company (Motu Signature: Name: /t ipri•o( Ci- DA l t4.4 Title: pros,a 04-4 Email Address: C(s1 ,pop - i Go XI Payment Bond (DB) Industrial Park Roadway Improvements (23104) Signature: L Name: Lauren Lane - Title: Attorney -in -Fact Email Address: laurenf@upshaw-insurance.com (Attach Power of Attorney and place surety seal below) END OF SECTION 006117• 2 Rev. 5/2024 M E RC HAN-17S BONDING COMPANY POWER OF ATTORNEY Know All Persons By These Presents, that MFRCIIANTS BONDING COMPANY (MUTUAL) and MERCHANTS NATIONAL BONDING, INC., both being corporations of the State of Iowa, d/b/a Merchants National Indemnity Company (in Califomia only) (herein collectively called the "Companies") do hereby make, constitute and appoint, individually, Cory B Bentley; Lauren Lane; Robert 13 Bentley; Ronald McQueen Hudson; Stephanie Taylor their true and lawful Attorney(s)-in-Fact, to sign its name as surety(ies) and to execute, seal and acknowledge any and all bonds, undertakings, contracts and other written instruments in the nature thereof, on behalf of the Companies in their business of guaranteeing the fidelity of persons, guaranteeing the performance of contracts and executing or guaranteeing bonds and undertakings required or permitted in any actions or proceedings allowed by law. This Power -of -Attorney is granted and is signed and sealed by facsimile under and by authority of the following By -Laws adopted by the Board of Directors of Merchants Bonding Company (Mutual) on April 23, 2011 and amended August 14, 2015 and adopted by the Board of Directors of MerchantsNational Bonding, Inc., on October 16, 2015. "The President, Secretary, Treasurer, or any Assistant Treasurer or any Assistant Secretary or any Vice President shall have power and authority to appoint Attorneys -in -Fact, and to authorize them to execute on behalf of the Company, and attach the seal of the Company thereto, bonds and undertakings, recognizances, contracts of indemnity and other writings obligatory in the nature thereof." "The signature of any authorized officer and the seal of the Company may be affixed by facsimile or electronic transmission to any Power of Attorney or Certification thereof authorizing the execution and delivery of any bond, undertaking, recognizance, or other suretyship obligations of the Company, and such signature and seal when so used shall have the same force and effect as though manually fixed." In connection with obligations in favor of the Florida Department of Transportation only, it is agreed that the power and aut hority hereby given to the Attorney -in -Fact includes any and all consents for the release of retained percentages and/or final estimates on engineering and construction contracts required by the State of Florida Department of Transportation. It is fully understood that consenting to the State of Florida Department of Transportation making payment of the final estimate to the Contractor and/or its assignee, shall not relieve this surety company of any of its obligations under its bond. In connection with obligations in favor of the Kentucky Department of Highways only, it is agreed that the power and authority hereby given to the Attorney -in -Fact cannot be modified or revoked unless prior written personal notice of such intent has been given to the Commissioner - Department of Highways of the Commonwealth of Kentucky at least thirty (30) days prior to the modification or revocation. In Witness Whereof, the Companies have caused this instrument to be signed and sealed this 3rd day of February , 2024 . •1,1 O fti. a: z: x•• 2003 •o STATE OF IOWA ii COUNTY OF DALLAS ss. ."""... : • �..... - C�MiO • �o DAP0,9 9. • .1 1933 : c MERCHANTS BONDING COMPANY (MUTUAL) MERCHANTS NATIONAL BONDING, INC. d/b/a MERCHANTS NATIONAL INDEMNITY COMPANY By x‘i On this 3rd day of February 2024 , before me appeared Larry Taylor, to me personally known, who being by me duly sworn did say that he is President of MERCHANTS BONDING COMPANY (MUTUAL) and MERCHANTS NATIONAL BONDING, INC.; and that the seals affixed to the foregoing instrument are the Corporate Seals of the Companies; and that the said instrument was signed and sealed in behalf of the Companies by authority of their respective Hoards of Directors. 0 Z • • ofte .m•r• I0w scc` r • Penni Miller Commission Number 787952 My Commission Expires January 20, 2027 (Expi ation of notary's commission does not invalidate this instrument) I, William Warner, Jr., Secretary of MERCHANTS BONDING COMPANY (MUTUAL) and MERCHANTS NATIONAL BONDING, INC., do hereby certify that the above and foregoing is a true and correct copy of the POWER -OF -ATTORNEY executed by said Companies, which is -still in full - force and effect and has not been amended or revoked. In Witness Whereof, I have hereunto set my hand and affixed the seal of the Companies on this 12 �. •P•(10Ng4 •• .•�O\N�' ���Sj •. •'may G0(iP .................... R9 •e • �.O..�Fl P 0,9 9. •• •:. :IXi -o- �O:z: • Q, o 0,3 v • 2003• `t>; . y•. 1933 4 . 0,6% . ' .... , .. .�4• . • .`;\-a•. 'am day of Novel9'113er _ ; 2024 . Secretary POA 0018 (1/24) .MERCHANTS BONDING COMPANY: MERCHANTS BONDING COMPANY (MUTUAL.) • P.O. BOX 14,198 • DES MOINES. IOWA 50306-3498 PHONE: (800) 678-8171 • FAX: (515) 243-3854 Have a complaint or need help? If you have a problem with a claim or your premium, call your insurance company or HMO first. If you can't work out the issue, the Texas Department of Insurance may be able to help. Even if you file a complaint with the Texas Department of Insurance, you should also file a complaint or appeal through your insurance company or HMO. If you don't, you may lose your right to appeal. To get information or file a complaint with your insurance company or HMO: Merchants Bonding Company (Mutual) Call: Compliance Officer at (800) 671-8171 Toll -free: (800) 671-8171 Email: regulatory@merchantsbonding.com Mail: P.O. Box 14498, Des Moines, Iowa S0306-3498 To get insurance information you may also contact your agent: Upshaw Insurance Agency, Inc. Can: 806-468-0400 Mail: PO Box 1299, Amarillo, TX 79105 The Texas Department of Insurance To get help with an insurance question or file a complaint with the state: CaII with a question: 1-800-252-3439 File a complaint: www.tdi.texas.gov Email: ConsumerProtection@tdi.texas.gov Mail: Consumer Protection, MC: CO-CP, Texas Department of Insurance, PO Box 12030, Austin, TX 78711-2030 zTiene una queja o necesita ayuda? Si tiene un problema con una reclamacion o con su prima de seguro, Ilame primero a su compania de seguros o HMO. Si no puede resolver el problema, es posible que el Departamento de Seguros de Texas (Texas Department of Insurance, por su nombre en ingles) pueda ayudar. Aun si usted presenta una queja ante el Departamento de Seguros de Texas, tambien debe presentar una queja a traves del proceso de quejas o de apelaciones de su compania de seguros o HMO. Si no to hace, podria perder su derecho para apelar. SUP 0032 TX (7/23) Para obtener informacion o para presentar una queja ante su compania de seguros o HMO: Merchants Bonding Company (Mutual) Llame a: Compliance Officer al (800) 671-8171 Telefono gratuito: (800) 678-8171 Correo electronico: regulatory@merchantsbonding.com Direccion postal: P.O. Box 14498 , Des Moines, Iowa, 50306-3498 El Departamento de Seguros de Texas Para obtener ayuda con una pregunta relacionada con los seguros o para presentar una queja ante el estado: Llame con sus preguntas al: 1-800-252-3439 Presente una queja en: www.tdi.texas.gov Correo electronico: ConsumerProtection@tdi.texas.gov Direccion postal: Consumer Protection, MC: CO-CP, Texas Department of Insurance, PO Box 12030, Austin, TX 78711-2030 SUP 0032 TX (7/23) 00 72 OODB GENERAL CONDITIONS — DESIGN/BUILD Table of Contents Page Article 1— Definitions and Terminology 10 1.01 Defined Terms 10 1.02 Terminology 14 Article 2 — Preliminary Matters; Design Services 16 2.01 Delivery of Bonds and Evidence of Insurance 16 2.02 Copies of Documents 16 2.03 Project Management System 16 2.04 Before Starting Work 16 2.05 Design Services 17 2.06 Construction Documents 18 Article 3 — Contract Documents: Intent, Requirements, Reuse 19 3.01 Intent 19 3.02 Reference Standards 19 3.03 Reporting and Resolving Discrepancies 20 3.04 Interpretation of the Contract Documents 20 3.05 Reuse of Documents 20 Article 4 — Commencement and Progress of the Work 21 4.01 Commencement of Contract Times; Notice to Proceed 21 4.02 Starting the Work 21 4.03 Progress Schedule 21 4.04 Delays in Design/Builder's Progress 21 Article 5 —Availability of Lands; Subsurface and Physical Conditions; Hazardous Environmental Conditions 23 5.01 Availability of Lands 23 5.02 Use of Site and Other Areas 23 5.03 Subsurface and Physical Conditions 23 5.04 Differing Subsurface or Physical Conditions 24 5.05 Hazardous Environmental Conditions at Site 25 Article 6 — Bonds and Insurance 26 6.01 Performance, Payment, and Other Bonds 26 General Conditions — Design/Build (LS) Corpus Christi Standards 007200-1 Rev 5/2024 6.02 Licensed Sureties 27 6.03 Required Minimum Insurance Coverage 27 6.04 General Insurance Provisions 28 6.05 Design/Builder's Insurance 29 6.06 Property Insurance 32 6.07 Waiver of Rights 33 6.08 Owner's Insurance for Project 33 6.09 Acceptable Evidence of Insurance 34 6.10 Certificate of Insurance 34 6.11 Insurance Policies 34 6.12 Continuing Evidence of Coverage 34 6.13 Notices Regarding Insurance 35 6.14 Texas Workers' Compensation Insurance Required Notice 35 Article 7 — Design/Builder's Responsibilities 37 7.01 Supervision and Superintendence 37 7.02 Labor; Working Hours 37 7.03 Services, Materials, and Equipment 38 7.04 Concerning Subcontractors, Suppliers, and Others 38 7.05 Patent Fees and Royalties 40 7.06 Permits 40 7.07 Taxes 40 7.08 Laws and Regulations 40 7.09 Safety and Protection 41 7.10 Safety Representative 41 7.11 Hazard Communication Programs 42 7.12 Emergencies 42 7.13 Design/Builder's General Warranty and Guarantee 42 7.14 INDEMNIFICATION 43 Article 8 — Other Work at the Site 45 8.01 Other Work 45 8.02 Coordination 46 8.03 Legal Relationships 46 Article 9 — Owner's and OPT's Responsibilities 47 General Conditions — Design/Build (LS) Corpus Christi Standards 007200-2 Rev 5/2024 9.01 Communications to Design/Builder 47 9.02 Replacement of Owner's Project Team Members 47 9.03 Furnish Data 47 9.04 Pay When Due 47 9.05 Lands and Easements; Reports and Tests 47 9.06 Insurance 47 9.07 Modifications 47 9.08 Inspections, Tests, and Approvals 47 9.09 Limitations on OPT's Responsibilities 47 9.10 Undisclosed Hazardous Environmental Condition 47 9.11 Compliance with Safety Program 48 Article 10 — OAR's Status During Construction 48 10.01 Owner's Representative 48 10.02 Visits to Site 48 10.03 Resident Project Representatives 48 10.04 Rejecting Defective Work 48 10.05 Shop Drawings, Modifications and Payments 48 10.06 Decisions on Requirements of Contract Documents and Acceptability of Work 48 10.07 Limitations on OPT's Authority and Responsibilities 49 Article 11— Amending the Contract Documents; Changes in the Work 49 11.01 Amending and Supplementing the Contract Documents 49 11.02 Owner -Authorized Changes in the Work 50 11.03 Unauthorized Changes in the Work 50 11.04 Change of Contract Price 50 11.05 Change of Contract Times 51 11.06 Substitutions 51 Article 12 — Change Management 52 12.01 Change Proposals Submitted by Design/Builder 52 12.02 OPT Will Evaluate Request for Modification 53 12.03 Execution of Change Orders 53 12.04 Notice to Surety 54 Article 13 — Claims 54 13.01 Claims 54 General Conditions — Design/Build (LS) Corpus Christi Standards 007200-3 Rev 5/2024 13.02 Claims Process 55 Article 14 — Prevailing Wage Rate Requirements 56 14.01 Payment of Prevailing Wage Rates 56 14.02 Records 56 14.03 Liability; Penalty; Criminal Offense 57 14.04 Prevailing Wage Rates 57 Article 15 — Cost of the Work; Allowances; Unit Price Work 58 15.01 Cost of the Work 58 15.02 Allowances 61 15.03 Unit Price Work 62 15.04 Contingencies 62 Article 16—Tests and Inspections; Correction, Removal, or Acceptance of Defective Work 63 16.01 Access to Work 63 16.02 Tests, Inspections and Approvals 63 16.03 Defective Work 64 16.04 Acceptance of Defective Work 64 16.05 Uncovering Work 65 16.06 Owner May Stop the Work 65 16.07 Owner May Correct Defective Work 65 Article 17 — Payments to Design/Builder; Set -Offs; Completion; Correction Period 66 17.01 Progress Payments 66 17.02 Application for Payment 68 17.03 Schedule of Values 70 17.04 Schedule of Anticipated Payments and Earned Value 71 17.05 Basis for Payments 71 17.06 Payment for Stored Materials and Equipment 72 17.07 Retainage and Set -Offs 72 17.08 Procedures for Submitting an Application for Payment 73 17.09 Responsibility of Owner's Authorized Representative 74 17.10 Design/Builder's Warranty of Title 75 17.11 Final Application for Payment 75 17.12 Final Payment 75 17.13 Waiver of Claims 76 General Conditions — Design/Build (LS) Corpus Christi Standards 007200-4 Rev 5/2024 17.14 Correction Period 76 Article 18 — Suspension of Work and Termination 76 18.01 Owner May Suspend Work 76 18.02 Owner May Terminate for Cause 77 18.03 Owner May Terminate For Convenience 78 Article 19 — Project Management 78 19.01 Work Included 78 19.02 Quality Assurance 79 19.03 Document Submittal 79 19.04 Required Permits 79 19.05 Safety Requirements 79 19.06 Access to the Site 80 19.07 Design/Builder's Use of Site 80 19.08 Protection of Existing Structures and Utilities 80 19.09 Pre -Construction Exploratory Excavations 81 19.10 Disruption of Services/Continued Operations 81 19.11 Delivery and Storage 82 19.12 Cleaning During Construction 83 19.13 Maintenance of Roads, Driveways, and Access 83 19.14 Area Access and Traffic Control 84 19.15 Overhead Electrical Wires 84 19.16 Blasting 84 19.17 Archeological Requirements 84 19.18 Endangered Species Resources 85 19.19 Cooperation with Public Agencies 85 Article 20 — Project Coordination 85 20.01 Work Included 85 20.02 Document Submittal 85 20.03 Communication During Project 85 20.04 Project Meetings 86 20.05 Requests for Information 87 20.06 Decision and Action Item Log 88 20.07 Notification By Design/Builder 88 General Conditions — Design/Build (LS) Corpus Christi Standards 007200-5 Rev 5/2024 20.08 Record Documents 88 Article 21— Quality Management 90 21.01 Design/Builder's Responsibilities 90 21.02 Quality Management Activities by OPT 92 21.03 Design/Builder's Use of OPT's Test Reports 92 21.04 Documentation 92 21.05 Standards 93 21.06 Delivery and Storage 93 21.07 Verification Testing for Corrected Defects 93 21.08 Test Reports 94 21.09 Defective Work 94 21.10 Limitation of Authority of Testing Laboratory 94 21.11 Quality Control Plan 95 21.12 Implement Design/Builder's Quality Control Plan 96 Article 22 — Final Resolution of Disputes 97 22.01 Senior Level Negotiations 97 22.02 Mediation 98 Article 23 — Minority/MBE/DBE Participation Policy 98 23.01 Policy 98 23.02 Definitions 98 23.03 Goals 99 23.04 Compliance 100 Article 24 — Document Management 100 24.01 Work Included 100 24.02 Quality Assurance 100 24.03 Design/Builder's Responsibilities 100 24.04 Document Submittal 100 24.05 Document Numbering 101 24.06 Document Requirements 102 Article 25 — Shop Drawings 102 25.01 Work Included 102 25.02 Quality Assurance 103 25.03 Design/Builder's Responsibilities 103 General Conditions — Design/Build (LS) Corpus Christi Standards 007200-6 Rev 5/2024 25.04 Shop Drawing Requirements 104 25.05 Special Certifications and Reports 105 25.06 Warranties and Guarantees 105 25.07 Shop Drawing Submittal Procedures 105 25.08 Sample and Mockup Submittal Procedures 107 25.09 Equal Non Specified Products 108 25.10 Requests for Deviation 109 25.11 OAR Responsibilities 109 25.12 Resubmission Requirements 110 Article 26 — Record Data 110 26.01 Work Included 110 26.02 Quality Assurance 111 26.03 Design/Builder's Responsibilities 111 26.04 Record Data Requirements 112 26.05 Special Certifications and Reports 112 26.06 Warranties and Guarantees 112 26.07 Record Data Submittal Procedures 112 26.08 OAR's Responsibilities 114 Article 27 — Progress Schedule 114 27.01 Requirements 114 27.02 Document Submittal 115 27.03 Schedule Requirements 115 27.04 Schedule Revisions 116 27.05 Float Time 117 Article 28 — Video and Photographic documentation 117 28.01 Work Included 117 28.02 Quality Assurance 118 28.03 Document Submittal 118 28.04 Photographs 118 28.05 Video Recording 118 Article 29 — Execution and Closeout 119 29.01 Substantial Completion 119 29.02 Partial Utilization 119 General Conditions — Design/Build (LS) Corpus Christi Standards 007200-7 Rev 5/2024 29.03 Final Inspection 120 29.04 Reinspection Fees 120 29.05 Closeout Documents Submittal 120 29.06 Transfer of Utilities 120 29.07 Warranties, Bonds and Service Agreements 121 Article 30-Temporary Facilities and controls 121 30.01 Work Included 121 30.02 Quality Assurance 122 30.03 Delivery and Storage 122 30.04 Job Conditions 122 30.05 Options 122 30.06 Temporary Field Offices 123 30.07 Temporary Storage Buildings 123 30.08 Temporary Sanitary Facilities 123 30.09 Temporary Heat 123 30.10 Temporary Utilities 123 30.11 Water for Constructions 124 30.12 Location of Temporary Facilities 124 30.13 Project Identification and Signs 124 30.14 Temporary Lighting 124 30.15 Drinking Water 124 30.16 Construction Fence 124 30.17 Removal of Temporary Facilities 125 30.18 Maintenance and Janitorial Service 125 Article 31 -Temporary Controls 125 31.01 Work Included 125 31.02 Quality Assurance 125 31.03 Document Submittal 126 31.04 Standards 126 31.05 Permits 126 31.06 Stormwater Pollution Control 126 31.07 Pollution Control 127 31.08 Earth Control 128 General Conditions - Design/Build (LS) Corpus Christi Standards 007200-8 Rev 5/2024 31.09 Ozone Advisory Days 128 31.10 Management of Water 128 31.11 Dewatering 129 31.12 Disposal of Highly Chlorinated or Contaminated Water 129 31.13 Windstorm Certification 130 31.14 Constructing, Maintaining and Removing Temporary Controls 130 Article 32 — Miscellaneous 130 32.01 Computation of Times 130 32.02 Owner's Right to Audit Design/Builder's Records 130 32.03 Independent Contractor 131 32.04 Cumulative Remedies 131 32.05 Limitation of Damages 131 32.06 No Waiver 132 32.07 Severability 132 32.08 Survival of Obligations 132 32.09 No Third Party Beneficiaries 132 32.10 Assignment of Contract 132 32.11 No Waiver of Sovereign Immunity 132 32.12 Controlling Law 132 32.13 Conditions Precedent to Right to Sue 132 32.14 Waiver of Trial by Jury 133 32.15 Attorney Fees 133 32.16 Compliance with Laws 133 32.17 Enforcement 133 32.18 Subject to Appropriation 133 32.19 Contract Sum 134 32.20 Design/Builder's Guarantee as Additional Remedy 134 32.21 Notices 134 32.22 Public Information 134 General Conditions — Design/Build (LS) Corpus Christi Standards 007200-9 Rev 5/2024 ARTICLE 1— DEFINITIONS AND TERMINOLOGY 1.01 Defined Terms A. Terms with initial capital letters, including the term's singular and plural forms, have the meanings indicated in this paragraph wherever used in the Bidding Requirements or Contract Documents. In addition to the terms specifically defined, terms with initial capital letters in the Contract Documents may include references to identified articles and paragraphs, and the titles of other documents or forms. 1. Addenda - Documents issued prior to the receipt of Bids which clarify or modify the Bidding Requirements or the proposed Contract Documents. 2. Agreement - The document executed between Owner and Design/Builder covering the Work. 3. Alternative Dispute Resolution - The process by which a disputed Claim may be settled as an alternative to litigation if Owner and Design/Builder cannot reach an agreement between themselves. 4. Application for Payment - The forms used by Design/Builder to request payments from Owner and the supporting documentation required by the Contract Documents. 5. Award Date —The date the City Council of the City of Corpus Christi (City) authorizes the City Manager or designee to execute the Contract on behalf of the City. 6. Bonds - Performance Bond, Payment Bond, Maintenance Bond, and other Surety instruments executed by Surety. When in singular form, refers to individual instrument. 7. Change Order - A document issued on or after the Effective Date of the Contract, which modifies the Work, Contract Price, Contract Times, or terms and conditions of the Contract. 8. City Engineer - The Corpus Christi City Engineer and/or designee as identified at the preconstruction conference or in the Notice to Proceed. 9. Claim - A demand or assertion by Owner or Design/Builder submitted in accordance with the requirements of the Contract Documents. A demand for money or services by an entity other than the Owner or Design/Builder is not a Claim. 10. Constituent of Concern - Asbestos, petroleum, radioactive materials, polychlorinated biphenyls (PCBs), hazardous wastes, and substances, products, wastes, or other materials that are or become listed, regulated, or addressed pursuant to: a. The Comprehensive Environmental Response, Compensation and Liability Act, 42 U.S.C. §§9601 et seq. ("CERCLA"); b. The Hazardous Materials Transportation Act, 49 U.S.C. §§5101 et seq.; c. The Resource Conservation and Recovery Act, 42 U.S.C. §§6901 et seq. ("RCRA"); d. The Toxic Substances Control Act, 15 U.S.C. §§2601 et seq.; e. The Clean Water Act, 33 U.S.C. §§1251 et seq.; f. The Clean Air Act, 42 U.S.C. §§7401 et seq.; or General Conditions — Design/Build (LS) Corpus Christi Standards 007200-10 Rev 5/2024 g• Any other Laws or Regulations regulating, relating to, or imposing liability or standards of conduct concerning hazardous, toxic, or dangerous waste, substance, or material. 11. Contract - The entire integrated set of documents concerning the Work and describing the relationship between the Owner and Design/Builder. 12. Contract Amendment - A document issued on or after the Effective Date of the Contract and signed by Owner and Design/Builder which: a. Authorizes new phases of the Work and establishes the Contract Price, Contract Times, or terms and conditions of the Contract for the new phase of Work; or b. Modifies the terms and conditions of the Contract but does not make changes in the Work. 13. Contract Documents - Those items designated as Contract Documents in the Agreement. 14. Contract Price - The monetary amount stated in the Agreement and as adjusted by Modifications, and increases or decreases in unit price quantities, if any, that Owner has agreed to pay Design/Builder for completion of the Work in accordance with the Contract Documents. 15. Contract Times - The number of days or the dates by which Design/Builder must: a. Achieve specified Milestones; b. Achieve Substantial Completion; and c. Complete the Work. 16. Design/Builder's Team - Design/Builder and Subcontractors, Suppliers, individuals, or entities directly or indirectly employed or retained by them to perform part of the Work or anyone for whose acts they may be liable. 17. Cost of the Work - The sum of costs incurred for the proper performance of the Work as allowed by Article 15. 18. Defective - When applied to Work, refers to Work that is unsatisfactory, faulty, or deficient in that it: a. Does not conform to the Contract Documents; b. Does not meet the requirements of applicable inspections, reference standards, tests, or approvals referred to in the Contract Documents; or c. Has been damaged or stolen prior to OAR's recommendation of final payment unless responsibility for the protection of the Work has been assumed by Owner at Substantial Completion. 19. Design/Builder — A team that includes a licensed engineer and/or architect and a construction contractor to provide design and construction services. 20. Design Criteria Package means the document prepared by Owner that specifies the general scope of the Design Services to be performed. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-11 Rev 5/2024 21. Design Services means any and all architectural, engineering and design services required to be performed by Design/Builder pursuant to the Contract and all labor, materials, supervision, equipment, computers, documents and all other things necessary for the performance of such services. 22. Drawings - The part of the Contract that graphically shows the scope, extent, and character of the Work. 23. Effective Date of the Contract - The date indicated in the Agreement on which the City Manager or designee has signed the Contract. 24. Field Order - A document issued by OAR requiring changes in the Work that do not change the Contract Price or the Contract Times. 25. Hazardous Environmental Condition - The presence of Constituents of Concern at the Site in quantities or circumstances that may present a danger to persons or property exposed to Constituents of Concern. The presence of Constituents of Concern at the Site necessary for the execution of the Work or to be incorporated in the Work is not a Hazardous Environmental Condition provided these Constituents of Concern are controlled and contained pursuant to industry practices, Laws and Regulations, and the requirements of the Contract. 26. Indemnified Costs - All costs, losses, damages, and legal or other dispute resolution costs resulting from claims or demands against Owner. These costs include fees for engineers, architects, attorneys, and other professionals. 27. Instruments of Service — Representations, in any medium of expression now known or later developed, of the tangible and intangible creative work performed by Design/Builder and may include studies, surveys, models, sketches, drawings, specifications, digital models and other similar materials. 28. Laws and Regulations; Laws or Regulations - Applicable laws, statutes, rules, regulations, ordinances, codes, and orders of governmental bodies, agencies, authorities, and courts having jurisdiction over the Project. 29. Liens - Charges, security interests, or encumbrances upon Contract related funds, real property, or personal property. 30. Milestone - A principal event in the performance of the Work that Design/Builder is required by Contract to complete by a specified date or within a specified period of time. 31. Modification - Change made to the Contract Documents by one of the following methods: a. Contract Amendment; b. Change Order; c. Field Order; or d. Work Change Directive. 32. Notice of Award - The notice of Owner's intent to enter into a contract with the Selected Proposer. 33. Owner - The City of Corpus Christi (City), a Texas home -rule municipal corporation and political subdivision organized under the laws of the State of Texas, acting by and General Conditions — Design/Build (LS) Corpus Christi Standards 007200-12 Rev 5/2024 through its duly authorized City Manager and designee, the City Engineer (the Director of Engineering Services), and the City's officers, employees, agents, or representatives, authorized to administer design and construction of the Project. 34. Owner's Authorized Representative or OAR - The individual or entity named as OAR in the Agreement and the consultants, subconsultants, individuals, or entities directly or indirectly employed or retained by them to provide construction management services to the Owner. The OAR may be an independent contractor or an employee of the Owner. 35. Owner's Project Team or OPT - The Owner, Owner's Authorized Representative, Resident Project Representative, and the consultants, subconsultants, individuals or entities directly or indirectly employed or retained by them to provide services to the Owner. 36. Partial Occupancy or Use - Use by Owner of a substantially completed part of the Work for the purpose for which it is intended (or a related purpose) prior to Substantial Completion of all the Work. 37. Progress Schedule - A schedule prepared and maintained by Design/Builder, describing the sequence and duration of the activities comprising the Design/Builder's plan to accomplish the Work within the Contract Times. The Progress Schedule must be a Critical Path Method (CPM) Schedule. 38. Project - The total undertaking to be accomplished for Owner under the Contract Documents. 39. Resident Project Representative or RPR - The authorized representative of OPT assigned to assist OAR at the Site. As used herein, the term Resident Project Representative includes assistants and field staff of the OAR. 40. Samples - Physical examples of materials, equipment, or workmanship representing some portion of the Work that are used to establish the standards for that portion of the Work. 41. Schedule of Documents - A schedule of required documents, prepared and maintained by Design/Builder. 42. Schedule of Values - A schedule, prepared and maintained by Design/Builder, allocating portions of the Contract Price to various portions of the Work and used as the basis for Design/Builder's Applications for Payment. 43. Shop Drawings - All drawings, diagrams, illustrations, schedules, and other data or information that are specifically prepared or assembled and submitted by Design/Builder to illustrate some portion of the Work. Shop Drawings, whether approved or not, are not Drawings and are not Contract Documents. 44. Site - Lands or areas indicated in the Contract Documents as being furnished by Owner upon which the Work is to be performed. The Site includes rights -of -way, easements, and other lands furnished by Owner which are designated for use by the Design/Builder. 45. Specifications - The part of the Contract that describes the requirements for materials, equipment, systems, standards, and workmanship as applied to the Work, and certain administrative requirements and procedural matters applicable to the Work. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-13 Rev 5/2024 46. Subcontractor - An individual or entity having a direct contract with Design/Builder or with other Subcontractors or Suppliers for the performance of a part of the Work. 47. Substantial Completion - The point where the Work or a specified part of the Work is sufficiently complete to be used for its intended purpose in accordance with the Contract Documents. 48. Supplier - A manufacturer, fabricator, supplier, distributor, materialman or vendor having a direct contract with Design/Builder or with Subcontractors or other Suppliers to furnish materials or equipment to be incorporated in the Work. 49. Technical Data - Those items expressly identified as Technical Data in the Contract Documents with respect to either: a. Subsurface conditions at the Site; b. Physical conditions relating to existing surface or subsurface structures at the Site, except Underground Facilities; or c. Hazardous Environmental Conditions at the Site. 50. Underground Facilities - All underground pipelines, conduits, ducts, cables, wires, manholes, vaults, tanks, tunnels, other similar facilities or appurtenances, and encasements containing these facilities which are used to convey electricity, gases, steam, liquid petroleum products, telephone or other communications, fiber optic transmissions, cable television, water, wastewater, storm water, other liquids or chemicals, or traffic or other control systems. 51. Unit Price Work - Work to be paid for on the basis of unit prices. 52. Work — All services required to design and construct the Project or its component parts as required by the Contract Documents. 53. Work Change Directive - A directive issued to Design/Builder on or after the Effective Date of the Contract ordering an addition, deletion, or revision in the Work. The Work Change Directive serves as a memorandum of understanding regarding the directive until a Change Order can be issued. 1.02 Terminology A. The words and terms discussed in this Paragraph 1.02 are not defined, but when used in the Request for Qualifications/Request for Proposal or Contract Documents, have the indicated meaning. B. It is understood that the cost for performing Work is included in the Contract Price and no additional compensation is to be paid by Owner unless specifically stated otherwise in the Contract Documents. Expressions including or similar to "at no additional cost to Owner," "at Design/Builder's expense," or similar words mean that the Design/Builder is to perform or provide specified operation of Work without an increase in the Contract Price. C. The terms "day" or "calendar day" mean a calendar day of 24 hours measured from midnight to the next midnight. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-14 Rev 5/2024 D. The meaning and intent of certain terms or adjectives are described as follows: 1. The terms "as allowed," "as approved," "as ordered," "as directed," or similar terms in the Contract Documents indicate an exercise of professional judgment by the OPT. 2. Adjectives including or similar to "reasonable," "suitable," "acceptable," "proper," "satisfactory," or similar adjectives are used to describe a determination of OPT regarding the Work. 3. Any exercise of professional judgment by the OPT will be made solely to evaluate the Work for general compliance with the Contract Documents unless there is a specific statement in the Contract Documents indicating otherwise. 4. The use of these or similar terms or adjectives does not assign a duty or give OPT authority to supervise or direct the performance of the Work or assign a duty or give authority to the OPT to undertake responsibilities contrary to the provisions of Articles 9 or 10 or other provisions of the Contract Documents. E. The use of the words "furnish," "install," "perform," and "provide" have the following meanings when used in connection with services, materials, or equipment: 1. Furnish means to supply and deliver the specified services, materials or equipment to the Site or other specified location ready for use or installation. 2. Install means to complete construction or assembly of the specified services, materials, or equipment so they are ready for their intended use. 3. Perform or provide means to furnish and install specified services, materials, or equipment, complete and ready for their intended use. 4. Perform or provide the specified services, materials or equipment complete and ready for intended use if the Contract Documents require specific services, materials, or equipment, but do not expressly use the words "furnish," "install," "perform," or "provide." F. Contract Documents are written in modified brief style: 1. Requirements apply to all Work of the same kind, class, and type even though the word "all" is not stated. 2. Simple imperative sentence structure is used which places a verb as the first word in the sentence. It is understood that the words "furnish," "install," "perform," "provide," or similar words include the meaning of the phrase "The Design/Builder shall..." before these words. 3. Unless specifically stated that action is to be taken by the OPT or others, it is understood that the action described is a requirement of the Design/Builder. G. Words or phrases that have a well-known technical or construction industry or trade meaning are used in the Contract Documents in accordance with this recognized meaning unless stated otherwise in the Contract Documents. H. Written documents are required where reference is made to notices, reports, approvals, consents, documents, statements, instructions, opinions or other types of communications required by the Contract Documents. Approval and consent documents must be received by Design/Builder prior to the action or decision for which approval or consent is given. These General Conditions — Design/Build (LS) Corpus Christi Standards 007200-15 Rev 5/2024 may be made in printed or electronic format through the OPT's project management information system or other electronic media as required by the Contract Documents or approved by the OAR. I. Giving notice as required by the Contract Documents may be by printed or electronic media using a method that requires acknowledgment of the receipt of that notice. ARTICLE 2 — PRELIMINARY MATTERS; DESIGN SERVICES 2.01 Delivery of Bonds and Evidence of Insurance A. Provide Bonds as required by Article 6. B. Provide evidence of insurance required by the Contract Documents with the executed Agreement. 2.02 Copies of Documents A. OPT is to furnish one copy of the executed Contract Documents in electronic portable document format (PDF). This document is the Project Record Copy of the Contract Documents. 2.03 Project Management System A. Owner shall administer its design and construction management through an internet-based project management system known as e-Builder. B. Design/Builder shall conduct all communication through and perform all project -related functions utilizing this project management system. This includes all correspondence, submittals, requests for information, payment requests and processing, contract amendments, change orders and other administrative activities. C. Owner shall administer the software and provide training to Design/Builder's Team. 2.04 Before Starting Work A. Design/Builder's Representative shall be an employee of the Design/Builder (unless this requirement is waived in writing by the Owner), shall be reasonably available to Owner and shall have the necessary expertise and experience required to supervise the Work. Design/Builder's Representative shall communicate regularly with Owner and shall be vested with authority to act on behalf of Design/Builder. Design/Builder shall replace the Design/Builder's Representative upon Owner's request in the event the Design/Builder's Representative is unable to perform to Owner's satisfaction. B. Design/Builder shall provide Owner with a monthly status report detailing the progress of the Work, including whether (i) the Work is proceeding according to schedule, (ii) discrepancies, conflicts, or ambiguities exist in the Contract Documents that require resolution, (iii) health and safety issues exist in connection with the Work, and (iv) other items require resolution so as not to jeopardize Design/Builder's ability to complete the Work for the Contract Price and within the Contract Time(s). C. Design/Builder shall prepare and submit, at least three days prior to the meeting contemplated by Section 2.03.D hereof, an initial schedule for the execution of the Work for General Conditions — Design/Build (LS) Corpus Christi Standards 007200-16 Rev 5/2024 Owner's review and approval. The initial schedule shall indicate the dates for the start and completion of the various stages of Work, including the dates when Owner information and approvals are required to enable Design/Builder to achieve the Contract Time(s). The schedule shall be revised by the preliminary schedule and as required by conditions and progress of the Work, but such revisions shall not relieve Design/Builder of its obligations to complete the Work within the Contract Time(s), as such dates may be adjusted in accordance with the Contract Documents. Owner's review of and response to the initial schedule shall not be construed as relieving Design/Builder of its complete and exclusive control over the means, methods, sequences and techniques for executing the Work. Design/Builder's schedules shall identify the critical path for completing the Work. D. The parties will meet within seven days after execution of the Agreement, to discuss issues affecting the administration of the Work and to implement the necessary procedures, including those relating to submittals and payment, to facilitate the ability of the parties to perform their obligations under the Contract Documents. Design/Builder shall submit the following to Owner's Representative for Owner's review and approval no later than the meeting contemplated in this paragraph: 1. Letter designating Design/Builder's Representative. 2. Preliminary Schedule of Values for all of the Work. The approved Initial Schedule of Values will (i) subdivide the Work into its respective parts, (ii) include values for all items comprising the Work and (iii) serve as the basis for monthly progress payments made to Design/Builder throughout the services of the Work. This Initial Schedule of Values will include, but separately itemize, the services for the Design Phase from the cost of Construction. 3. Proposed Production Schedule for Design Phase Services in the form and substance required by the Agreement which will be used for determining the amount to be paid for those services over the duration of the Contract. E. Design/Builder shall not substitute any Subcontractor, Sub -subcontractor, person or organization that has been accepted by Owner, unless the substitute has been accepted in writing by Owner. 2.05 Design Services A. Design/Builder shall, consistent with applicable state licensing laws, provide through qualified, licensed design professionals employed by Design/Builder, or procured from qualified, independent licensed Design Consultants, the necessary design services, including architectural, engineering and other design professional services, for the preparation of the required drawings, specifications and other design submittals to permit Design/Builder to complete the Work consistent with the Contract Documents. Nothing in the Contract Documents is intended or deemed to create any legal or contractual relationship between Owner and any Design Consultant. B. The standard of care for all design professional services performed to execute the Work shall be the care and skill ordinarily used by members of the design profession practicing under similar conditions at the same time and locality of the Project. Notwithstanding the preceding sentence, if the parties agree upon specific performance standards for any aspect of the Work, which standards are to be set forth in an exhibit to the Agreement entitled General Conditions — Design/Build (LS) Corpus Christi Standards 007200-17 Rev 5/2024 "Performance Standard Requirements," the design professional services shall be performed to achieve such standards. C. Design/Builder and Owner shall, consistent with any applicable provision of the Contract Documents, agree upon any interim design submissions that Owner may wish to review, which interim design submissions may include design criteria, drawings, diagrams and specifications setting forth the Project requirements. On or about the time of the scheduled submissions, Design/Builder and Owner shall meet and confer about the submissions, with Design/Builder identifying during such meetings, among other things, the evolution of the design and any significant changes or deviations from the Contract Documents, or, if applicable, previously submitted design submissions. Minutes of the meetings will be maintained by Design/Builder and provided to all attendees for review. Following the design review meeting, Owner shall review and approve the interim design submissions in a time that is consistent with the turnaround times set forth in Design/Builder's schedule. 2.06 Construction Documents A. Design/Builder shall submit to Owner Construction Documents setting forth in detail drawings and specifications describing the requirements for construction of the Work. The Construction Documents shall be consistent with the latest set of interim design submissions, as such submissions may have been modified in a design review meeting. The parties shall have a design review meeting to discuss, and Owner shall review and approve the Construction Documents in accordance with the procedures set forth above. Design/Builder shall proceed with construction in accordance with the approved Construction Documents and shall submit a set of approved Construction Documents to Owner prior to commencement of construction. B. Owner's review and approval of interim design submissions and the Construction Documents is for the purpose of mutually establishing a conformed set of Contract Documents compatible with the requirements of the Work. Neither Owner's review nor approval of any interim design submissions and Construction Documents shall be deemed to transfer any design liability from Design/Builder to Owner. C. To the extent not prohibited by the Contract Documents or Legal Requirements, Design/Builder may prepare interim design submissions and Construction Documents for a portion of the Work to permit construction to proceed on that portion of the Work prior to completion of the Construction Documents for the entire Work. D. Design/Builder shall perform the Work in accordance with all Legal Requirements and shall provide all notices applicable to the Work as required by the Legal Requirements. E. The Contract Price and/or Contract Time(s) shall be adjusted to compensate Design/Builder for the effects of any changes in the Legal Requirements enacted after the date of the Agreement affecting the performance of the Work. Such effects may include, without limitation, revisions Design/Builder is required to make to the Construction Documents because of changes in Legal Requirements. F. Except as otherwise provided in the Contract Documents, Design/Builder shall obtain and pay for all necessary permits, approvals, licenses, government charges and fees required for the prosecution of the Work by any government or quasi -government entity having jurisdiction over the Project. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-18 Rev 5/2024 G. Design/Builder shall provide reasonable assistance to Owner in obtaining those permits, approvals and licenses that are Owner's responsibility. ARTICLE 3 — CONTRACT DOCUMENTS: INTENT, REQUIREMENTS, REUSE 3.01 Intent A. Requirements of components of the Contract Documents are as binding as if required by all Contract Documents. It is the intent of the Contract Documents to describe a functionally complete Project. 1. The Contract requirements described in the Contract Documents apply to Work regardless of where it is described in the Contract Documents, unless specifically noted otherwise. 2. In submitting a proposal for this Project and in entering into this Contract, Design/Builder represents: a. Design/Builder has studied the design criteria, the Site, local conditions, Laws and Regulations, and other conditions that may affect the Work; b. Design/Builder has studied any Technical Data or other information referred to in the Contract Documents and has or will make additional surveys and investigations as deemed necessary for the performance of the Work; B. The Project Record Copy of the Contract Documents governs if there is a discrepancy between the Project Record Copy of the Contract Documents and subsequent electronic or digital versions of the Contract Documents, including printed copies derived from these electronic or digital versions. C. The Contract Documents comprise the entire Agreement between Owner and Design/Builder and supersedes all prior written or oral negotiations, representations, and agreements. The Contract Documents may be modified only by a Modification. D. Request clarification from OAR for a decision before proceeding if Design/Builder is not clear on the meaning of the Contract Documents. OAR is to issue clarifications and interpretations of the Contract Documents in accordance with the Contract Documents. 3.02 Reference Standards A. Standard Specifications, Codes, Laws and Regulations: 1. Reference in the Contract Documents to standard specifications, manuals, reference standards, or codes of technical societies, organizations, or associations, or to Laws or Regulations, whether specific or implied, are those in effect at the time Design/Builder's proposal is submitted or when Design/Builder negotiates the Contract Price unless specifically stated otherwise in the Contract Documents. 2. No provision of referenced standard specifications, manuals, reference standards, codes, or instructions of a Supplier changes the duties or responsibilities of OPT or Design/Builder from those described in the Contract Documents or assigns a duty to or gives authority to the OPT to supervise or direct the performance of the Work or undertake responsibilities inconsistent with the Contract Documents. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-19 Rev 5/2024 3. The provisions of the Contract Documents take precedence over standard specifications, manuals, reference standards, codes, or instructions of a Supplier unless specifically stated otherwise in the Contract Documents. B. Comply with applicable construction industry standards, whether referenced or not. 1. Standards referenced in the Contract Documents govern over standards not referenced but recognized as applicable in the construction industry. 2. Comply with the requirements of the Contract Documents if they produce a higher quality of Work than the applicable construction industry standards. C. Make copies of reference standards available if requested by OAR. 3.03 Reporting and Resolving Discrepancies A. Reporting Discrepancies: 1. Immediately notify the OAR of conflicts, errors, ambiguities, or discrepancies in the Contract Documents or discrepancies between the Contract Documents and: a. Applicable Laws or Regulations; b. Actual field conditions; c. Standard specifications, manuals, reference standards, or codes. 2. Design/Builder is liable to the Owner for failure to report conflicts, errors, ambiguities, or discrepancies in the Contract Documents of which Design/Builder has actual knowledge. 3.04 Interpretation of the Contract Documents A. Submit questions concerning the non -technical or contractual / administrative requirements of the Contract Documents to the OAR immediately after those questions arise. OAR is to provide an interpretation of the Contract Documents regarding these questions and will coordinate the response of the OPT to Design/Builder. B. OPT may initiate a Modification to the Contract Documents through the OAR if a response to the question indicates that a change in the Contract Documents is required. Design/Builder may appeal OAR's interpretation by submitting a Change Proposal. 3.05 Reuse of Documents A. Design/Builder's Team has no rights to the Contract Documents and may not use the Contract Documents, or copies or electronic media editions of the Contract Documents, other than for the construction of this Project. This provision survives final payment or termination of the Contract. B. Design/Builder certifies that title to all Instruments of Service prepared for the Work shall pass to Owner upon payment for that portion of the Work. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-20 Rev 5/2024 ARTICLE 4 — COMMENCEMENT AND PROGRESS OF THE WORK 4.01 Commencement of Contract Times; Notice to Proceed A. The Contract Times commence to run on the date indicated in the Notice to Proceed. 4.02 Starting the Work A. Begin performing the Work on the date indicated in the Notice to Proceed. Do not begin Work prior to having the insurance required in Article 6 in force or before the date indicated in the Notice to Proceed. 4.03 Progress Schedule A. Submit a Schedule that complies with Article 27 for the Design and Construction phases of the Project. B. Design and Construct the Work in accordance with the Progress Schedule established in accordance with the Contract Documents. 1. Adjust the Progress Schedule as required to accurately reflect actual progress on the Work. 2. Submit proposed adjustments in the Progress Schedule that change the Contract Times in accordance with the requirements of Article 11. C. Continue performing Work and adhere to the Progress Schedule during disputes or disagreements with Owner. Do not delay or postpone Work pending resolution of disputes or disagreements, or during an appeal process. 4.04 Delays in Design/Builder's Progress A. No Damages for Delay: Design/Builder shall receive no compensation for delays or hindrances to the Work, except in the case of direct interference with means and methods by the Owner. In no event shall the Design/Builder be entitled to any compensation or recovery of any special damages in connection with any delays, including without limitation: consequential damages, lost opportunity costs, impact damages, or other similar damages. Owner's exercise of any of its rights or remedies under the Contract Documents (including without limitation ordering changes in the Work, or directing suspension, rescheduling, or correction of the Work), regardless of the extent or frequency of Owner's exercise of such rights or remedies, shall not be construed as active interference in the Design/Builder's performance of the Work. An extension of Contract Time, to the extent permitted, shall be the sole remedy of the Design/Builder for any acknowledged delays. Design/Builder agrees that the extension of time provides an equitable adjustment. B. Design/Builder is not entitled to an adjustment in Contract Price or Contract Times for delays, disruptions, or interference caused by or within the control of Design/Builder's Team. C. No time extensions are allowed for weather conditions, other than those listed in Paragraph 4.04.D, for Projects using calendar days or a fixed date to establish the Contract Time. Design/Builder is to include the cost associated with weather related delays in the Contract Price and assumes the risks associated with delays related to weather conditions. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-21 Rev 5/2024 D. Design/Builder is entitled to an equitable adjustment in the Contract Times if Design/Builder's performance or progress is delayed, disrupted or interfered with by unanticipated causes not the fault of and beyond the control of Owner or Design/Builder. These adjustments in Contract Times are the Design/Builder's sole and exclusive remedy for the delays, disruption, and interference described in this paragraph. These unanticipated causes may include: 1. Severe and unavoidable natural catastrophes e.g. fires, floods, hurricanes, epidemics, and earthquakes; 2. Acts or failures to act of utility owners performing other work at or adjacent to the Site; 3. Acts of war or terrorism; and 4. Rain days in excess of the number specified in a calendar year. A rain day is defined as any day in which the amount of rain measured by the National Weather Services at the Power Street Stormwater Pump Station is 0.50 inch or greater. Records indicate the following average number of rain days for each month: Month Day Month Days January 3 July 3 February 3 August 4 March 2 September 7 April 3 October 4 May 4 November 3 June 4 December 3 E. Delays, disruption, and interference to the performance or progress of the Work resulting from the following are governed by Article 5: 1. The existence of a differing subsurface or physical condition; and 2. Hazardous Environmental Conditions. F. Article 8 governs delays, disruption, and interference to the performance or progress of the Work resulting from the performance of certain other work at or adjacent to the Site. G. Notify the OAR immediately of a potential delaying, disrupting, or interfering event. Submit a Change Proposal seeking an adjustment in Contract Price or Contract Times within 30 days of the commencement of the delaying, disrupting, or interfering event. Claims for adjustment to the Contract Price or Contract Times that do not strictly comply with Article 13 are waived. H. Design/Builder is only entitled to an adjustment of the Contract Times for specific delays, disruptions, and interference to the performance or progress of the Work that can be demonstrated to directly impact the ability of the Design/Builder to complete the Work within the Contract Times. No adjustments in Contract Times are allowed for delays on components of the Work which were or could have been completed without impacting the Contract Times. I. Design/Builder is not entitled to an adjustment in Contract Price or Contract Times for delay, disruption, or interference caused by or within the control of the Owner if this delay is General Conditions — Design/Build (LS) Corpus Christi Standards 007200-22 Rev 5/2024 concurrent with a delay, disruption, or interference attributable to or within the control of the Design/Builder's Team. ARTICLE 5 —AVAILABILITY OF LANDS; SUBSURFACE AND PHYSICAL CONDITIONS; HAZARDOUS ENVIRONMENTAL CONDITIONS 5.01 Availability of Lands A. Owner is to furnish the Site and inform the Design/Builder of encumbrances or restrictions known to Owner related to use of the Site with which Design/Builder must comply in performing the Work. B. Provide for additional lands and access Design/Builder requires for temporary construction facilities or storage of materials and equipment, other than those identified in the Contract Documents. Provide documentation of authority to use these additional lands to OAR before using them. 5.02 Use of Site and Other Areas A. Limitation on Use of Site and Other Areas: 1. Confine construction equipment, temporary construction facilities, the storage of materials and equipment, and the operations of workers to the Site, adjacent areas that Owner or Design/Builder has arranged to use through construction easements or agreements, and other adjacent areas as permitted by Laws and Regulations. Assume full responsibility for damage or injuries which result from the performance of the Work or from other actions or conduct of the Design/Builder's Team, including: a. Damage to the Site; b. Damage to adjacent areas used for Design/Builder's Team's operations; c. Damage to other adjacent land or areas; and d. Injuries and losses sustained by the owners or occupants of these lands or areas. 2. Take the following action if a damage or injury claim is made by the owner or occupant of adjacent land or area because of the performance of the Work, or because of other actions or conduct of the Design/Builder's Team: a. Take immediate corrective or remedial action as required by Paragraph 7.09; and b. Attempt to settle the claim through negotiations with the owner or occupant, or otherwise resolve the claim by mediation or other dispute resolution proceeding or at law. 5.03 Subsurface and Physical Conditions A. Owner makes no representation whatsoever as to the completeness of any information in Technical Data, and Design -Builder specifically acknowledges that Owner assumes and accepts no responsibility that the geotechnical information, as may be available in the geotechnical reports is accurate or completely describes actual site conditions that may affect the Work. Owner does not assume any responsibility whatsoever in respect to the sufficiency and locations of borings made, or of the log of test borings, or of other General Conditions — Design/Build (LS) Corpus Christi Standards 007200-23 Rev 5/2024 investigations, or of the interpretations made thereof, and there is no warranty or guarantee, either expressed or implied, that the conditions indicated by such investigations are representative of those existing throughout such area, or any part thereof or that unforeseen developments may not occur. B. The Design/Builder is responsible for: 1. Investigating and field -verifying the location of underground facilities before beginning Work; 2. Reviewing and checking available information and data regarding existing Underground Facilities at the Site; 3. Complying with Laws and Regulations related to locating Underground Facilities before beginning Work; 4. Coordinating the Work with the owners, including Owner, of Underground Facilities during construction; and 5. The safety and protection of existing Underground Facilities at or adjacent to the Site and repairing damage resulting from the Work. 5.04 Differing Subsurface or Physical Conditions A. Notify OAR immediately, but in no event later than 3 days, after becoming aware of a subsurface or physical condition that is uncovered or revealed at the Site, and before further disturbing the subsurface or physical conditions or performing any related Work that is of an unusual nature and differs materially from conditions ordinarily encountered and generally recognized as inherent in work of the character provided for in the Contract Documents. Do not further disturb or perform Work related to this subsurface or physical condition, except in an emergency as required by Paragraph 7.12, until permission to do so is issued by OAR. B. OAR is to issue a statement to Design/Builder regarding the subsurface or physical condition in question and recommend action as appropriate. C. Possible Contract Price and Contract Times Adjustments: 1. Design/Builder is entitled to an equitable adjustment in Contract Price or Contract Times to the extent that a differing subsurface or physical condition causes a change in Design/Builder's cost or time to perform the Work provided the condition falls under either Paragraph 5.04.A. Any adjustment in Contract Price for Work that is paid for on a unit price basis is subject to the provisions of Paragraph 15.03. 2. Design/Builder is not entitled to an adjustment in the Contract Price or Contract Times with respect to a subsurface or physical condition if: a. Design/Builder knew of the existence of the subsurface or physical condition at the time Design/Builder made an offer to Owner with respect to Contract Price and Contract Times; b. The existence of the subsurface or physical condition could have been discovered or revealed as a result of examinations, investigations, explorations, tests, or General Conditions — Design/Build (LS) Corpus Christi Standards 007200-24 Rev 5/2024 studies of the Site and contiguous areas expressly required by the Proposal Requirements or Contract Documents; or c. Design/Builder failed to give notice as required by Paragraph 5.04.A. 3. Design/Builder may submit a Change Proposal no later than 30 days after OAR's issuance of the statement to Design/Builder regarding the subsurface or physical condition in question. 4. A Change Order is to be issued by the OAR if Owner and Design/Builder agree that Design/Builder is entitled to an adjustment in the Contract Price or Contract Times and agree to the amount or extent of adjustments in the Contract Price or Contract Times. 5.05 Hazardous Environmental Conditions at Site A. Technical Data may contain reports and drawings relating to Hazardous Environmental Conditions. These reports and drawings are not Contract Documents. The information and data shown or indicated with respect to Hazardous Environmental Conditions at or adjacent to the Site is based on information and data furnished to Owner by others. Owner is not responsible for the accuracy or completeness of information or data provided by others that Owner makes available to Design -Builder. B. Design -Builder may not rely upon or make claims against Owner with respect to: 1. The completeness of these reports for Design -Builder's purposes, including aspects of the means, methods, techniques, sequences and procedures of construction to be employed by Design -Builder or Design -Builder's safety precautions and programs related to Hazardous Environmental Conditions; 2. Other data, interpretations, opinions, and information contained in these reports; or 3. Any Design -Builder interpretation of or conclusion drawn from Technical Data or other data, interpretations, opinions or information. C. The results of tests performed on materials described in environmental reports specifically prepared for the Project and made available to Design -Builder are defined as Technical Data. D. Design/Builder is not responsible for removing or remediating Hazardous Environmental Conditions encountered, uncovered or revealed at the Site unless this removal or remediation is expressly identified in the Contract Documents to be within the scope of the Work. E. Design/Builder is responsible for controlling, containing, and duly removing and remediating Constituents of Concern brought to the Site by Design/Builder's Team and paying associated costs. 1. Owner may remove and remediate the Hazardous Environmental Condition and impose a set-off against payments to Design/Builder for associated costs if Design/Builder's Team creates a Hazardous Environmental Condition, and Design/Builder does not take acceptable action to remove and remediate the Hazardous Environmental Condition. 2. Design/Builder's obligation to indemnify Owner for claims arising out of or related to Hazardous Environmental Conditions are as set forth in Paragraph 7.14. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-25 Rev 5/2024 F. Immediately notify the OAR and take the following action if Design/Builder uncovers or reveals a Hazardous Environmental Condition at the Site or adjacent areas used by the Design/Builder's Team that was not created by the Design/Builder's Team, not identified in the Contract Documents and is unknown to Design/Builder: 1. Secure or otherwise isolate this condition; 2. Stop Work in affected areas or connected with the condition, except in an emergency as required by Paragraph 7.12; and 3. Do not resume Work in connection with the Hazardous Environmental Condition or in affected areas until after OPT has obtained required permits and OAR sends notice to the Design/Builder: a. Specifying that this condition and affected areas are or have been rendered safe for the resumption of Work; or b. Specifying special conditions under which Work may be resumed safely. 4. Owner may order the portion of the Work that is in the area affected by the Hazardous Environmental Condition to be deleted from the Work following the procedures in Article 11 if Design/Builder does not agree to: a. Resume the Work based on a reasonable belief it is unsafe; or b. Resume the Work under the special conditions provided by the OAR. 5. Owner may have this deleted portion of the Work performed by Owner's own forces or others in accordance with Article 8. G. Design/Builder may submit a Change Proposal or Owner may impose a set-off if an agreement is not reached within 10 days of OAR's notice regarding the resumption of Work as to whether Design/Builder is entitled to an adjustment in Contract Price or Contract Times or on the amount or extent of adjustments resulting from this Work stoppage or special conditions under which Design/Builder agrees to resume Work. H. The provisions of Paragraph 5.04 do not apply to the presence of Constituents of Concern or a Hazardous Environmental Condition uncovered or revealed at the Site. ARTICLE 6 — BONDS AND INSURANCE 6.01 Performance, Payment, and Other Bonds A. Furnish Performance and Payment Bonds, each in an amount equal to the contract price for construction, as security for the faithful performance and payment of Design/Builder's obligations under the Contract Documents. These Bonds are to remain in effect until 1 year after the date of final payment. Furnish other Bonds as required by the Contract Documents. B. Bonds furnished by the Design/Builder must meet the requirements of Texas Insurance Code Chapter 3503, Texas Government Code Chapter 2253, and all other applicable Laws and Regulations. C. Notify OAR immediately if the surety on Bonds furnished by Design/Builder: 1. Is declared bankrupt or becomes insolvent; 2. Has its right to do business in Texas terminated; or General Conditions — Design/Build (LS) Corpus Christi Standards 007200-26 Rev 5/2024 3. Ceases to meet the requirements of Paragraph 6.02. Provide a Bond and surety which comply with the requirements of Paragraph 6.02 within 20 days after the event giving rise to this notification. D. Design/Builder is to use amounts paid by Owner to Design/Builder under the Contract for the performance of the Contract and to satisfy claims against the Payment Bond. E. Notify the OAR of claims filed against the Payment Bond. Notify the claimant and OAR of undisputed amounts and the basis for challenging disputed amounts when a claimant has satisfied the conditions prescribed by Texas Government Code Chapter 2253. Promptly pay undisputed amount. F. Owner is not liable for payment of costs or expenses of claimants under the Payment Bond. Owner has no obligations to pay, give notice or take other action to claimants under the Payment Bond. G. Owner may exclude the Design/Builder from the Site and exercise Owner's termination rights under Article 18 if Design/Builder fails to obtain or maintain required Bonds. H. OPT will provide a copy of the Payment Bond to Subcontractors, Suppliers, or other persons or entities claiming to have furnished labor or materials used in the performance of the Work that request this information in accordance with Texas Government Code Chapter 2253. 6.02 Licensed Sureties A. Provide Bonds in the form prescribed by the Contract Documents from sureties named in the list of "Companies Holding Certificates of Authority as Acceptable Sureties on Federal Bonds and as Acceptable Reinsuring Companies" as published in Circular 570 (amended) by the Financial Management Service, Surety Bond Branch, U.S. Department of the Treasury. B. Provide Bonds required by the Contract Documents from surety companies that are duly licensed or authorized to provide bonds in the State of Texas. 6.03 Required Minimum Insurance Coverage A. Obtain and maintain insurance as required in this Article. B. Deliver evidence of insurance to the Owner to demonstrate that Design/Builder has obtained and is maintaining the policies, coverages, and endorsements required by the Contract Documents. Type of Insurance Minimum Insurance Coverage Commercial General Liability including 1. Commercial Form 2. Premises — Completed Operations 3. Premises — Medical Expense 4. Explosions and Collapse Hazard 5. Underground Hazard $1,000,000 Per Occurrence 6. Products / Completed Operations Hazard $2,000,000 Aggregate 7. Contractual Liability 8. Broad Form Property Damage 9. Independent Contractors General Conditions — Design/Build (LS) Corpus Christi Standards 007200-27 Rev 5/2024 10. Personal & Advertising Injury 11.Fire Damage (Damage to Rented Premises) Business Automobile Liability - Owned, Non - Owned, Rented and Leased $500,000 Combined Single Limit Workers' Compensation Statutory Employer's Liability $500,000/ 500,000/ 500,000 Excess Liability/Umbrella Liability $1,000,000 Per Occurrence Contractor's Pollution Liability / Environmental Impairment Coverage Not limited to sudden and accidental discharge. To include long-term environmental impact for the disposal of pollutants/contaminants. $1,000,000 Per Claim Builder's Risk (All Perils including Collapse) Equal to Full Replacement Cost of Structure and Contents Installation Floater Required if installing city -owned equipment Equal to Contract Price Professional Liability (Errors and Omissions) $1,000,000 Per Claim If claims made policy, retro date must be prior to inception of Design -Build Agreement, have extended reporting period provisions and identify any limitations regarding who is insured. 6.04 General Insurance Provisions A. Provide insurance coverages and limits meeting the requirements for insurance in accordance with this Article 6. B. Provide endorsements to the policies as outlined in this Article. C. Obtain insurance from companies that are duly licensed or authorized in the State of Texas to issue insurance policies for the required limits and coverages. Provide insurance from companies that have an A.M. Best rating of A-VIII or better. D. Furnish copies of endorsements and documentation of applicable self -insured retentions and deductibles upon request by OPT or any named insured or additional insured. Design/Builder may block out (redact) any confidential premium or pricing information contained in any endorsement furnished under this Contract. E. The name and number of the Project must be referenced on the certificate of insurance. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-28 Rev 5/2024 F. OPT's failure to demand such certificates or other evidence of the Design/Builder's full compliance with the insurance requirements or failure to identify a deficiency in compliance from the evidence provided is not a waiver of the Design/Builder's obligation to obtain and maintain the insurance required by the Contract Documents. G. Notify the Owner if the Design/Builder fails to purchase or maintain the insurance required by the Contract Documents. Design/Builder shall not be allowed to perform any Work on the Project until the required insurance policies are in effect. A Certificate of Liability Insurance shall be submitted to the OPT. H. Owner may exclude the Design/Builder from the Site and exercise Owner's termination rights under Article 18 if Design/Builder fails to obtain or maintain the required insurance. I. Owner does not represent that the insurance coverage and limits established in this Contract are adequate to protect Design/Builder or Design/Builder's interests. J. The required insurance and insurance limits do not limit the Design/Builder's liability under the indemnities granted to Owner in the Contract Documents. K. Provide for an endorsement that the "other insurance" clause shall not apply to the OPT where the OPT is an additional insured shown on the policy. Design/Builder's insurance is primary and non-contributory with respect to any insurance or self-insurance carried by the OPT for liability arising out of operations under this Contract. L. Include the Owner and list the other members of the OPT and any other individuals or entities as additional insureds on all policies with the exception of the workers' compensation policy and Design/Builder's professional liability policy. 6.05 Design/Builder's Insurance A. Purchase and maintain workers' compensation and employer's liability insurance for: 1. Claims under workers' compensation, disability benefits, and other similar employee benefit acts. Obtain workers' compensation coverage through a licensed insurance company in accordance with Texas law and written on a policy and endorsements approved by the Texas Department of Insurance. Provide insurance in amounts to meet all workers' compensation obligations. Provide an "All Other States" endorsement if Design/Builder is not domiciled in Texas and policy is not written in accordance with Texas Department of Insurance rules. 2. Claims for damages because of bodily injury, occupational sickness or disease, or death of Design/Builder's employees. 3. United States Longshoreman and Harbor Workers' Compensation Act and Jones Act coverage (if applicable). 4. Foreign voluntary worker compensation (if applicable). B. Purchase and maintain commercial general liability insurance covering all operations by or on behalf of Design/Builder. The expected coverage is that which would be included in a commercially available ISO Commercial General Liability policy and should provide coverage on an occurrence basis, against: 1. Claims for damages because of bodily injury, sickness or disease, or death of any person other than Design/Builder's employees; General Conditions — Design/Build (LS) Corpus Christi Standards 007200-29 Rev 5/2024 2. Claims for damages insured by reasonably available personal injury liability coverage which are sustained; 3. By any person as a result of an offense directly or indirectly related to the employment of such person by Design/Builder; and 4. Claims for damages, other than to the Work itself, because of injury to or destruction of tangible property wherever located, including any resulting loss of use. C. Provide Design/Builder's commercial general liability policy that is written on a 1996 (or later) ISO commercial general liability form (occurrence form) and include the following coverages and endorsements: 1. Products and completed operations coverage as required in the Contract Documents. 2. Insurance is to remain in effect for 3 years after final payment. Furnish evidence of the continuation of this insurance at final payment and again each year for 3 years after final payment to Owner and each named insured or additional insured. a. If required by the Contract Documents, provide and maintain Installation Floater insurance for property under the care, custody, or control of Design/Builder. Provide Installation Floater insurance that is a broad form or "All Peril" policy providing coverage for all materials, supplies, machinery, fixtures, and equipment which will be incorporated into the Work. 1) Provide coverage under the Design/Builder's Installation Floater that includes: a) Faulty or Defective workmanship, materials, maintenance, or construction; b) Cost to remove Defective or damaged Work from the Site or to protect it from loss or damage; c) Cost to cleanup and remove pollutants; d) Coverage for testing and startup; e) Any loss to property while in transit; f) Any loss at the Site; g) Any loss while in storage, both on and off the Site; and h) Any loss to temporary Project Works if their value is included in the Contract Price. 2) Coverage cannot be contingent on an external cause or risk or limited to property for which the Design/Builder is legally liable. Provide limits of insurance adequate to cover the value of the installation. Pay any deductible carried under this coverage and assume responsibility for claims on materials, supplies, machinery, fixtures, and equipment which will be incorporated into the Work while in transit or in storage. 3. Blanket contractual liability coverage for Design/Builder's contractual indemnity obligations in Paragraph 7.14, and all other contractual indemnity obligations of Design/Builder in the Contract Documents. Industry standard ISO Contractual Liability coverage will meet this obligation. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-30 Rev 5/2024 4. Broad form property damage coverage. 5. Severability of interest. 6. Underground explosion and collapse coverage. 7. Personal injury coverage. 8. Endorsement CG 2032, "Additional Insured - Engineers, Architects or Surveyors Not Engaged by the Named Insured" or its equivalent. D. Purchase and maintain automobile liability insurance against claims for damages because of bodily injury or death of any person or property damage arising out of the ownership, maintenance or use of any motor vehicle. E. For Projects with a Contract Value that exceeds $5,000,000, purchase and maintain umbrella or excess liability insurance written over the underlying employer's liability, commercial general liability, and automobile liability insurance described in the paragraphs above. Provide coverage that is at least as broad as all underlying policies. Provide a policy that provides first -dollar liability coverage as needed. F. Provide Design/Builder's commercial general liability and automobile liability policies that: 1. Are written on an occurrence basis; 2. Include the individuals or entities identified in the Contract Documents as additional insureds; 3. Include coverage for Owner as defined in Article 1; and 4. Provide primary coverage for all claims covered by the policies, including those arising from both ongoing and completed operations. G. Purchase and maintain insurance coverage for third -party injury and property damage claims, including clean-up costs that result from Hazardous Environmental Conditions which result from Design/Builder's operations and completed operations. Provide Design/Builder's pollution liability insurance that includes long-term environmental impacts for the disposal of pollutants/contaminants and is not limited to sudden and accidental discharge. The completed operations coverage is to remain in effect for 3 years after final payment. The policy must name OPT and any other individuals and entities identified in the Contract Documents as additional insureds. H. Purchase and maintain applicable professional liability insurance, or have Subcontractors and Suppliers do so, if Design/Builder or any Subcontractor or Supplier will provide or furnish professional services under this Contract. I. The policies of insurance required by this Article must: 1. Include at least the specific coverages and be written for not less than the limits of liability provided in the Contract Documents or required by Laws or Regulations, whichever is greater. 2. Contain a provision that coverage afforded will not be canceled or materially changed until at least 30 days prior written notice has been given to Design/Builder, Owner, and all named insureds and additional insureds. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-31 Rev 5/2024 3. Remain in effect at all times when Design/Builder is performing Work or is at the Site to conduct tasks arising from the Contract Documents. 4. Be appropriate for the Work being performed and provide protection from claims resulting from the Design/Builder's performance of the Work and Design/Builder's other obligations under the Contract Documents, whether performed by Design/Builder, Subcontractor, Supplier, anyone directly or indirectly employed or retained by any of them, or by anyone for whose acts they may be liable. J. The coverage requirements for specific policies of insurance must be met directly by those policies and may not rely on excess or umbrella insurance provided in other policies to meet the coverage requirement. 6.06 Property Insurance A. Purchase and maintain builder's risk insurance in the amount of the full replacement cost of the Project. This policy is subject to the deductible amounts requirements in the Contract Documents or those required by Laws and Regulations and must comply with the requirements of Paragraph 6.09. This insurance shall: 1. Include the OPT, Design/Builder, and all Subcontractors, and any other individuals or entities identified in the Contract Documents, as named insureds. 2. Be written on a builder's risk "all risk" policy form that includes insurance for physical loss or damage to the Work, temporary buildings, falsework, and materials and equipment in transit, and insures against at least the following perils or causes of loss: fire; lightning; windstorm; riot; civil commotion; terrorism; vehicle impact; aircraft; smoke; theft; vandalism and malicious mischief; mechanical breakdown, boiler explosion, and artificially generated electric current; earthquake; volcanic activity, and other earth movement; flood; collapse; explosion; debris removal; demolition occasioned by enforcement of Laws and Regulations; water damage (other than that caused by flood); and such other perils or causes of loss as may be specifically required by this Section. If insurance against mechanical breakdown, boiler explosion, and artificially generated electric current; earthquake; volcanic activity, and other earth movement; or flood, are not commercially available under builder's risk, by endorsement or otherwise, this insurance may be provided through other insurance policies acceptable to Owner and Design/Builder. 3. Cover expenses incurred in the repair or replacement of any insured property. 4. Cover materials and equipment in transit or stored prior to being incorporated in the Work. 5. Cover Owner -furnished or assigned property. 6. Allow for partial utilization of the Work by Owner. 7. Allow for the waiver of the insurer's subrogation rights as set forth below. 8. Provide primary coverage for all losses and damages caused by the perils or causes of loss covered. 9. Not include a co-insurance clause. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-32 Rev 5/2024 10. Include a broad exception for ensuing losses from physical damage or loss with respect to any Defective workmanship, design, or materials exclusions. 11. Include testing and startup. 12. Be maintained in effect until the Work as a whole is complete, unless otherwise agreed to in writing by Owner and Design/Builder. B. Evidence of insurance provided must contain a provision or endorsement that the coverage afforded will not be canceled or materially changed or renewal refused until at least 30 days' prior written notice has been given to Owner and Design/Builder and to each named insured. C. Pay for costs not covered by the policy deductible. D. Notify builder's risk insurance provider if Owner will occupy or use a portion or portions of the Work prior to Substantial Completion of all the Work. Maintain the builder's risk insurance in effect during this Partial Occupancy or Use. E. Design/Builder may purchase other special insurance to be included in or to supplement the builder's risk or property insurance policies provided under the Contract Documents. F. Design/Builder, Subcontractors, or employees of the Design/Builder or a Subcontractor owning property items, such as tools, construction equipment, or other personal property not expressly covered in the insurance required by the Contract Documents are responsible for providing their own insurance. 6.07 Waiver of Rights A. Insurance shall include a waiver of subrogation in favor of the additional insureds identified in the Contract Documents. B. All policies purchased in accordance with this Article are to contain provisions to the effect that the insurers have no rights of recovery against OPT, named insureds or additional insureds in the event of a payment for loss or damage. Design/Builder and insurers waive all rights against the Owner's Indemnities for losses and damages created by or resulting from any of the perils or causes of loss covered by these policies and any other applicable property insurance. None of these waivers extend to the rights Design/Builder has to the proceeds of insurance as trustee. C. Design/Builder is responsible for assuring that agreements with Subcontractors contain provisions that the Subcontractor waive all rights against Owner, Design/Builder, named insureds and additional insureds, and the officers, directors, members, partners, employees, agents, consultants, and subcontractors of each and any of them, for all losses and damages created by or resulting from any of the perils or causes of loss covered by builder's risk insurance and other property insurance. 6.08 Owner's Insurance for Project A. Owner is not responsible for purchasing and maintaining any insurance to protect the interest of the Design/Builder, Subcontractors, or others in the Work. The stated limits of insurance required are minimum only. Determine the limits that are adequate. These limits may be basic policy limits or any combination of basic limits and umbrella limits. In any event, Design/Builder is fully responsible for all losses arising out of, resulting from, or connected with operations under this Contract whether or not these losses are covered by insurance. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-33 Rev 5/2024 The acceptance of evidence of insurance by the OPT, named insureds, or additional insureds does not release the Design/Builder from compliance with the insurance requirements of the Contract Documents. 6.09 Acceptable Evidence of Insurance A. Provide evidence of insurance acceptable to the Owner with the executed Contract Documents. Provide the following as evidence of insurance: 1. Certificates of Insurance on an acceptable form; 2. Riders or endorsements to policies; and 3. Policy limits and deductibles. B. Provide a list of "Additional Insureds" for each policy. C. Provide evidence that waivers of subrogation are provided on all applicable policies. D. Provide evidence of requirements for 30 days' notice before cancellation or any material change in the policy's terms and conditions, limits of coverage, or change in deductible amount. 6.10 Certificate of Insurance A. Submit Certificates of Insurance meeting the following requirements: 1. Form has been filed with and approved by the Texas Department of Insurance under Texas Insurance Code §1811.101; or 2. Form is a standard form deemed approved by the Department under Texas Insurance Code §1811.101. 3. No requirements of this Contract may be interpreted as requiring the issuance of a certificate of insurance on a certificate of insurance form that has not first been filed with and approved by the Texas Department of Insurance. B. Include the name of the Project in the description of operations box on the certificate of insurance. 6.11 Insurance Policies A. If requested by the Owner, make available for viewing a copy of insurance policies, declaration pages and endorsements, and documentation of applicable self -insured retentions and deductibles. B. Design/Builder may block out (redact) any proprietary information or confidential premium pricing information contained in any policy or endorsement furnished under this Contract. 6.12 Continuing Evidence of Coverage A. Provide updated, revised, or new evidence of insurance in accordance with the Contract Documents prior to the expiration of existing policies. B. Provide evidence of continuation of insurance coverage at final payment and for the following 3 years. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-34 Rev 5/2024 6.13 Notices Regarding Insurance A. Notices regarding insurance are to be sent to the Owner at the following address: City of Corpus Christi — Engineering Attn: Contract Admin. P.O. Box 9277 Corpus Christi, TX 78469-9277 B. Submit questions regarding insurance requirements to the Facilities Contract Administrator by calling 361-826-3500. 6.14 Texas Workers' Compensation Insurance Required Notice A. Definitions: 1. Certificate of coverage ("certificate") - A copy of a certificate of insurance, a certificate of authority to self -insure issued by the commission, or a coverage agreement (TWCC- 81, TWCC-82, TWCC-83, or TWCC-84), showing statutory workers' compensation insurance coverage for the person's or entity's employees providing services on a project, for the duration of the Project. 2. Duration of the Project - includes the time from the beginning of the Work on the Project until the Design/Builder's/person's Work on the Project has been completed and accepted by the governmental entity. 3. Persons providing services on the Project ("Subcontractor" in §406.096) - includes all persons or entities performing all or part of the services the Design/Builder has undertaken to perform on the Project, regardless of whether that person contracted directly with the Design/Builder and regardless of whether that person has employees. This includes, without limitation, independent contractors, subcontractors, leasing companies, motor carriers, owner -operators, employees of any such entity, or employees of any entity which furnishes persons to provide services on the Project. "Services" include, without limitation, providing, hauling, or delivering equipment or materials, or providing labor, transportation, or other service related to a project. "Services" does not include activities unrelated to the Project, such as food/beverage vendors, office supply deliveries, and delivery of portable toilets. B. The Design/Builder shall provide coverage, based on proper reporting of classification codes and payroll amounts and filing of any coverage agreements, which meets the statutory requirements of Texas Labor Code, Section 401.011(44) for all employees of the Design/Builder providing services on the Project, for the duration of the Project. C. The Design/Builder must provide a certificate of coverage to the governmental entity prior to being awarded the Contract. D. If the coverage period shown on the Design/Builder's current certificate of coverage ends during the duration of the Project, the Design/Builder must, prior to the end of the coverage period, file a new certificate of coverage with the governmental entity showing that coverage has been extended. E. The Design/Builder shall obtain from each person providing services on a project, and provide to the governmental entity: General Conditions — Design/Build (LS) Corpus Christi Standards 007200-35 Rev 5/2024 1. A certificate of coverage, prior to that person beginning Work on the Project, so the governmental entity will have on file certificates of coverage showing coverage for all persons providing services on the Project; and 2. No later than seven days after receipt by the Design/Builder, a new certificate of coverage showing extension of coverage, if the coverage period shown on the current certificate of coverage ends during the duration of the Project. F. The Design/Builder shall retain all required certificates of coverage for the duration of the Project and for one year thereafter. G. The Design/Builder shall notify the governmental entity in writing by certified mail or personal delivery, within 10 days after the Design/Builder knew or should have known, of any change that materially affects the provision of coverage of any person providing services on the Project. H. The Design/Builder shall post on each Project Site a notice, in the text, form and manner prescribed by the Texas Workers' Compensation Commission, informing all persons providing services on the Project that they are required to be covered, and stating how a person may verify coverage and report lack of coverage. I. The Design/Builder shall contractually require each person with whom it contracts to provide services on a project, to: 1. Provide coverage, based on proper reporting of classification codes and payroll amounts and filing of any coverage agreements, which meets the statutory requirements of Texas Labor Code, Section 401.011(44) for all of its employees providing services on the Project, for the duration of the Project; 2. Provide to the Design/Builder, prior to that person beginning Work on the Project, a certificate of coverage showing that coverage is being provided for all employees of the person providing services on the Project, for the duration of the Project; 3. Provide the Design/Builder, prior to the end of the coverage period, a new certificate of coverage showing extension of coverage, if the coverage period shown on the current certificate of coverage ends during the duration of the Project; 4. Obtain from each other person with whom it contracts, and provide to the Design/Builder: a. A certificate of coverage, prior to the other person beginning Work on the Project; and b. A new certificate of coverage showing extension of coverage, prior to the end of the coverage period, if the coverage period shown on the current certificate of coverage ends during the duration of the Project; 5. Retain all required certificates of coverage on file for the duration of the Project and for one year thereafter; 6. Notify the governmental entity in writing by certified mail or personal delivery, within 10 days after the person knew or should have known, of any change that materially affects the provision of coverage of any person providing services on the Project; and General Conditions — Design/Build (LS) Corpus Christi Standards 007200-36 Rev 5/2024 7. Contractually require each person with whom it contracts, to perform as required by this section, with the certificates of coverage to be provided to the person for whom they are providing services. J. By signing this Contract or providing or causing to be provided a certificate of coverage, the Design/Builder is representing to the governmental entity that all employees of the Design/Builder who will provide services on the Project will be covered by workers' compensation coverage for the duration of the Project, that the coverage will be based on proper reporting of classification codes and payroll amounts, and that all coverage agreements will be filed with the appropriate insurance carrier or, in the case of a self - insured, with the commission's Division of Self -Insurance Regulation. Providing false or misleading information may subject the Design/Builder to administrative penalties, criminal penalties, civil penalties, or other civil actions. K. The Design/Builder's failure to comply with any of these provisions is a breach of contract by the Design/Builder which entitles the governmental entity to declare the Contract void if the Design/Builder does not remedy the breach within ten days after receipt of notice of breach from the governmental entity. ARTICLE 7 — DESIGN/BUILDER'S RESPONSIBILITIES 7.01 Supervision and Superintendence A. Supervise, inspect, and direct the performance of the Work in accordance with the Contract Documents. Design/Builder is solely responsible for the means, methods, techniques, sequences, and procedures of construction. B. Provide a competent resident superintendent acceptable to the OPT. The resident superintendent or acceptable qualified assistant is to be present at all times when Work is being done. Do not replace this resident superintendent except under extraordinary circumstances. Provide a replacement resident superintendent equally competent to the previous resident superintendent if replacement is required. Notify the Owner prior to replacing the resident superintendent and obtain Owner's consent to the change in superintendent. 7.02 Labor; Working Hours A. Provide competent, suitably qualified personnel to survey and lay out the Work and perform Work to complete the Project. Maintain good discipline and order at the Site. B. Perform Work at the Site during regular working hours except as otherwise required for the safety or protection of persons or the Work or property at the Site or adjacent to the Site and except as otherwise stated in the Contract Documents. Regular working hours are between sunrise and sundown Monday through Saturday unless other times are specifically authorized in writing by OAR. C. Do not perform Work on a Sunday or legal holiday without OAR's consent. The following legal holidays are observed by the Owner: Holiday Date Observed New Year's Day January 1 General Conditions — Design/Build (LS) Corpus Christi Standards 007200-37 Rev 5/2024 Holiday Date Observed Martin Luther King Jr Day Third Monday in January Memorial Day Last Monday in May Juneteenth June 19 Independence Day July 4 Labor Day First Monday in September Thanksgiving Day Fourth Thursday in November Friday after Thanksgiving Friday after Thanksgiving Christmas Day December 25 D. If a legal holiday falls on a Saturday, it will be observed the preceding Friday. If a legal holiday falls on a Sunday, it will be observed the following Monday. E. Pay additional cost incurred by Owner for services of the OAR or RPR to observe Work constructed outside of regular working hours. OAR will issue a Set-off in the Application for Payment for this cost per Article 17. 7.03 Services, Materials, and Equipment A. Provide services, materials, equipment, labor, transportation, construction equipment and machinery, tools, appliances, fuel, power, light, heat, telephone, water, sanitary facilities, temporary facilities, and other facilities and incidentals necessary for the performance, testing, start-up, and completion of the Work, whether or not these items are specifically called for in the Contract Documents. B. Provide new materials and equipment to be incorporated into the Work. Provide special warranties and guarantees required by the Contract Documents. Provide satisfactory evidence, including reports of required tests, as to the source, kind, and quality of materials and equipment as required by the Contract Documents or as requested by the OAR. C. Store, apply, install, connect, erect, protect, use, clean, and condition materials and equipment in accordance with instructions of the applicable Supplier, unless otherwise required by the Contract Documents. 7.04 Concerning Subcontractors, Suppliers, and Others A. Design/Builder may retain Subcontractors and Suppliers for the performance of parts of the Work. All Subcontractors and Suppliers must be acceptable to Owner. B. Design/Builder must retain specific Subcontractors, Suppliers, or other individuals or entities for the performance of designated parts of the Work if required to do so by the Contract Documents. C. Submit a list of proposed Subcontractors and Suppliers to OAR prior to entering into binding subcontracts or purchase orders. These proposed Subcontractors or Suppliers are deemed acceptable to Owner unless Owner raises a substantive, reasonable objection within 30 days after receiving this list. Under no circumstances shall any Subcontractor debarred under Chapter 41 of The Code of Ordinances, City of Corpus Christi, be deemed acceptable to Owner. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-38 Rev 5/2024 D. Owner may require the replacement of Subcontractors, Suppliers, or other individuals or entities retained by the Design/Builder. Provide an acceptable replacement for the rejected Subcontractor, Supplier, or other individual or entity. Owner also may require Design/Builder to retain specific replacements, subject to Design/Builder's reasonable objections. E. Design/Builder may be entitled to an adjustment in Contract Price or Contract Times with respect to a replacement of Subcontractors, Suppliers, or other entities required by Owner. The Design/Builder is not entitled to an adjustment in Contract Price or Contract Time with respect to replacement of any individual deemed unsuitable by the OPT. Notify OAR immediately if a replacement of Subcontractors, Suppliers, or other entity increases the Contract Price or Contract Times. Initiate a Change Proposal for the adjustment within 10 days of Owner's notice to replace a Subcontractor, Supplier, or other entity retained by Design/Builder to perform part of the Work. Do not make the replacement until the change in Contract Price or Contract Times has been accepted by the Owner if Change Proposal is to be submitted. F. Owner's initial acceptance of Subcontractors, Suppliers, or other individuals or entities, or their replacements, does not constitute a waiver of the obligation of the Design/Builder to complete the Work in accordance with the Contract Documents. G. Maintain a current and complete list of Subcontractors and Suppliers that are to perform or furnish part of the Work. H. Design/Builder is fully responsible for the acts and omissions of Subcontractors, Suppliers, and other individuals or entities performing or furnishing Work. I. Design/Builder is solely responsible for scheduling and coordinating the work of Subcontractors, Suppliers, and other individuals or entities performing or furnishing Work. J. Require Subcontractors, Suppliers, and other individuals or entities performing or furnishing Work to communicate with OPT through Design/Builder. K. Contracts between the Design/Builder and their Subcontractors or Suppliers may specifically bind the Subcontractors or Suppliers to the applicable terms and conditions of the Contract Documents. Design/Builder is responsible for meeting the requirements of the Contract Documents if they choose to not bind the Subcontractors or Suppliers to applicable terms or conditions of the Contract Documents. 1. All Subcontractors employed on this Project must be required to obtain Workers' Compensation Insurance. 2. Proof of this insurance will be required prior to the start of any Work. L. OPT may furnish information about amounts paid to Design/Builder for Work provided by Subcontractors or Suppliers to the entity providing the Work. M. Nothing in the Contract Documents: 1. Creates a contractual relationship between members of the OPT and members of the Design/Builder's Team. 2. Creates an obligation on the part of the Owner to pay or to see to the payment of money due members of the Design/Builder's Team, except as may be required by Laws and Regulations. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-39 Rev 5/2024 7.05 Patent Fees and Royalties A. Pay license fees, royalties, and costs incident to the use of inventions, designs, processes, products, or devices which are patented or copyrighted by others in the performance of the Work, or to incorporate these inventions, designs, processes, products, or devices which are patented or copyrighted by others in the Work. Design/Builder is to include the cost associated with the use of patented or copyrighted products or processes, whether specified or selected by the Design/Builder, in the Contract Price. B. Design/Builder's obligation to indemnify Owner for claims arising out of or related to infringement of patent rights and copyrights are as set forth in Paragraph 7.14. 7.06 Permits A. Obtain and pay for construction permits and licenses. OPT is to assist Design/Builder in obtaining permits and licenses when required to do so by applicable Laws and Regulations. Pay governmental charges and inspection fees necessary for the prosecution of the Work which are applicable at the time the Design/Builder's proposal is submitted or when Design/Builder negotiates the Contract Price. This Project is not exempt from City permits and fees unless expressly stated otherwise. 7.07 Taxes A. Design/Builder is responsible for all taxes and duties arising out of the Work. The Owner generally qualifies as a tax-exempt agency as defined by the statutes of the State of Texas and is usually not subject to any city or state sales or use taxes, however certain items such as rented equipment may be taxable even though Owner is a tax-exempt agency. Design/Builder is responsible for including in the Contract Price any applicable sales and use taxes and is responsible for complying with all applicable statutes and rulings of the State Comptroller. Pay sales, consumer, use, and other similar taxes required to be paid by Design/Builder in accordance with the Laws and Regulations. B. The Owner is exempt from the Federal Transportation and Excise Tax. Design/Builder must comply with all federal regulations governing the exemptions. C. Products incorporated into the Work are exempt from state sales tax according to the provisions of Subchapter H, Chapter 151, of the Texas Tax Code. D. Design/Builder may not include any amounts for sales, use, or similar taxes for which the Owner is exempt in the Contract Price or any proposed Change Order or Application for Payment. E. Obtain tax exemption certificates or other documentation necessary to establish Owner's exemption from such taxes. 7.08 Laws and Regulations A. Give required notices and comply with Laws and Regulations applicable to the performance of the Work. OPT is not responsible for monitoring Design/Builder's compliance with Laws or Regulations except where expressly required by applicable Laws and Regulations. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-40 Rev 5/2024 B. Pay costs resulting from actions taken by Design/Builder that are contrary to Laws or Regulations. Design/Builder is responsible for determining that the design aspects of the Work described in the Contract Documents is in accordance with Laws and Regulations 7.09 Safety and Protection A. Design/Builder is solely responsible for initiating, maintaining, and supervising safety precautions and programs in connection with the Work. This responsibility does not relieve Subcontractors of their responsibility for the safety of persons or property in the performance of their work, nor for compliance with applicable safety Laws and Regulations. B. Take necessary precautions for the safety of persons on the Site or who may be affected by the Work, and provide the necessary protection to prevent damage, injury, or loss to: 1. Work and materials and equipment to be incorporated in the Work, whether stored on or off Site; and 2. Other property at or adjacent to the Site, including trees, shrubs, lawns, walks, pavements, roadways, structures, other work in progress, utilities, and Underground Facilities not designated for removal, relocation, or replacement in the course of construction. C. Comply with applicable Laws and Regulations relating to the safety and protection of persons or property. Erect and maintain necessary safeguards for safety and protection. Notify Owner; the owners of adjacent property, Underground Facilities, and other utilities; and other contractors and utility owners performing work at or adjacent to the Site when prosecution of the Work may affect them. Cooperate with them in the protection, removal, relocation, and replacement of their property or work in progress. 1. Comply with requirements of Underground Facility Damage Prevention and Safety Act, Texas Utilities Code Chapter 251. 2. Comply with all applicable safety rules and regulations of the Federal Occupational Health and Safety Act of 1970 and subsequent amendments (OSHA). D. Remedy damage, injury, or loss to property referred to in Paragraph 7.09.E caused by Design/Builder's Team. Pay remediation costs unless the damage or loss is: 1. Attributable to acts or omissions of Owner; or 2. Not attributable to the actions or failure to act of the Design/Builder's Team. E. Design/Builder's duties and responsibilities for safety and protection of persons or the Work or property at or adjacent to the Site continues until Work is completed and resumes whenever Design/Builder's Team returns to the Site to fulfill warranty or correction obligations or to conduct other tasks. F. Comply with the applicable requirements of the Owner's safety program if required to do so. 7.10 Safety Representative A. Provide a qualified and experienced safety representative at the Site whose duties and responsibilities are the prevention of accidents and maintaining and supervising safety programs. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-41 Rev 5/2024 7.11 Hazard Communication Programs A. Coordinate the exchange of material safety data sheets or other hazard communication information required to be made available or exchanged between or among employers at the Site in accordance with Laws or Regulations. 7.12 Emergencies A. Act to prevent threatened damage, injury or loss in emergencies affecting the safety or protection of persons or the Work or property at or adjacent to the Site. Notify OAR immediately if Design/Builder believes that significant changes in the Work or variations from the Contract Documents have been caused or are required as a result of this need to act. A Modification is to be issued by OAR if OPT determines that the incident giving rise to the emergency action was not the responsibility of the Design/Builder and that a change in the Contract Documents is required because of the action taken by Design/Builder in response to this emergency. 7.13 Design/Builder's General Warranty and Guarantee A. Design/Builder warrants and guarantees to Owner that Work is in accordance with the Contract Documents and is not Defective. Owner is entitled to rely on Design/Builder's warranty and guarantee. Assume and bear responsibility for costs and time delays associated with variations from the requirements of the Contract Documents. B. This Design/Builder's warranty and guarantee excludes defects or damage caused by improper maintenance or operation, abuse, or modification by OPT; or normal wear and tear under normal usage. C. Design/Builder's obligation to perform and complete Work in accordance with the Contract Documents is absolute. None of the following constitute an acceptance of Defective Work or a release of Design/Builder's obligation to perform Work in accordance with the Contract Documents: 1. Observations by OPT; 2. Recommendation by OAR to pay or payment by Owner of progress or final payments; 3. The issuance of a Certificate of Substantial Completion; 4. Use or occupancy of part of the Work by Owner; 5. Review and approval of a Shop Drawing or Sample; 6. Inspections, tests, or approvals by others; or 7. Correction of Defective Work by Owner. D. The Contract Documents may require the Design/Builder to accept the assignment of a contract between the Owner and a contractor or supplier. The specific warranties, guarantees, and correction obligations contained in an assigned contract govern with respect to Design/Builder's performance obligations to Owner for the Work described in an assigned contract. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-42 Rev 5/2024 7.14 INDEMNIFICATION A. Professional Services Indemnity Design/Builder shall fully indemnify and hold harmless the Owner from and against any and all claims, damages, liabilities or costs, including reasonable attorney fees and court costs, to the extent that the damage is caused by or results from an act of negligence, intentional tort, intellectual property infringement or failure to pay a subcontractor or supplier committed by Design/Builder or its agent, or another entity over which Design/Builder exercises control while in the exercise of rights or performance of the duties under the Contract. This indemnification does not apply to any liability resulting from the negligent acts or omissions of the Owner or its employees, to the extent of such negligence. Design/Builder shall defend Owner, with counsel satisfactory to Owner, from and against any and all claims, damages, liabilities or costs, including reasonable attorney fees and court costs, if the claim is not based wholly or partly on the negligence of, fault of or breach of contract by Owner. If a claim is based wholly or partly on the negligence of, fault of or breach of contract by Owner, Design/Builder shall reimburse the Owner's reasonable attorney's fees in proportion to the Design/Builder's liability. B. Construction Services Indemnity 1. To the fullest extent permitted by law, Design/Builder shall indemnify, defend, and hold harmless the Owner from and against claims, damages, losses and expenses, including but not limited to attorney's fees or dispute resolution costs, arising out of or resulting from performance of the Work and/or failure to comply with the terms and conditions of the contract, violations of Laws or Regulations, or bodily injury, death or destruction of tangible property caused by the acts, omissions or negligence of the Design/Builder's Team, regardless of whether such claim, damage, loss or expense is alleged to be caused in part by an Owner hereunder, subject to the Owner's defenses and liability limits under the Texas Tort Claims Act. However, nothing herein shall be construed to require Design/Builder to indemnify an Owner against General Conditions — Design/Build (LS) Corpus Christi Standards 007200-43 Rev 5/2024 a claim, loss, damage or expense caused by the sole negligence of an Owner. 2. To the fullest extent permitted by law, Design/Builder shall indemnify, defend, and hold harmless the Owner from and against Indemnified Costs, arising out of or relating to: (i) the failure to control, contain, or remove a Constituent of Concern brought to the Site by Design/Builder's Team or a Hazardous Environmental Condition created by Design/Builder's Team, (ii) Design/Builder's Team's action or inaction related to damages, delays, disruptions or interference with the work of Owner's employees, other contractors, or utility owners performing other work at or adjacent to the Site, or (iii) the correction of Defective Work. Nothing in this paragraph obligates the Design/Builder to indemnify the Owner from the consequences of the Owner's sole negligence. 3. To the fullest extent permitted by law, Design/Builder shall indemnify, defend, and hold harmless the Owner from and against Indemnified Costs resulting from infringement on patent rights or copyrights by Design/Builder's Team. C. The indemnification obligations of this Paragraph 7.14 are not limited by the amount or type of damages, compensation or benefits payable by or for members of the Design/Builder's Team or other individuals or entities under workers' compensation acts, disability benefit acts, or other employee benefit acts in claims against Owner by an employee or the survivor or personal representative of employee of Design/Builder's Team. The indemnification obligations of this Paragraph 7.14 shall not be deemed to be released, waived or modified in any respect by reason of any surety or insurance provided by Design/Builder. D. Notify the other party within 10 days if Owner or Design/Builder receives notice of any claim or circumstances that could give rise to an indemnified loss. The notice must include the following: 1. A description of the indemnification event in reasonable detail; 2. The basis on which indemnification may be due; and 3. The anticipated amount of the indemnified loss. This notice does not stop or prevent Owner from later asserting a different basis for indemnification or a different amount of indemnified loss than that indicated in the initial notice. Owner does not waive any rights to indemnification except to the extent that Design/Builder is prejudiced, suffers loss, or incurs expense because of the delay if Owner does not provide this notice within the 10-day period. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-44 Rev 5/2024 E. Defense of Indemnification Claims: 1. Assume the defense of the claim with counsel chosen by the Design/Builder and pay related costs, unless Owner decides otherwise. Design/Builder's counsel must be acceptable to Owner. Control the defense and any negotiations to settle the claim. Advise Owner as to its defense of the claim within 10 days after being notified of the indemnification request. Owner may assume and control the defense if Design/Builder does not assume the defense. Pay all defense expenses of the Owner as an indemnified loss. 2. Owner may retain separate counsel to participate in, but not control, the defense and any settlement negotiations if Design/Builder defends the claim. Design/Builder may not settle the claim without the consent or agreement of Owner. Design/Builder may settle the claim with Owner's consent and agreement unless it: a. Would result in injunctive relief or other equitable remedies or otherwise require Owner to comply with restrictions or limitations that adversely affect Owner; b. Would require Owner to pay amounts that Design/Builder does not fund in full; or c. Would not result in Owner's full and complete release from all liability to the plaintiffs or claimants who are parties to or otherwise bound by the settlement. ARTICLE 8 — OTHER WORK AT THE SITE 8.01 Other Work A. Owner may arrange for other work at or adjacent to the Site which is not part of the Design/Builder's Work. This other work may be performed by Owner's employees or through other contractors. Utility owners may perform work on their utilities and facilities at or adjacent to the Site. Include costs associated with coordinating with entities performing other work or associated with connecting to this other work in the Contract Price if this other work is shown in the Contract Documents. B. OPT is to notify Design/Builder of other work prior to starting the work and provide any knowledge they have regarding the start of utility work at or adjacent to the Site to Design/Builder. C. Provide other contractors: 1. Proper and safe access to the Site; 2. Reasonable opportunity for the introduction and storage of materials and equipment; and 3. Reasonable opportunity to execute their work. D. Provide cutting, fitting, and patching of the Work required to properly connect or integrate with other work. Do not endanger the work of others by cutting, excavating, or otherwise altering the work of others without the consent of OAR and the others whose work will be affected. E. Inspect the work of others and immediately notify OAR if the proper execution of part of Design/Builder's Work depends upon work performed by others and this work has not been performed or is unsuitable for the proper execution of Design/Builder's Work. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-45 Rev 5/2024 Design/Builder's failure to notify the OAR constitutes an acceptance of this other work as acceptable for integration with Design/Builder's Work. This acceptance does not apply to latent defects or deficiencies in the work of others. F. Take adequate measures to prevent damages, delays, disruptions, or interference with the work of Owner, other contractors, or utility owners performing other work at or adjacent to the Site. 8.02 Coordination A. Owner has sole authority and responsibility for coordination of this other work unless otherwise provided in the Contract Documents. The Owner is to identify the entity with authority and responsibility for coordination of the activities of the various contractors, the limitations of their authority, and the work to be coordinated prior to the start of other work at or adjacent to the Site. 8.03 Legal Relationships A. Design/Builder may be entitled to a change in Contract Price or Contract Times if, while performing other work at or adjacent to the Site for Owner, the other contractor retained by Owner: 1. Damages the Work or property of Design/Builder's Team; 2. Delays, disrupts, or interferes with the execution of the Work; or 3. Increases the scope or cost of performing the Work through their actions or inaction. B. Notify the OAR immediately of the event leading to a potential Change Proposal so corrective action can be taken. Submit the Change Proposal within 30 days of the event if corrective action has not adequately mitigated the impact of the actions or inactions of others. C. Take prompt corrective action if Design/Builder's Team damages, delays, disrupts, or interferes with the work of Owner's employees, other contractors, or utility owners performing other work at or adjacent to the Site or agree to compensate other contractors or utility owners for correcting the damage. Promptly attempt to settle claims with other contractors or utility owners if Design/Builder damages, delays, disrupts, or interferes with the work of other contractors or utility owners performing other work at or adjacent to the Site. D. Owner may impose a set-off against payments due to Design/Builder and assign the Owner's contractual rights against Design/Builder with respect to the breach of the obligations described in this Paragraph 8.03 to other contractors if damages, delays, disruptions, or interference occur. E. Design/Builder's obligation to indemnify Owner for claims arising out of or related to damages, delays, disruptions, and interference with other work at the Site are as set forth in Paragraph 7.14. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-46 Rev 5/2024 ARTICLE 9 — OWNER'S AND OPT'S RESPONSIBILITIES 9.01 Communications to Design/Builder A. OPT issues communications to Design/Builder through OAR except as otherwise provided in the Contract Documents. 9.02 Replacement of Owner's Project Team Members A. Owner may replace members of the OPT at its discretion. 9.03 Furnish Data A. OPT is to furnish the data required of OPT under the Contract Documents. 9.04 Pay When Due A. Owner is to make payments to Design/Builder when due as described in Article 17. 9.05 Lands and Easements; Reports and Tests A. Owner's duties with respect to providing lands and easements are described in Paragraph 5.01. OPT will make copies of reports of explorations and tests of subsurface conditions and drawings of physical conditions relating to existing surface or subsurface structures at the Site available to Design/Builder in accordance with Paragraph 5.03. 9.06 Insurance A. Owner's responsibilities with respect to purchasing and maintaining insurance are described in Article 6. 9.07 Modifications A. Owner's responsibilities with respect to Modifications are described in Article 11. 9.08 Inspections, Tests, and Approvals A. OPT's responsibility with respect to certain inspections, tests, and approvals are described in Paragraph 16.02. 9.09 Limitations on OPT's Responsibilities A. The OPT does not supervise, direct, or have control or authority over, and is not responsible for Design/Builder's means, methods, techniques, sequences, or procedures of construction, or related safety precautions and programs, or for failure of Design/Builder to comply with Laws and Regulations applicable to the performance of the Work. OPT is not responsible for Design/Builder's failure to perform the Work in accordance with the Contract Documents. 9.10 Undisclosed Hazardous Environmental Condition A. OPT's responsibility for undisclosed Hazardous Environmental Conditions is described in Paragraph 5.05. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-47 Rev 5/2024 9.11 Compliance with Safety Program A. Design/Builder is to inform the OAR of its safety programs, and OPT is to comply with the specific applicable requirements of this program. 9.12 Plans and Specifications A. Owner does not warrant the plans and specifications. ARTICLE 10 — OAR'S STATUS DURING CONSTRUCTION 10.01 Owner's Representative A. OAR is Owner's representative. The duties and responsibilities and the limitations of authority of OAR as Owner's representative are described in the Contract Documents. 10.02 Visits to Site A. OAR is to observe the Work to check the quality and quantity of Work, implement Owner's quality assurance program, and administer the Contract as Owner's representative as described in the Contract Documents. OAR's visits and observations are subject to the limitations on OAR's authority and responsibility described in the Contract Documents. 10.03 Resident Project Representatives A. Resident Project Representatives assist OAR in observing the progress and quality of the Work at the Site. The limitations on Resident Project Representatives' authority and responsibility are described in the Contract Documents. 10.04 Rejecting Defective Work A. OPT has the authority to reject Work in accordance with Article 16. OAR is to issue a Defective Work Notice to Design/Builder and document when Defective Work has been corrected or accepted in accordance with Article 16. 10.05 Shop Drawings, Modifications and Payments A. OAR's authority related to Shop Drawings and Samples are described in the Contract Documents. B. OAR's authority related to Modifications is described in Article 11. C. OAR's authority related to Applications for Payment is described in Articles 15 and 17. 10.06 Decisions on Requirements of Contract Documents and Acceptability of Work A. OAR is to render decisions regarding non -technical or contractual / administrative requirements of the Contract Documents and will coordinate the response of the OPT to Design/Builder. B. OAR is to render decisions regarding the conformance of the Work to the requirements of the Contract Documents. OAR will render a decision to either correct the Defective Work or General Conditions — Design/Build (LS) Corpus Christi Standards 007200-48 Rev 5/2024 accept the Work under the provisions of Article 16 if Work does not conform to the Contract Documents. C. Design/Builder may appeal OAR's decision by submitting a Change Proposal if Design/Builder does not agree with the OAR's decision. 10.07 Limitations on OPT's Authority and Responsibilities A. OPT is not responsible for the acts or omissions of Design/Builder's Team. No actions or failure to act, or decisions made in good faith to exercise or not exercise the authority or responsibility available under the Contract Documents creates a duty in contract, tort, or otherwise of the OPT to the Design/Builder or members of the Design/Builder's Team. ARTICLE 11— AMENDING THE CONTRACT DOCUMENTS; CHANGES IN THE WORK 11.01 Amending and Supplementing the Contract Documents A. The Contract Documents may be modified by a Contract Amendment, Change Order, Work Change Directive, or Field Order. 1. Contract Amendment: Owner and Design/Builder may modify the terms and conditions of the Contract Documents using a Contract Amendment. A Contract Amendment may be used for: a. Changes that do not involve: 1) The performance or acceptability of the Work; 2) The design as described in the Drawings, Specifications, or otherwise; or 3) Other engineering, architectural or technical matters. b. Authorizing new phases of the Work and establishing the Contract Price, Contract Times, or terms and conditions of the Contract for the new phase of Work when using phased construction or purchasing Goods and Special Services to be incorporated into the Project. 2. Change Order: All changes to the Contract Documents that include a change in the Contract Price or the Contract Times for previously authorized Work, or changes to the final design must be made by a Change Order. A Change Order may also be used to establish modifications of the Contract Documents that do not affect the Contract Price or Contract Times. 3. Work Change Directive: A Work Change Directive does not change the Contract Price or the Contract Times but is evidence that the parties expect that the modifications ordered or documented by a Work Change Directive will be incorporated in a subsequently issued Change Order following negotiations on the Contract Price and Contract Times. If negotiations under the terms of the Contract Documents governing adjustments, expressly including Paragraphs 11.04 and 11.05 are unsuccessful, Design/Builder must submit a Change Proposal seeking an adjustment of the Contract Price or the Contract Times no later than 30 days after the completion of the Work set out in the Work Change Directive. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-49 Rev 5/2024 4. Field Order: OPT may require minor changes in the Work that do not change the Contract Price or Contract Times using a Field Order. OAR may issue a Field Order for non -technical, administrative issues. Submit a Change Proposal if Design/Builder believes that a Field Order justifies an adjustment in the Contract Price or Contract Times before proceeding with the Work described in the Field Order. B. Perform added or revised Work under the applicable provisions of the Contract Documents for the same or similar Work unless different Drawings, Specifications or directions are provided in the Modification. 11.02 Owner -Authorized Changes in the Work A. Owner may order additions, deletions or revisions in the Work at any time. B. These changes may be authorized by a Modification. Proceed with the Work involved or, in the case of a deletion in the Work, immediately cease construction activities with respect to the deleted Work upon receipt of the Modification. Nothing in this paragraph obligates the Design/Builder to undertake Work that Design/Builder reasonably concludes cannot be performed in a manner consistent with Design/Builder's safety obligations under the Contract Documents or Laws and Regulations. 11.03 Unauthorized Changes in the Work A. Design/Builder is not entitled to an increase in the Contract Price or an extension of the Contract Times with respect to Work performed that is not required by the Contract Documents, except in the case of an emergency as provided in Paragraph 7.12, or in the case of uncovering Work as provided in Paragraph 16.05. B. Design/Builder is responsible for costs and time delays associated with variations from the requirements of the Contract Documents unless the variations are specifically approved by Change Order. 11.04 Change of Contract Price A. The Contract Price for authorized Work can only be changed by a Change Order. Any Change Proposal for an adjustment in the Contract Price must comply with the provisions of Article 12. Any Claim for an adjustment of Contract Price must comply with the provisions of Article 13. B. An adjustment in the Contract Price is to be determined as follows: 1. By applying unit prices to the quantities of the items involved, subject to the provisions of Paragraph 15.03, where the Work involved is covered by unit prices in the Contract Documents; 2. By a mutually agreed lump sum where the Work involved is not covered by unit prices in the Contract Documents; or 3. Payment on the basis of the Cost of the Work determined as provided in Article 15 when the Work involved is not covered by unit prices in the Contract Documents, and the parties do not reach a mutual agreement to a lump sum. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-50 Rev 5/2024 11.05 Change of Contract Times A. The Contract Times for authorized Work can only be changed by Change Order. Any Change Proposal for an adjustment in the Contract Times must comply with the provisions of Article 12. Any Claim for an adjustment in the Contract Times must comply with the provisions of Article 13. B. An adjustment of the Contract Times is subject to the limitations described in Paragraph 4.04. C. Design/Builder shall be entitled to an extension of Contract Time for delays or disruptions due to unusually severe weather in excess of weather normally experienced at the job site, as determined from climatological data set forth by the National Weather Service and which affects the Project's critical path. Design/Builder shall bear the entire economic risk of all weather delays and disruptions. Design/Builder shall not be entitled to any increase in the Contract Price by reason of such delays or disruptions. Upon Design/Builder reaching Substantial Completion, Owner and Design/Builder shall look back at the entire duration of the calendar day Project and review the totality of what Design/Builder claims were unusually severe weather disruptions. If the Project was delayed or disrupted due to unusually severe weather in excess of weather normally experienced over the entire duration of the Project, Design/Builder may submit a Change Proposal for an extension of the Contract Time for delays or disruptions due to unusually severe weather in excess of weather normally experienced at the job site, as determined from climatological data set forth by the National Weather Service and which affects the Project's critical path. Any time extension granted shall be non -compensatory. 11.06 Substitutions A. The products of the listed Suppliers are to be furnished where Specifications list several manufacturers but do not specifically list "or equal" or "or approved equal" products. Use of any products other than those specifically listed is a substitution. Follow these procedures for a substitution. B. Substitutions are defined as any product that the Design/Builder proposes to provide for the Project in lieu of the specified product. Submit a Change Proposal per Article 12 along with a Shop Drawing as required by Article 25 to request approval of a substitution. C. Prove that the product is acceptable as a substitute. It is not the Owner's responsibility to prove the product is not acceptable as a substitute. 1. Indicate on a point -by -point basis for each specified feature that the product is acceptable to meet the intent of the Contract Documents. 2. Make a direct comparison with the specified Suppliers' published data sheets and available information. Provide this printed material with the documents submitted. 3. The decision of the OPT regarding the acceptability of the proposed substitute product is final. D. Provide a written certification that, in making the substitution request, the Design/Builder: 1. Has determined that the substituted product will perform in substantially the same manner and result in the same ability to meet the specified performance as the specified product. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-51 Rev 5/2024 2. Will provide the same warranties and/or bonds for the substituted product as specified or as would be provided by the manufacturer of the specified product. 3. Will assume all responsibility to coordinate any modifications that may be necessary to incorporate the substituted product into the Project and will waive all claims for additional Work which may be necessary to incorporate the substituted product into the Project which may subsequently become apparent. 4. Will maintain the same time schedule as for the specified product. E. Pay for review of substitutions in accordance with Article 25. ARTICLE 12 — CHANGE MANAGEMENT 12.01 Change Proposals Submitted by Design/Builder A. Submit a Change Proposal to the OAR to: 1. Respond to a Request for Change Proposal; 2. Request an adjustment in the Contract Price or Contract Times; 3. Appeal an initial decision by OPT concerning the requirements of the Contract Documents or relating to the acceptability of the Work under the Contract Documents; 4. Contest a set-off against payment due; or 5. Seek other relief under the Contract Documents. B. Submit each Change Proposal to OAR no later than 30 days after the event initiating the Change Proposal. 1. Assign a number to the Change Proposal when issued. 2. Include with the Change Proposal: a. A complete description of the proposed Modification if Design/Builder initiated or proposed changes to the OPT's description of the proposed Modification. b. The reason the Modification is requested, if not in response to a Request for a Change Proposal. c. A detailed breakdown of the cost of the change if the Modification requires a change in Contract Price. The itemized breakdown is to include: 1) List of materials and equipment to be installed; 2) Man hours for classification; 3) Equipment used in construction; 4) Consumable supplies, fuels, and materials; 5) Royalties and patent fees; 6) Bonds and insurance; 7) Overhead and profit; 8) Field office costs; and General Conditions — Design/Build (LS) Corpus Christi Standards 007200-52 Rev 5/2024 9) Other items of cost. d. Provide the level of detail outlined in the paragraph above for each Subcontractor or Supplier actually performing the Work if Work is to be provided by a Subcontractor or Supplier. Indicate appropriate Design/Builder mark-ups for Work provided through Subcontractors and Suppliers. Provide the level of detail outline in the paragraph above for self -performed Work. e. Submit Change Proposals that comply with Article 15 for Cost of Work. f. Provide a revised schedule. Show the effect of the change on the Project Schedule and the Contract Times. C. Submit a Change Proposal to the OAR to request a Field Order. D. A Change Proposal is required for all substitutions or deviations from the Contract Documents. E. Request changes to products in accordance with Article 25. 12.02 OPT Will Evaluate Request for Modification A. OAR is to advise OPT regarding the Change Proposal. OPT is to review each Change Proposal and Design/Builder's supporting data, and within 30 days after receipt of the documents, direct the OAR to either approve or deny the Change Proposal in whole or in part. OAR is to issue a Change Order for an approved Change Proposal. The Design/Builder may deem the Change Proposal to be denied if OAR does not take action on the Change Proposal within 30 days and start the time for appeal of the denial under Article 13. 1. Change Orders and Contract Amendments will be sent to the Design/Builder for execution with a copy to the Owner recommending approval. A Work Change Directive may be issued if Work needs to progress before the Change Order or Contract Amendment can be authorized by the Owner. 2. Work Change Directives, Change Orders, and Contract Amendments can only be approved by the Owner. a. Work performed on the Change Proposal prior to receiving a Work Change Directive or approval of the Change Order or Contract Amendment is performed at the Design/Builder's risk. b. No payment will be made for Work on Change Orders or Contract Amendments until approved by the Owner. B. The Design/Builder may be informed that the Request for a Change Proposal is not approved, and construction is to proceed in accordance with the Contract Documents. 12.03 Execution of Change Orders A. Owner and Design/Builder are to execute Change Orders covering: 1. Changes in the Contract Price or Contract Times, which are agreed to by Owner and Design/Builder, including undisputed sums or amount of time for Work actually performed in accordance with a Work Change Directive; General Conditions — Design/Build (LS) Corpus Christi Standards 007200-53 Rev 5/2024 2. Changes in the Work which are: a. Ordered by Owner pursuant to Article 11, b. Required because Defective Work was accepted under Paragraph 16.04 or Owner's correction of Defective Work under Paragraph 16.07, or c. Agreed to by the Owner and Design/Builder; and 3. Changes in the Contract Price or Contract Times, or other changes under Article 11 or Article 13. B. Acceptance of a Change Order by Design/Builder constitutes a full accord and satisfaction for any and all claims and costs of any kind, whether direct or indirect, including but not limited to impact, delay or acceleration damages arising from the subject matter of the Change Order. Each Change Order must be specific and final as to prices and extensions of time, with no reservations or other provisions allowing for future additional money or time as a result of the particular changes identified and fully compensated in the Change Order. The execution of a Change Order by Design/Builder constitutes conclusive evidence of Design/Builder's agreement to the ordered changes in the Work. This Contract, as amended, forever releases any claim against Owner for additional time or compensation for matters relating to or arising out of or resulting from the Work included within or affected by the executed Change Order. This release applies to claims related to the cumulative impact of all Change Orders and to any claim related to the effect of a change on unchanged Work. C. All Change Orders require approval by either the City Council or Owner by administrative action. The approval process requires a minimum of 45 days after submission in final form with all supporting data. Receipt of Design/Builder's submission by Owner constitutes neither acceptance nor approval of a Change Order, nor a warranty that the Change Order will be authorized by City Council or administrative action. The time required for the approval process may not be considered a delay and no extensions to the Contract Times or increase in the Contract Price will be considered or granted as a result of the process. Design/Builder may proceed with Work if a Work Change Directive is issued. D. lithe Design/Builder refuses to execute a Change Order that is required to be executed under the terms of this Paragraph 12.03, the Change Order is deemed to be in full force as if executed by Design/Builder. Design/Builder may file a Claim for payment and/or time, pursuant to Article 13. 12.04 Notice to Surety A. Notify the surety of Modifications affecting the general scope of the Work, changes in the provisions of the Contract Documents, or changes in Contract Price or Contract Times. Adjust the amount of each Bond when Modifications change the Contract Price. ARTICLE 13 — CLAIMS 13.01 Claims A. Strictly follow the Claims process described in this Article for the following disputes between Owner and Design/Builder: 1. Seeking an adjustment of Contract Price or Contract Times; General Conditions — Design/Build (LS) Corpus Christi Standards 007200-54 Rev 5/2024 2. Contesting an initial decision by OAR concerning the requirements of the Contract Documents or the acceptability of Work under the Contract Documents; 3. Appealing OAR's decision regarding a Change Proposal; 4. Seeking resolution of a contractual issue that OAR has declined to address; or 5. Seeking other relief with respect to the terms of the Contract. 13.02 Claims Process A. Claims must be initiated by written notice. Notice must conspicuously state that it is a notice of a Claim in the subject line or first sentence. Notice must also list the date of first occurrence of the claimed event. B. Notice of a Claim by Design/Builder must be in writing and delivered to the Owner and OAR within 14 days after the start of the event giving rise to the Claim. Failure by Design/Builder to submit written notice of a Claim within 14 days shall constitute a waiver of such Claim. C. Submit the complete Claim with supporting documentation to Owner no later than 90 days after the start of the event giving rise to the Claim (unless OAR allows additional time for claimant to submit additional or more accurate data in support of such Claim). The Claim must be signed and sworn to by Design/Builder, certifying that the Claim is made in good faith, that the supporting data is accurate and complete, and that to the best of Design/Builder's knowledge and belief, the relief requested accurately reflects the full compensation to which Design/Builder is entitled. Failure by Design/Builder to submit the Claim in 90 days shall constitute a waiver of such Claim. D. Any Claims by Design/Builder that are not brought within 90 days following the termination of the Contract are waived and shall be automatically deemed denied. E. Claims by Owner must be submitted by written notice to Design/Builder. F. The responsibility to substantiate a Claim rests with the entity making the Claim. Claims must contain sufficient detail to allow the other party to fully review the Claim. 1. Claims seeking an adjustment of Contract Price must include the Design/Builder's job cost report. Provide additional documentation as requested by OAR. 2. Claims seeking an adjustment of Contract Time must include a Time Impact Analysis and native schedule files in Primavera or MS Project digital format. Provide additional documentation as requested by OAR. G. OAR will review a Claim by Design/Builder within 30 days of receipt of the Claim and take one or more of the following actions: 1. Request additional supporting data; 2. Issue a recommendation; or 3. Suggest a compromise. H. If the OAR does not take any action, the Claim shall be deemed denied 30 days after receipt of the Claim. I. Following receipt of OAR's initial recommendation regarding a Claim, the Design/Builder and the Owner may seek to resolve the Claim through the exchange of information and direct General Conditions — Design/Build (LS) Corpus Christi Standards 007200-55 Rev 5/2024 negotiations. If no agreement is reached within 90 days, the Claim shall be deemed denied. The Owner and Design/Builder may extend the time for resolving the Claim by mutual agreement. Notify OAR of any actions taken on a Claim. J. If the Owner and Design/Builder reach a mutual agreement regarding a Claim, the results of the agreement or action on the Claim will be incorporated in a Change Order by the OAR to the extent they affect the Contract Documents, the Contract Price, or the Contract Times. K. If the Claim is denied in whole or in part, this action is final and binding unless the procedure described in Article 22 for final resolution of disputes is invoked by filing a notice of appeal within 30 days after this action. The Notice of Appeal must include an expert report supporting the claimant's position. L. Both parties shall continue to perform all obligations under the Agreement during the pendency of any dispute or disagreement relating to this Agreement. M. Any failure of Design/Builder to comply with any of the foregoing conditions precedent with regard to any such Claim shall constitute a waiver of any entitlement to submit or pursue such Claim. Design/Builder further agrees to waive discovery related to any events giving rise to the waived Claim in the event of litigation. N. Receipt and review of a Claim by City shall not be construed as a waiver of any defenses available to the City under the Contract Documents or at law. ARTICLE 14 — PREVAILING WAGE RATE REQUIREMENTS 14.01 Payment of Prevailing Wage Rates A. Design/Builder and any Subcontractors employed on this Project for construction shall pay not less than the rates established by the Owner as required by Texas Government Code Chapter 2258. B. Design/Builder and its Subcontractors are required to pay Davis -Bacon Wage Rates for heavy construction in Nueces County, Texas. C. Design/Builder and its Subcontractors are required to pay laborers and mechanics an overtime rate of not less than one and one-half times the basic rate for all hours worked in excess of forty hours in a given workweek. 14.02 Records A. In accordance with Tex. Gov't Code §2258.024, the Design/Builder and its Subcontractors, if any, shall keep a record showing: 1. The name and occupation of each worker employed by the Design/Builder or Subcontractor in the construction of the Work; and 2. The actual per diem wages paid to each worker. B. The record shall be open at all reasonable hours to inspection by the officers and agents of the Owner. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-56 Rev 5/2024 14.03 Liability; Penalty; Criminal Offense A. Tex. Gov't Code §2258.003 — Liability: An officer, agent, or employee of the Owner is not liable in a civil action for any act or omission implementing or enforcing Chapter 2258 unless the action was made in bad faith. B. Tex. Gov't Code §2258.023(b) — Penalty: Any Design/Builder or Subcontractor who violates the requirements of Chapter 2258, shall pay to the Owner, on whose behalf the Contract is made, $60 for each worker employed on each calendar day or part of the day that the worker is paid less than the wage rates stipulated in the Contract. C. Tex. Gov't Code §2258.058 — Criminal Offense: 1. An officer, agent, or representative of the Owner commits an offense if the person willfully violates or does not comply with a provision of Chapter 2258. 2. Any Design/Builder or Subcontractor, or an agent or representative of the Design/Builder or Subcontractor, commits an offense if the person violates Tex. Gov't Code §2258.024. 3. An offense is punishable by: a. A fine not to exceed $500; b. Confinement in jail for a term not to exceed 6 months; or c. Both a fine and confinement. 14.04 Prevailing Wage Rates A. The minimum rates for various labor classifications as established by the Owner are shown below: Wage Determination Construction Type Project Type (WD) No TX21 Heavy Heavy Construction Projects (including Sewer and Water Line Construction and Drainage Projects) TX29 Highway Highway Construction Projects (excluding tunnels, building structures in rest area projects & railroad construction; bascule, suspension & spandrel arch bridges designed for commercial navigation, bridges involving marine construction; and other major bridges). TX33 Heavy Pipeline - On -Shore Pipeline Construction TX34 Heavy Pipeline - Off -Shore Construction TX288 Building Building Construction Projects (does not include single family homes or apartments up to and including 4 stories) General Conditions — Design/Build (LS) Corpus Christi Standards 007200-57 Rev 5/2024 TX51 Heavy Dredging projects along the Texas gulf coast area including all public channels, harbors, rivers, tributaries and the Gulf Intracoastal Waterways. TX55 Heavy Tunnel Construction Projects (Bored, 48" In Diameter Or More) ARTICLE 15 — COST OF THE WORK; ALLOWANCES; UNIT PRICE WORK 15.01 Cost of the Work A. The Cost of the Work is the sum of costs described in this Paragraph 15.01, except those excluded in Paragraph 15.01.D, necessary for the proper performance of the Work. The provisions of this Paragraph 15.01 are used for two distinct purposes: 1. To determine Cost of the Work when Cost of the Work is a component of the Contract Price under cost-plus, time -and -materials, or other cost -based terms; or 2. To determine the value of a Change Order, Change Proposal, Claim, set-off, or other adjustment in Contract Price. B. Design/Builder is entitled only to those additional or incremental costs required because of the change in the Work or because of the event giving rise to the adjustment when the value of the adjustment is determined on the basis of the Cost of the Work. C. Costs included in the Cost of the Work may not exceed the prevailing costs in the proximate area of the Site for similar work unless agreed to by the Owner. Cost of the Work includes only the following items: 1. Payroll costs for Design/Builder's employees performing the Work, including one foreman per crew, and other required and agreed upon personnel for the time they are employed on the Work. Employees are to be paid according to wage rates for job classifications as agreed to by Owner. Where the Cost of the Work is being used under provisions of Paragraph 15.01.A.2, rates paid for this Work are to be the same as paid for Contract Work as established by certified payroll. Payroll costs may include: a. Actual costs paid for salaries and wages; b. Actual cost paid for fringe benefits, which may include: 1) Social security contributions, 2) Unemployment, 3) Excise and payroll taxes, 4) Workers' compensation, 5) Health and retirement benefits, 6) Bonuses, and 7) Paid time off for sick leave, vacations, and holidays; and c. Actual cost of additional compensation paid for performing Work outside of regular working hours, on Sunday or legal holidays, to the extent authorized by Owner. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-58 Rev 5/2024 2. Cost of materials and equipment furnished and incorporated in the Work, including transportation and storage costs and required Suppliers' field services. Design/Builder may retain cash discounts unless Owner provided funds to the Design/Builder for early payment of these materials and equipment. Cash discounts are to be credited to Owner if the Owner provides funds for early payment. Make provisions for trade discounts, rebates, refunds, and returns from sale of surplus materials and equipment and reduce the Cost of the Work by these amounts. 3. Payments made by Design/Builder to Subcontractors for Work performed by Subcontractors. Obtain competitive bids from Subcontractors acceptable to Owner unless Owner agrees to use Subcontractors proposed by the Design/Builder. Bids are to be opened in the presence of the OAR and other designated members for the OPT. Provide copies of bids to the OAR to use in determining, with the OPT, which bids are acceptable. The Subcontractor's Cost of the Work and fee are determined in the same manner as Design/Builder's Cost of the Work and fee as provided in this Paragraph 15.01 if the subcontract provides that the Subcontractor is to be paid on the basis of Cost of the Work plus a fee. 4. Supplemental costs including the following: a. The proportion of necessary transportation, travel, and subsistence expenses of Design/Builder's employees incurred in discharge of duties connected with the Work; b. Costs of materials, supplies, equipment, machinery, appliances, office, and temporary facilities at the Site including transportation and maintenance costs; c. Costs of hand tools not owned by the workers consumed in the performance of the Work. Costs of hand tools not owned by the workers which are used but not consumed in the performance of the Work and which remain the property of Design/Builder, less their market value when Work is completed; d. For Design/Builder- and Subcontractor -owned machinery, trucks, power tools or other equipment, use the FHWA rental rates found in the Rental Rate Blue Book ("Blue Book") multiplied by the regional adjustment factor and the rate adjustment factor to establish hourly rates. Use the rates in effect for each section of the Blue Book at the time of use. Payment will be made for the actual hours used in the Work. 1) Standby costs will be paid at 50% of the FHWA rental rates found in the Blue Book if Design/Builder is directed by Owner in writing to standby. Standby costs will not be allowed during periods when the equipment would otherwise have been idle. For a six -day work week, no more than eight hours per a 24-hour day, no more than 48 hours per week and no more than 208 hours per month shall be paid of standby time. Operating costs shall not be charged by Design/Builder. e. Rental of construction equipment, including the costs of transporting, loading, unloading, assembling, dismantling, and removing construction equipment, whether rented from Design/Builder or others, in accordance with rental agreements approved by Owner. Costs for rental of equipment will not be paid when the equipment is no longer necessary for the Work. Justify idle time for General Conditions — Design/Build (LS) Corpus Christi Standards 007200-59 Rev 5/2024 equipment by demonstrating that it was necessary to keep equipment on Site for related future Work; f. Applicable sales, consumer, use, and other similar taxes related to the Work for which the Owner is not exempt, and which Design/Builder pays consistent with Laws and Regulations; g. Deposits lost for causes other than negligence of Design/Builder's Team; h. Royalty payments and fees for permits and licenses; i. Cost of additional utilities, fuel, and sanitary facilities at the Site; j. Minor expense items directly required by the Work; and k. Premiums for Bonds and insurance required by the Contract Documents. D. The Cost of the Work does not include the following items: 1. Payroll costs and other compensation of Design/Builder's officers, executives, principals of partnerships and sole proprietorships, general managers, safety managers, superintendents, engineers, architects, estimators, attorneys, auditors, accountants, purchasing and contracting agents, expediters, clerks, and other personnel employed by Design/Builder, whether at the Site or in Design/Builder's principal or branch office, for general administration of the Work and not specifically included in the agreed upon schedule of job classifications referred to in Paragraph 15.01.C.1 or specifically covered by Paragraph 15.01.C.4. These administrative costs are covered by the Design/Builder's fee. 2. Office expenses other than Design/Builder's office at the Site. 3. Any part of Design/Builder's capital expenses, including interest on Design/Builder's capital employed for the Work and charges against Design/Builder for delinquent payments. 4. Costs due to the actions of Design/Builder's Team for the correction of Defective Work, disposal of materials or equipment that do not comply with Specifications, and correcting damage to property. 5. Losses, damages, and related expenses caused by damage to the Work or sustained by Design/Builder in connection with the performance of the Work. Design/Builder is entitled to recover costs if covered by insurance provided in accordance with Article 6. Such losses may include settlements made with the approval of Owner. Do not include these losses, damages, and expenses in the Cost of the Work when determining Design/Builder's fee. 6. Any Indemnified Cost paid with regard to Design/Builder's indemnification of Owner. 7. Other overhead or general expense costs and the costs of items not described in Paragraphs 15.01.C. E. The Design/Builder's fee for profit and overhead is determined as follows: 1. In accordance with the Agreement when the Work is performed on a cost-plus basis; 2. A mutually acceptable fixed fee; or General Conditions — Design/Build (LS) Corpus Christi Standards 007200-60 Rev 5/2024 3. A fee based on the following percentages of the various portions of the Cost of the Work: a. The Design/Builder's fee is 15 percent for costs incurred under Paragraphs 15.01.C.1, 15.01.C.2 and 15.01.C.4; b. The Design/Builder's fee is 5 percent for costs incurred under Paragraph 15.01.C.3; c. Fees are to be determined as follows where one or more tiers of subcontracts are used: 1) The Subcontractor's fee is 15 percent for costs incurred under Paragraphs 15.01.C.1 and 15.01.C.2 for the Subcontractor that actually performs the Work at whatever tier; 2) The Subcontractor's fee is 5 percent for costs incurred under Paragraph 15.01.C.4 for the Subcontractor that actually performs the Work at whatever tier; and 3) The Design/Builder and Subcontractors of a tier higher than that of the Subcontractor that actually performs the Work are to be allowed a fee of 5 percent of the fee plus underlying costs incurred by the next lower tier Subcontractor. d. No fee is payable on the basis of costs itemized under Paragraph 15.01.D; e. Five percent of the net decrease in the cost is to be deducted for changes which result in a net decrease in Contract Price; and 4. The adjustment in Design/Builder's fee is based on the net change in accordance with Paragraphs 15.05.B.1 through 15.05.B.5, inclusive when both additions and credits are involved in any one change. F. Establish and maintain records in accordance with generally accepted accounting practices and submit these records, including an itemized cost breakdown together with supporting data, in a form and at intervals acceptable to OAR whenever the Cost of the Work is to be determined pursuant to this Paragraph 15.01. G. Use the Rental Rate Blue Book to calculate cost of construction equipment. 15.02 Allowances A. Include allowances specified in the Contract Documents in the Contract Price and provide Work covered by the allowance as authorized by the Owner through the OAR. B. Design/Builder agrees that: 1. The cash allowance is used to compensate the Design/Builder for the cost of furnishing materials and equipment for the Work covered by the allowance item in the Contract Documents. Cost may include applicable taxes. Make provisions for trade discounts, rebates, and refunds and reduce the allowance costs by these amounts. 2. Design/Builder's costs for unloading and handling on the Site, labor, installation, overhead, profit, and other expenses contemplated for the cash allowances have been included in the Contract Price and not in the allowances; and General Conditions — Design/Build (LS) Corpus Christi Standards 007200-61 Rev 5/2024 3. Costs for cash allowances and installation costs as described in Paragraphs 15.02.B.1 and 15.02.B.2 above are included in the Contract Price. C. OAR will issue a Change Order to adjust the Contract Price by the difference between the allowance amount and the actual amount paid by Design/Builder for Work covered by the allowance. The Change Order will be issued at the time costs are incurred by Design/Builder for Work covered by the allowance and this Work is included on the Application for Payment. 15.03 Unit Price Work A. The initial Contract Price for Unit Price Work is equal to the sum of the unit price line items in the Agreement. Each unit price line item amount is equal to the product of the unit price for each line item times the estimated quantity of each item as indicated in the Contract. B. The estimated quantities of items of Unit Price Work are not guaranteed. Payments to Design/Builder for Unit Price Work are to be based on actual quantities measured for Work in place. C. Each unit price is deemed to include an amount considered by Design/Builder to be adequate to cover Design/Builder's overhead and profit for each separately identified item. D. OAR is to determine the actual quantities and classifications of Unit Price Work performed by Design/Builder to be incorporated into each Application for Payment. OAR's decision on actual quantities is final and binding, subject to the provisions of Paragraph 15.03.E. E. Design/Builder may submit a Change Proposal, or Owner may file a Claim, seeking an adjustment in the Contract Price within 30 days of OAR's decision under Paragraph 15.03.D, if: 1. The total cost of a particular item of Unit Price Work amounts to 20 percent or more of the total Contract Price and the variation in the quantity of that particular item of Unit Price Work performed by the Design/Builder differs by more than 20 percent from the estimated quantity of an item indicated in the Contract; 2. There is no corresponding adjustment with respect to other items of Work; and 3. Design/Builder believes it has incurred additional expense as a result of this condition or Owner believes that the quantity variation entitles Owner to an adjustment in the Contract Price. 15.04 Contingencies A. Contingency funds may be included in the Contract Price to pay for Work not defined specifically by the Contract Documents that is essential to the completion of the Project. Contingency funds will be as described in the Contract. B. The contingency funds may be used for costs incurred by the Design/Builder provided these costs are approved by the Owner. Costs are to be determined and documented in accordance with Paragraph 15.01. The contingency funds are not to be used for the following items: 1. Cost overruns due to changes in material costs after the Contract Price is established, unless specific price escalation provisions are made in the Contract. 2. Rework required to correct Defective Work. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-62 Rev 5/2024 3. Inefficiencies in completing the Work due to the Design/Builder's selected means, methods, sequences, or procedures of construction. 4. Work Design/Builder failed to include in the Contract Price. 5. Changes required by changes in Laws and Regulations enacted after the Contract Price is established. 6. Any Work that does not constitute a change in Scope in the Work included in the Contract Price. C. OAR is to issue a Change Order for approved expenditures from contingency funds. When the Change Order is issued, the costs are to be added to the Application for Payment. Design/Builder is to maintain a tabulation showing the contingency amount, adjustments to the contingency amount, and amounts remaining as the Project progresses. D. Any contingency amounts that are not included in a Change Order are retained by the Owner. A Change Order will be issued to deduct unused contingency amounts from the Contract Price prior to final payment. ARTICLE 16 — TESTS AND INSPECTIONS; CORRECTION, REMOVAL, OR ACCEPTANCE OF DEFECTIVE WORK 16.01 Access to Work A. Provide safe access to the Site and the Work for the observation, inspection, and testing of the Work in progress. Design/Builder can require compliance with Design/Builder's safety procedures and programs as part of providing safe access. 16.02 Tests, Inspections and Approvals A. OPT may retain and pay for the services of an independent inspector, testing laboratory, or other qualified individual or entity to perform inspections. Notify OAR when the Work is ready for required inspections and tests. Provide adequate notice to allow for coordination with entities providing inspection or testing as determined by the OAR. Cooperate with inspection and testing personnel and assist with providing access for required inspections, tests, and handling test specimens or Samples. B. Arrange for and facilitate inspections, tests, and approvals required by Laws or Regulations of governmental entities having jurisdiction that require Work to be inspected, tested, or approved by an employee or other representative of that entity. Pay associated costs and furnish OAR with the required certificates of inspection or approval. C. Arrange, obtain, and pay for inspections and tests required: 1. By the Contract Documents, unless the Contract Documents expressly allocate responsibility for a specific inspection or test to OPT; 2. To attain OPT's acceptance of materials or equipment to be incorporated in the Work; 3. By manufacturers of equipment furnished under the Contract Documents; 4. For testing, adjusting, and balancing of mechanical, electrical, and other equipment to be incorporated into the Work; General Conditions — Design/Build (LS) Corpus Christi Standards 007200-63 Rev 5/2024 5. For acceptance of materials, mix designs, or equipment submitted for approval prior to Design/Builder's purchase thereof for incorporation in the Work; 6. For re -inspecting or retesting Defective Work, including any associated costs incurred by the testing laboratory for cancelled tests or standby time; and 7. For retesting due to failed tests. D. Provide independent inspectors, testing laboratories, or other qualified individuals or entities acceptable to OPT to provide these inspections and tests. 16.03 Defective Work A. It is Design/Builder's obligation to ensure that the Work is not Defective. B. OPT has the authority to determine whether Work is Defective and to reject Defective Work. C. OAR is to notify Design/Builder of Defective Work of which OPT has actual knowledge. D. Promptly correct Defective Work. E. Take no action that would void or otherwise impair Owner's special warranties or guarantees when correcting Defective Work. F. Pay claims, costs, losses, and damages arising out of or relating to Defective Work, including: 1. Costs for correction, removal, and replacement of Defective Work; 2. Cost of the inspection and testing related to correction of Defective Work; 3. Fines levied against Owner by governmental authorities because of Defective Work; and 4. Costs of repair or replacement of work of others resulting from Defective Work. 16.04 Acceptance of Defective Work A. Owner may elect to accept Defective Work instead of requiring correction or removal and replacement of Defective Work provided: 1. This acceptance occurs prior to final payment; 2. Design/Builder confirms that the Defective Work is in general accordance with the design intent and applicable engineering or architectural principles; and 3. Design/Builder confirms that acceptance of the Defective Work does not endanger public health or safety. B. Owner may impose a reasonable set-off against payments due under Article 17 for costs associated with OPT's evaluation of Defective Work to determine if it can be accepted and to determine the diminished value of the Work. Owner may impose a reasonable set-off against payments due under Article 17 if the parties are unable to agree as to the decrease in the Contract Price to compensate Owner for the diminished value of Defective Work accepted. OAR is to issue a Modification for acceptance of the Defective Work prior to final payment. Pay an appropriate amount to Owner if the acceptance of Defective Work occurs after final payment. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-64 Rev 5/2024 16.05 Uncovering Work A. OPT has the authority to require inspection or testing of the Work, whether or not the Work is fabricated, installed or completed. B. Work that is covered prior to approval of the OAR must be uncovered for OPT's observation if requested by OAR. Pay for uncovering Work and its subsequent restoration unless Design/Builder has given OAR timely notice of Design/Builder's intention to cover the Work, and OAR fails to act with reasonable promptness in response to this notice. C. Provide necessary labor, material, and equipment and uncover, expose, or otherwise make available the portion of the Work suspected of being Defective for observation, inspection, or testing if OPT considers it necessary or advisable that covered Work be observed by OPT or inspected or tested by others as directed by the OAR. 1. Pay for claims, costs, losses, and damages associated with uncovering, exposing, observing, inspecting, and testing if it is found that the uncovered Work is Defective. Pay costs for correction of Defective Work. Pay for reconstruction, repair, or replacement of work of others resulting from the Defective Work if it is found that the uncovered Work is Defective. 16.06 Owner May Stop the Work A. Owner may order Design/Builder to stop the Work if: 1. The Work is Defective; 2. Design/Builder fails to supply sufficient skilled workers or suitable materials or equipment; or 3. Design/Builder performs Work that may fail to conform to the Contract Documents when completed. This stop work order is to remain in effect until the reason for the stop work order has been eliminated. Owner's right to stop the Work does not create a duty to exercise this right for the benefit of Design/Builder's Team or surety. 16.07 Owner May Correct Defective Work A. Owner may remedy deficiencies in the Work after 7 days' notice to Design/Builder if: 1. Design/Builder fails to correct Defective Work, or to remove and replace rejected Work as required by OPT; 2. Design/Builder fails to perform the Work in accordance with the Contract Documents; or 3. Design/Builder fails to comply with other provisions of the Contract Documents. B. Owner may: 1. Exclude Design/Builder from the Site; 2. Take possession of the Work and suspend Design/Builder's services related to the Work; and 3. Incorporate stored materials and equipment in the Work. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-65 Rev 5/2024 C. Allow OPT access to the Site and off Site storage areas to enable Owner to exercise the rights and remedies under this Paragraph 16.07. D. All claims, costs, losses, and damages incurred or sustained by Owner in exercising the rights and remedies under this Paragraph 16.07 are to be charged against Design/Builder as a set- off against payments due under Article 17. These claims, costs, losses, and damages include costs of repair and the cost of replacement of work of others destroyed or damaged by correction, removal, or replacement of Design/Builder's Defective Work. E. Design/Builder is not allowed an extension of the Contract Times because of delays in the performance of the Work attributable to the exercise of the Owner's rights and remedies under this Paragraph 16.07. ARTICLE 17 — PAYMENTS TO DESIGN/BUILDER; SET -OFFS; COMPLETION; CORRECTION PERIOD 17.01 Progress Payments A. Progress payment requests are to be submitted to the OAR on the Application for Payment form provided by the OAR following procedures in this Article 17. 1. Progress payments for lump sum Work are to be paid on the basis of the earned value to date at the amounts shown in the Schedule of Values submitted as required by Paragraph 17.03. Final payment will be for the total lump sum amount. 2. Progress payments for Unit Price Work are based on the number of units completed as determined under the provisions of Paragraph 15.03. 3. Progress payments for Work to be paid on the basis of the Cost of the Work per Paragraphs 15.01, 15.02 and 15.04 are to be paid for Work completed by Design/Builder during the pay period. B. Reduction in Payment by Owner: 1. Owner is entitled to impose a set-off against payment based on the following: a. Claims made against Owner or costs, losses, or damages incurred by Owner related to: 1) Design/Builder's conduct in the performance of the Work, including, but not limited to, workplace injuries, non-compliance with Laws and Regulations, or patent infringement; or 2) Design/Builder's failure to take reasonable and customary measures to avoid damage, delay, disruption, and interference with other work at or adjacent to the Site, including but not limited to, workplace injuries, property damage, and non-compliance with Laws and Regulations. b. Owner has been required to remove or remediate a Hazardous Environmental Condition for which Design/Builder is responsible; c. Work is Defective, or completed Work has been damaged by Design/Builder's Team, requiring correction or replacement; d. Owner has been required to correct Defective Work or complete Work in accordance with Paragraph 16.07; General Conditions — Design/Build (LS) Corpus Christi Standards 007200-66 Rev 5/2024 e. The Contract Price has been reduced by Change Orders; f. Events have occurred that would constitute a default by Design/Builder justifying a termination for cause; Liquidated damages have accrued as a result of Design/Builder's failure to achieve Milestones, Substantial Completion, or completion of the Work; h. Liens have been filed in connection with the Work, except where Design/Builder has delivered a specific Bond satisfactory to Owner to secure the satisfaction and discharge of these Liens; g• i. Failure to submit up-to-date record documents as required by the Contract Documents; j. Failure to submit monthly Progress Schedule updates or revised schedules as requested by the OAR; k. Failure to provide Project photographs required by the Contract Documents; I. Failure to provide Certified Payroll required by the Contract Documents; m. Compensation for OPT for overtime charges of OAR or RPR, third review of documents, review of substitutions, re -inspection fees, inspections or designs related to correction of Defective Work, or other services identified as requiring payment by the Design/Builder; n. Costs for tests performed by the Owner to verify that Work previously tested and found to be Defective has been corrected; o. OPT has actual knowledge of the occurrence of events that would constitute a default by Design/Builder and therefore justify termination for cause under the Contract Documents with associated cost impacts; Other items entitling Owner to a set-off against the amount recommended; or Payment would result in an over -payment of the Contract Price. p• q• 2. Compensation for services of OPT staff is to be at the rates established by negotiations between OPT and Design/Builder. 3. OAR is to notify Design/Builder stating the amount and the reasons for an imposed set- off. The Owner is to pay the Design/Builder amounts remaining after deduction of the set-off. Owner is to pay the set-off amount agreed to by Owner and Design/Builder if Design/Builder remedies the reasons for the set-off. Design/Builder may submit a Change Proposal contesting the set-off. C. Delayed Payments: 1. No money shall be paid by Owner upon any claim, debt, demand, or account whatsoever, to any person, firm, or corporation who is in arrears to Owner for taxes; and Owner shall be entitled to counterclaim and automatically offset against any such debt, claim, demand, or account in the amount of taxes so in arrears and no assignment or transfer of such debt, claim, demand, or account after said taxes are due, shall affect the right of Owner to offset said taxes, and associated penalties and interest if applicable, against the same. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-67 Rev 5/2024 2. No payment will be made for Work authorized by a Work Change Directive until the Work Change Directive is incorporated into a Change Order. Payment can be included in an Application for payment when the Change Order is approved. D. The Owner is to pay the amount of payment recommended by the OAR within 30 days after receipt of the Application for Payment and accompanying documentation from the OAR. 17.02 Application for Payment A. Submit Applications for Payment for completed Work and for materials and equipment in accordance with the Design/Build Agreement and this Article 17. The Contract Price is to include costs for: 1. Providing the Work in accordance with the Contract Documents; 2. Design Services, including preliminary services, subsurface utility exploration and coordination of utility relocation, design submittals and approvals; 3. Installing Owner furnished equipment and materials; 4. Providing Work for Alternates and Allowances; 5. Commissioning, start-up, training and initial maintenance and operation; 6. Acceptance testing in manufacturer's facilities or on Site; 7. All home office overhead costs and expenses, including profit made directly or indirectly for the Project; 8. Project management, Contract administration, field office, and field operations staff, including supervision, clerical support, and technology system support; 9. Professional services including design fees, legal fees, and other professional services; 10. Bonds and insurance; 11. Permits, licenses, patent fees, and royalties; 12. Taxes; 13. Providing all documents and Samples required by the Contract Documents; 14. Facilities and equipment at the Site including: a. Field offices, office furnishings, and all related office supplies, software, and equipment, b. Storage facilities for Design/Builder's use, storage facilities for stored materials and equipment, including spare parts storage, c. Shops, physical plant, construction equipment, small tools, vehicles, technology and telecommunications equipment, d. Safety equipment and facilities to provide safe access and working conditions for workers and for others working at the Site, e. Temporary facilities for power and communications, f. Potable water and sanitation facilities, and General Conditions — Design/Build (LS) Corpus Christi Standards 007200-68 Rev 5/2024 g. Mobilization and demobilization for all of these facilities and equipment; 15. Products, materials, and equipment stored at the Site or other suitable location; 16. Products, materials, and equipment permanently incorporated into the Project; 17. Temporary facilities for managing water, including facilities for pumping, storage, and treatment as required for construction and protection of the environment; 18. Temporary facilities for managing environment conditions and Constituents of Concern; 19. Temporary facilities such as sheeting, shoring, bracing, formwork, embankments, storage facilities, working areas, and other facilities required for construction of the Project; 20. Temporary and permanent facilities for protection of all overhead, surface, or underground structures or features; 21. Temporary and permanent facilities for removal, relocation, or replacement of any overhead, surface, or underground structures or features; 22. Products, materials, and equipment consumed during the construction of the Project; 23. Design/Builder labor and supervision to complete the Project, including that provided through Subcontractors or Suppliers; 24. Correcting Defective Work during the Contract Times, during the Correction Period, or as required to meet any warranty provision of the Contract Documents; 25. Risk associated with weather and environmental conditions, start-up, and initial operation of facilities including equipment, processes, and systems; 26. Design/Builder's safety programs, including management, administration, and training; 27. Maintenance of facilities, including equipment, processes, and systems until operation is transferred to Owner; 28. Providing warranties, extended or special warranties, or extended service agreements; 29. Cleanup and disposal of any and all surplus materials; and 30. Demobilization of all physical, temporary facilities not incorporated into the Project. B. Include the cost not specifically set forth as an individual payment item but required to provide a complete and functional system in the Contract Price. C. Provide written approval of the surety company providing Bonds for the Schedule of Values, Application for Payment form, and method of payment prior to submitting the first Application for Payment. Payment will not be made without this approval. D. OAR may withhold processing Applications for Payment if any of the following processes or documentation are not up to date: 1. Record Documents per Article 20. 2. Progress Schedule per Article 27. 3. Project photographs per Article 28. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-69 Rev 5/2024 4. Documentation required to comply with Owner's Minority / MBE / DBE Participation Policy. 5. Documentation required to substantiate any approved Project deviation, including overruns of the estimated quantity. 6. Documentation required by funding agency, if applicable. 17.03 Schedule of Values A. Submit a detailed Schedule of Values for the Work at least 10 days prior to submitting the first Application for Payment. Update as needed as the Work progresses from design to construction. B. Submit the Schedule of Values in the form attached to the Application for Payment - Tabulation of Earned Value of Original Contract Performed. C. Do not submit an Application for Payment until the Schedule of Values has been approved by the OAR. D. If unit prices are included in the Contract, use each unit price line item in the Contract as a unit price line item in the Schedule of Values. E. Divide lump sum line items, including Subcontractor and Supplier amounts in the Schedule of Values into smaller components to allow more accurate determination of the earned value for each item. 1. Provide adequate detail to allow a more accurate determination of the earned value expressed as a percentage of Work completed for each item. 2. Line items may not exceed $50,000.00, unless they are for products, materials or equipment permanently incorporated into the Project that cannot be subdivided into units or subassemblies. 3. Lump sum items may be divided into an estimated number of units to determine earned value. a. The estimated number of units times the cost per unit must equal the lump sum amount for that line item. b. Design/Builder will receive payment for the lump sum for the line item, regardless of the number of units installed, unless an adjustment is made by Change Order. 4. Include Design/Builder's overhead and profit in each line item in proportion to the value of the line item to the Contract Price. 5. Include the cost not specifically set forth as an individual payment item but required to provide a complete and functional system in the Contract Price for each item. 6. These line items may be used to establish the value of Work to be added or deleted from the Project. 7. The sum of all values listed in the schedule must equal the total Contract Price. F. Subdivide each line item in the Schedule of Values into two payment components. The first component is the direct cost for products, materials, and equipment permanently incorporated into the Project. The second component is all other costs associated with the General Conditions — Design/Build (LS) Corpus Christi Standards 007200-70 Rev 5/2024 item in the Contract. The sum of the two components must equal the value of the line item in the Schedule of Values. G. Where a percentage of the line value is allowed for a specified stage of completion, show the value for each stage of completion as a component of that line item cost. 17.04 Schedule of Anticipated Payments and Earned Value A. Submit a schedule of the anticipated Application for Payments showing the application numbers, submission dates, and the anticipated amount to be requested. Incorporate retainage into the development of this schedule of anticipated payments. B. Submit a tabulation of the anticipated Total Earned Value of Fees, Work, and Materials to create a graphic (curve) representation of the anticipated progress on the Project each month. Adjust this table and curve to incorporate Modifications. Use this curve to compare actual progress on the Project each month by comparing the anticipated cumulative Total Earned Value of Fees, Work, and Materials to the actual Total Earned Value of Fees, Work, and Materials each month. Use the comparison of values to determine performance on budget and schedule. C. Update the Schedule of Payments as necessary to provide a reasonably accurate indication of the funds required to make payments each month to the Design/Builder for Work performed. 17.05 Basis for Payments A. Lump Sum Contracts: 1. Payment will be made for the earned value of Work completed during the payment period expressed as a percentage of Work completed for each line item during the payment period per the Contract Documents. 2. Payment amount is the value of Work completed per the Contract Documents multiplied by the percentage of Work completed. 3. Payment for lump sum items divided into an estimated number of units to determine earned value per Paragraph 17.03 will be made for the measured number of units. 4. Payment for stored materials and equipment will be made per Paragraph 17.06. B. Unit Price Contracts: 1. Payment will be made for the actual quantity of Work completed during the payment period and for materials and equipment stored during the payment period per the Contract Documents. a. Payment amount is the Work quantity measured per the Contract Documents multiplied by the unit prices for that line item in the Contract. b. Payment for stored materials and equipment will be made per Paragraph 17.06. 2. Measure the Work described in the Contract for payment. Payment will be made only for the actual measured and/or computed length, area, solid contents, number, and weight, unless other provisions are made in the Contract Documents. Payment on a unit price basis will not be made for Work outside finished dimensions shown in the General Conditions — Design/Build (LS) Corpus Christi Standards 007200-71 Rev 5/2024 Contract Documents. Include cost for waste, overages, and tolerances in the unit price for that line item. 17.06 Payment for Stored Materials and Equipment A. Store materials and equipment properly at the Site. 1. Payment will be made for the invoice amount less the specified retainage. 2. Payment for materials and equipment shown in the Application for Payment and attachments will be made for the invoice amount, up to the value shown in the Schedule of Values for that line item. Costs for material and equipment in excess of the value shown in the Schedule of Values may not be added to other line items. 3. Payment will be made in full for the value shown in the line item for products and materials if invoices for materials and equipment are less than the amount shown in the line item and it can be demonstrated that no additional materials or equipment are required to complete Work described in that item. 4. Provide invoices at the time materials are included on the Application for Payment and attachments. Include invoice numbers so that a comparison can be made between invoices and amounts included on the Application for Payment and attachments. B. Provide a bill of sale, invoice, or other documentation warranting that Owner has received the materials and equipment free and clear of Liens. Provide documentation of payment for materials and equipment with the next Application for Payment. Adjust payment to the amount actually paid if this differs from the invoice amount. Remove items from the tabulation of materials and equipment if this documentation is not provided. Payment will not be made for material and equipment without documentation of payment. C. Design/Builders can be paid for non-perishable materials on hand stored at the site, provided that invoices are furnished to the City for verification of the material value, and that Design/Builder provides documents, satisfactory to the City, that show that the material supplier has been paid for the materials delivered to the work site. D. Provide evidence that the materials and equipment are covered by appropriate property insurance or other arrangements to protect Owner's interest. E. The Work covered by progress payments becomes the property of the Owner at the time of payment. The Design/Builder's obligations with regard to proper care and maintenance, insurance, and other requirements are not changed by this transfer of ownership until accepted in accordance with the General Conditions. F. Payment for materials and equipment does not constitute acceptance of the product. 17.07 Retainage and Set -Offs A. Retainage will be withheld from each Application for Payment per the Agreement. Retainage will be released with the final payment. B. Reduce payments for set -offs per the General Conditions. Include the appropriate attachment to the Application for Payment. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-72 Rev 5/2024 17.08 Procedures for Submitting an Application for Payment A. Submit a draft Application for Payment to the OAR each month at least 20 days before the date established in the Contract for Owner to make progress payments. Do not submit Applications for Payment more often than monthly. Review the draft Application for Payment with the OAR to determine concurrence with: 1. The earned value for each lump sum item including the value of properly stored and documented materials and equipment for each item in the original Contract. 2. The quantity of Work completed for each unit price item. 3. Set -offs included in the Application for Payment. 4. Values requested for materials and equipment consistent with invoices for materials and equipment. B. Submit Applications for Payment monthly through the OAR after agreement has been reached on the draft Application for Payment. 1. Number each application sequentially and include the dates for the application period. 2. Show the total amounts for earned value of original Contract performed, earned value for Work on approved Contract Amendments and Change Orders, retainage, and set- offs. Show total amounts that correspond to totals indicated on the attached tabulation for each. 3. Include Attachment A to show the earned value on each line item in the Schedule of Values for Work shown in the original Contract. 4. Include Attachment B to show the earned value on line items for approved Change Orders. Add items to Attachment B as Change Orders are approved. Change Orders must be approved before payment can be made on Change Order items. 5. Include Attachment C to document set -offs required per the Contract Documents. Show each set-off as it is applied. Show a corresponding line item to reduce the set-off amount if a payment held by a set-off is released for payment. 6. Include Attachment D to allow tracking of invoices used to support amounts requested as materials in Attachments A and B. Enter materials to show the amount of the invoice assigned to each item in Attachment A or B if an invoice includes materials used on several line items. 7. Complete the certification stating that all Work, including materials and equipment, covered by this Application for Payment have been completed or delivered and stored in accordance with the Contract Documents, that all amounts have been paid for Work, materials, and equipment for which previous payments have been made by the Owner, and that the current payment amount shown in this Application for Payment is now due. C. Submit attachments in Portable Document Format (PDF): 1. Generate attachments to the Application for Payment using the Excel spreadsheet provided. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-73 Rev 5/2024 2. Submit PDF documents with adequate resolution to allow documents to be printed in a format equivalent to the document original. Documents are to be scalable to allow printing on standard 8-1/2 x 11 or 11 x 17 paper. 17.09 Responsibility of Owner's Authorized Representative A. OAR will review draft Application for Payment with Design/Builder to reach an agreement on the values that will be recommended for payment by the OAR. B. OAR will review Application for Payment submitted by Design/Builder to determine that the Application for Payment has been properly submitted and is in accordance with the agreed to draft Application for Payment. C. OAR is to either recommend payment of the Application for Payment to Owner or notify the Design/Builder of the OPT's reasons for not recommending payment. Design/Builder may make necessary corrections and resubmit the Application for Payment if it is not recommended within 10 days after receipt of the notice. OAR will review resubmitted Application for Payment and reject or recommend payment of the Application for Payment to Owner as appropriate. D. OAR's recommendation of the Application for Payment constitutes a representation by OPT that based on their experience and the information available: 1. The Work has progressed to the point indicated; 2. The quality of the Work is generally in accordance with the Contract Documents; and 3. Requirements prerequisite to payment have been met. E. This representation is subject to: 1. Further evaluation of the Work as a functioning whole; 2. The results of subsequent tests called for in the Contract Documents; or 3. Any other qualifications stated in the recommendation. F. OPT does not represent by recommending payment: 1. Inspections made to check the quality or the quantity of the Work as it has been performed have been exhaustive, extended to every aspect of the Work in progress, or involved detailed inspections of the Work; or 2. Other matters or issues between the parties that might entitle Design/Builder to additional compensation or entitle Owner to withhold payment to Design/Builder may or may not exist. G. Neither OPT's review of Design/Builder's Work for the purposes of recommending payments nor OAR's recommendation of payment imposes responsibility on OPT: 1. To supervise, direct, or control the Work; 2. For the means, methods, techniques, sequences, or procedures of construction, or safety precautions and programs; 3. For Design/Builder's failure to comply with Laws and Regulations applicable to Design/Builder's performance of the Work; General Conditions — Design/Build (LS) Corpus Christi Standards 007200-74 Rev 5/2024 4. To make examinations to ascertain how or for what purposes Design/Builder has used the monies paid on account of the Contract Price; or 5. To determine that title to the Work, materials, or equipment has passed to Owner free and clear of Liens. 17.10 Design/Builder's Warranty of Title A. Design/Builder warrants and guarantees that title to the Work, materials, and equipment furnished under the Contract is to pass to Owner free and clear of Liens, title defects, and patent, licensing, copyright, or royalty obligations no later than 7 days after the time of payment by Owner of the Application for Payment which includes these items. 17.11 Final Application for Payment A. Include adjustments to the Contract Price in the final Application for Payment for: 1. Approved Change Orders and Contract Amendments, 2. Allowances not previously adjusted by Change Order, 3. Deductions for Defective Work that has been accepted by the Owner, 4. Penalties and bonuses, 5. Deductions for liquidated damages, 6. Deduction for all final set -offs, and 7. Other adjustments if needed. B. OAR will prepare a final Change Order reflecting the approved adjustments to the Contract Price which have not been covered by previously approved Change Orders and if necessary reconcile estimate unit price quantities with actual quantities. 17.12 Final Payment A. Make final Application for Payment after completing required corrections identified during the final inspection and delivering items and documents required by the Contract Documents. Provide the following with the final Application for Payment: 1. Consent of Surety to final payment acknowledging unsettled disputes; and 2. Certification of Payment of Debts and Claims or Certification of Release of Liens or furnish receipts or releases in full from Subcontractors and Suppliers. B. OAR is to either recommend payment of the final Application for Payment to Owner if OPT is satisfied that the Work has been completed and Design/Builder's other obligations under the Contract Documents have been fulfilled or notify the Design/Builder of the OPT's reasons for not recommending final payment. C. The Work is complete, subject to surviving obligations, when it is ready for final payment as established by the OAR's recommendation of payment of the final Application for Payment to Owner and the issuance of a Certificate of Final Completion. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-75 Rev 5/2024 D. The Owner is to pay the amount of final payment recommended by the OAR within 30 days after receipt of the final Application for Payment and accompanying documentation from the OAR. 17.13 Waiver of Claims A. The making of final payment does not constitute a waiver by Owner of claims or rights against Design/Builder. Owner expressly reserves claims and rights arising from: 1. Unsettled Liens or claims for non-payment; 2. Defective Work appearing after final inspection; 3. Design/Builder's failure to comply with the Contract Documents or the terms of specified special guarantees; or 4. Design/Builder's continuing obligations under the Contract Documents. B. Design/Builder waives claims and rights against Owner by accepting final payment with the exception of those Claims made in accordance with the provisions of Article 22 and specifically noted in the Certificate of Final Completion. 17.14 Correction Period A. Promptly correct Defective Work without cost to Owner for 1 year after the date of Substantial Completion or, in the event of a latent defect, within 1 year after discovery thereof by City. B. Promptly correct damages to the Site or adjacent areas that Design/Builder has arranged to use through construction easements or other agreements. Promptly correct damages to Work or the work of others. Make corrections without cost to Owner. C. Owner may have the Defective Work and damages corrected if Design/Builder does not comply with the terms of OAR's instructions, or in an emergency where delay would cause serious risk of loss or damage. D. Design/Builder's obligation to indemnify Owner for claims arising out of or related to the correction of Defective Work are as set forth in Paragraph 7.14. E. Design/Builder's obligations under this paragraph are in addition to other obligations or warranties. The provisions of this paragraph are not a substitute for, or a waiver of, the provisions of applicable statutes of limitation or repose. ARTICLE 18 — SUSPENSION OF WORK AND TERMINATION 18.01 Owner May Suspend Work A. Owner may suspend the Work or a portion of the Work for a period of not more than 90 consecutive days, at any time and without cause, by notice to Design/Builder. This notice fixes the date on which Design/Builder is to resume Work. Design/Builder is entitled to adjustments in the Contract Price and Contract Times directly attributable to this suspension only if efforts are made to mitigate the cost impacts of the suspension. Meet with the Owner within 10 days of the notice of suspension to discuss specific strategies to reduce or eliminate General Conditions — Design/Build (LS) Corpus Christi Standards 007200-76 Rev 5/2024 the cost of delays. Submit a Change Proposal seeking an adjustment no later than 30 days after the date fixed for resumption of Work. 18.02 Owner May Terminate for Cause A. The occurrence of one or more of the following events constitutes a default by Design/Builder and justifies termination for cause: 1. Design/Builder's persistent failure to perform the Work in accordance with the Contract Documents, including failure to supply sufficient skilled workers or suitable materials or equipment; 2. Failure to adhere to the Progress Schedule; 3. Failure of the Design/Builder to provide a satisfactory replacement Bond or insurance in the event either is lost or canceled; 4. Failure of Design/Builder to maintain financial solvency to adequately complete the Project as indicated by one or more of the following: a. A petition of bankruptcy is filed by or against Design/Builder, b. Design/Builder is adjudged as bankrupt or insolvent, c. Design/Builder or surety makes a general assignment for the benefit of creditors, d. A receiver is appointed for the benefit of Design/Builder's creditors, or e. A receiver is appointed on account of Design/Builder's insolvency; 5. Design/Builder's disregard of Laws or Regulations of public bodies having jurisdiction; 6. Design/Builder's repeated disregard of the authority of OPT; 7. Design/Builder's failure to prosecute the work with diligence; or 8. Design/Builder's other material breach of the contract. B. Design/Builder and surety must provide adequate assurance of future performance in accordance with the Contract Documents that is satisfactory to Owner if Design/Builder is believed to be in financial distress due to the existence of one or more of the indicators listed in Paragraph 18.02.A.4. Owner may terminate Design/Builder's performance under this Contract if Design/Builder and surety fail to provide adequate documentation satisfactory to Owner within 10 days of OAR's request for this information. C. Owner may declare Design/Builder to be in default, give notice to Design/Builder and surety that Design/Builder's performance under the Contract is terminated, and enforce the rights available to Owner under the Performance Bond after giving Design/Builder and surety 10 days' notice that one or more of the events identified in Paragraph 18.02.A has occurred. D. Owner may exclude Design/Builder from the Site, take possession of the Work, incorporate the materials and equipment stored and complete the Work as Owner may deem expedient if Owner has terminated Design/Builder's performance under the Contract for cause. E. Owner may elect not to proceed with termination of Design/Builder's performance under the Contract under this Paragraph 18.02 if Design/Builder begins to cure the cause for termination within 7 days of receipt of notice of intent to terminate. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-77 Rev 5/2024 F. Design/Builder is not entitled to receive further payments until the Work is completed if Owner proceeds as provided in this Paragraph 18.02. The amount of the Contract Price remaining is to be paid to the Design/Builder if the unpaid balance exceeds the cost to complete the Work. The cost to complete the Work may include related claims, costs, losses, damages, and the fees and charges of engineers, architects, attorneys, and other professionals retained by Owner. Pay the difference to Owner if the cost to complete the Work including related claims, costs, losses, and damages exceeds the unpaid balance of the Contract Price. Owner is not required to obtain the lowest price for the Work performed when exercising its rights or remedies under this paragraph. G. Termination of Design/Builder's performance does not affect the rights or remedies of Owner against Design/Builder or against surety under the Payment Bond or Performance Bond. Owner does not release Design/Builder from liability by paying or retaining money due Design/Builder. H. In the event the Owner terminates the contract for cause, and it is later determined that cause for termination was lacking, the termination will be deemed a termination without cause under Paragraph 18.03. 18.03 Owner May Terminate For Convenience A. Owner may terminate the Contract without cause after giving 7 days' notice to Design/Builder of the effective date of termination. Design/Builder is to be paid for the following if Owner terminates for convenience: 1. Work completed in accordance with the Contract Documents prior to the effective date of termination; 2. Actual costs sustained prior to the effective date of termination for Work in progress, plus a fee calculated in accordance with Paragraph 15.05; and 3. Reasonable expenses directly attributable to termination, including costs incurred to prepare a termination for convenience cost proposal. B. No payment is payable to Design/Builder for loss of anticipated overhead, profits or revenue, or other economic loss arising out of or resulting from this termination. ARTICLE 19 — PROJECT MANAGEMENT 19.01 Work Included A. Furnish resources required to complete the Project with an acceptable standard of quality within the Contract Times. B. Construct Project in accordance with current safety practices. C. Manage Site to allow access to Site and control construction operations. D. Construct temporary facilities to provide and maintain control over environmental conditions at the Site. Remove temporary facilities when no longer needed. E. Provide temporary controls for pollutions, management of water and management of excess earth. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-78 Rev 5/2024 19.02 Quality Assurance A. Employ competent workmen, skilled in the occupation for which they are employed. Provide Work meeting quality requirements of the Contract Documents. B. Remove Defective Work from the Site immediately unless provisions have been made and approved by the OPT to allow repair of the product at the Site. Clearly mark Work as Defective until it is removed or allowable repairs have been completed. 19.03 Document Submittal A. Provide documents in accordance with Article 24. 1. Provide copies of Supplier's printed storage instructions prior to furnishing materials or products and installation instructions prior to beginning the installation. 2. Incorporate field notes, sketches, recordings, and computations made by the Design/Builder in Record Data. 19.04 Required Permits A. Obtain building permits for the Project from the local authorities having jurisdiction. Pay building permit fees and include this cost in the Contract Price. B. Obtain environmental permits required for construction at the Site. C. Provide required permits for transporting heavy or oversized loads. D. Provide other permits required to conduct any part of the Work. E. Arrange for inspections and certification by agencies having jurisdiction over the Work. F. Make arrangements with private utility companies and pay for fees associated with obtaining services, or for inspection fees. G. Retain copies of permits and licenses at the Site and observe and comply with all regulations and conditions of the permit or license. 19.05 Safety Requirements A. Manage safety to protect the safety and welfare of persons at the Site. B. Provide safe access to move through the Site. Provide protective devices to warn and protect from hazards at the Site. C. Provide safe access for those performing tests and inspections. D. Comply with latest provisions of the Occupational Health and Safety Administration and other Laws and Regulation. E. Cooperate with accident investigations. Provide two copies of all reports, including insurance company reports, prepared concerning accidents, injury, or death related to the Project to the OAR as Record Data per Article 26. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-79 Rev 5/2024 19.06 Access to the Site A. Maintain access to the facilities at all times. Do not obstruct roads, pedestrian walks, or access to the various buildings, structures, stairways, or entrances. Provide safe access for normal operations during construction. B. Provide adequate and safe access for inspections. Leave ladders, bridges, scaffolding, and protective equipment in place until inspections have been completed. Construct additional safe access if required for inspections. C. Use roadways for construction traffic only with written approval of the appropriate representatives of each entity. Obtain written approval to use roads to deliver heavy or oversized loads to the Site. Furnish copies of the written approvals to the Owner as Record Data per Article 26. 19.07 Design/Builder's Use of Site A. Limit the use of Site for Work and storage to those areas approved by the OAR. Coordinate the use of the premises with the OAR. B. Provide security at the Site as necessary to protect against vandalism and loss by theft. C. Do not permit alcoholic beverages or illegal substances on the Site. Do not allow persons under the influence of alcoholic beverages or illegal substances to enter or remain on the Site at any time. Persons on Site under the influence of alcoholic beverages or illegal substances will be permanently prohibited from returning to the Site. Criminal or civil penalties may also apply. D. Park construction equipment in designated areas only and provide spill control measures. E. Park employees' vehicles in designated areas only. F. Obtain written permission of the Owner before entering privately -owned land outside of the Owner's property, rights -of -way, or easements. G. Do not allow the use of audio devices, obnoxious, vulgar or abusive language, or sexual harassment in any form. These actions will cause immediate and permanent removal of the offender from the premises. Criminal or civil penalties may apply. H. Require Workers to wear clothing that is inoffensive and meets safety requirements. I. Do not allow firearms or weapons of any sort to be brought on to the Site under any conditions. No exception is to be made for persons with concealed handgun permits. Remove any firearms or weapons and the person possessing these firearms or weapons immediately from the Site. 19.08 Protection of Existing Structures and Utilities A. Examine the Site and review the available information concerning the Site. Locate utilities, streets, driveways, fences, drainage structures, sidewalks, curbs, and gutters. Verify the elevations of the structures adjacent to excavations. B. Determine if existing structures, poles, piping, or other utilities at excavations will require relocation or replacement. Prepare a Plan of Action and coordinate Work with local utility companies and others for the relocation or replacement. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-80 Rev 5/2024 C. Protect buildings, utilities, street surfaces, driveways, sidewalks, curb and gutter, fences, wells, drainage structures, piping, valves, manholes, electrical conduits, and other systems or structures unless they are shown to be replaced or relocated on the Drawings. Restore damaged items to the satisfaction of the OPT and utility owner. D. Carefully support and protect all structures and/or utilities so that there will be no failure or settlement where excavation or demolition endangers adjacent structures and utilities. Do not take existing utilities out of service unless approved by the OAR. Notify and cooperate with the utility owner if it is necessary to move services, poles, guy wires, pipelines, or other obstructions. E. Protect existing trees and landscaping at the Site. 1. Identify trees that may be removed during construction with OPT. 2. Mark trees to be removed with paint. 3. Protect trees to remain from damage by wrapping trunks with 2 x 4 timbers around the perimeter, securely wired in place, where machinery must operate around existing trees. Protect branches and limbs from damage by equipment. 4. Protect root zone from compaction. 19.09 Pre -Construction Exploratory Excavations A. Excavate and expose existing pipelines that cross within 20 feet of Project pipelines prior to any Work. Survey the line to determine its exact vertical and horizontal location at each point the existing pipeline may potentially conflict with the Work. B. Excavate and expose existing parallel pipelines at 300 feet intervals (maximum) for existing pipelines which are within 10 feet of Project pipelines. Survey the line to determine its exact vertical and horizontal location at each point where the line is excavated and exposed. C. Prepare a Plan of Action indicating the owner of pipelines excavated and surveyed and all pertinent survey data, including the station where lines cross or conflicts may exist and the distance to the pavement centerline and elevations of the top of existing pipelines. D. Do not perform Work on the Project until all exploratory excavations have been completed and the Plan of Action has been approved by the OAR. 19.10 Disruption of Services/Continued Operations A. Existing facilities are to continue in service as usual during the construction unless noted otherwise. Owners of utilities must be able to operate and maintain the facilities. Keep disruptions to existing utilities, piping, process piping, or electrical services to a minimum. 1. Do not restrict access to critical valves or operators. 2. Limit operations to the minimum amount of space needed to complete the specified Work. 3. Maintain storm sewers and sanitary sewers in service at all times. Provide temporary service around the construction or otherwise construct the structure in a manner that the flow is not restricted. B. Provide a Plan of Action if facilities must be taken out of operation. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-81 Rev 5/2024 19.11 Delivery and Storage A. Deliver products and materials to the Site in time to prevent delays in construction. B. Deliver packaged products to Site in original undamaged containers with identifying labels attached. Open cartons as necessary to check for damage and to verify invoices. Reseal cartons and store properly until used. Leave products in packages or other containers until installed. C. Assume full responsibility for the protection and safekeeping of products stored at the Site. D. Store products at locations acceptable to the OAR and to allow Owner access to maintain and operate existing facilities. E. Store products in accordance with the Supplier's storage instructions immediately upon delivery. Leave seals and labels intact. F. Provide additional storage areas as needed for construction. Store products subject to damage by elements in substantial weather -tight enclosures or storage sheds. Provide and maintain storage sheds as required for the protection of products. Provide temperature, humidity control, and ventilation within the ranges stated in the Supplier's instructions. Remove storage facilities at the completion of the Project. G. Protect the pipe interior. Keep all foreign materials such as dirt, debris, animals, or other objects out of the pipe during the Work. Cap or plug ends of installed pipe in an approved manner when pipe is not being installed. Clean or wash out pipe sections that become contaminated before continuing with installation. Take precautions to prevent the pipe from floating or moving out of the proper position during or after laying operations. Immediately correct any pipe that moves from its correct position. H. Provide adequate exterior storage for products that may be stored out-of-doors. 1. Provide substantial platforms, blocking, or skids to support materials and products above ground which has been sloped to provide drainage. Protect products from soiling or staining. 2. Cover products subject to discoloration or deterioration from exposure to the elements, with impervious sheet materials. Provide ventilation to prevent condensation below covering. 3. Store loose, granular materials on clean, solid surfaces, or on rigid sheet materials, to prevent mixing with foreign matter. 4. Provide surface drainage to prevent erosion and ponding of water. 5. Prevent mixing of refuse or chemically injurious materials or liquids with stored materials. 6. Pipes and conduits stored outdoors are to have open ends sealed to prevent the entrance of dirt, moisture, and other injurious materials. Protect PVC pipe from ultraviolet light exposure. 7. Store light weight products to prevent wind damage. I. Maintain storage facilities. Inspect stored products on a weekly basis and after periods of severe weather to verify that: General Conditions — Design/Build (LS) Corpus Christi Standards 007200-82 Rev 5/2024 1. Storage facilities continue to meet specified requirements; 2. Supplier's required environmental conditions are continually maintained; and 3. Products that can be damaged by exposure to the elements are not adversely affected. J. Replace any stored item damaged by inadequate protection or environmental controls. K. Payment may be withheld for any products not properly stored. 19.12 Cleaning During Construction A. Provide positive methods to minimize raising dust from construction operations and provide positive means to prevent air -borne dust from disbursing into the atmosphere. Control dust and dirt from demolition, cutting, and patching operations. B. Clean the Project as Work progresses and dispose of waste materials, keeping the Site free from accumulations of waste or rubbish. Provide containers on Site for waste collection. Do not allow waste materials or debris to blow around or off of the Site. Control dust from waste materials. Transport waste materials with as few handlings as possible. C. Comply with Laws and Regulations. Do not burn or bury waste materials. Remove waste materials, rubbish and debris from the Site and legally dispose of these at public or private disposal facilities. D. Provide a final cleaning to thoroughly clean the entire Site and make ready for acceptance. 1. Remove construction debris, boxes, and trash from the Site. 2. Remove construction storage sheds and field offices. 3. Restore grade to match surrounding condition and remove excess dirt. 4. Sweep all drives and parking lots clean of dirt and debris. Use water trucks or hose down paved site to like new appearance. 19.13 Maintenance of Roads, Driveways, and Access A. Maintain roads and streets in a manner that is suitable for safe operations of public vehicles during all phases of construction unless the Owner approves a street closing. Do not close public roads overnight. B. Submit a Notification by Design/Builder for Owner's approval of a street closing. The request shall state: 1. The reason for closing the street. 2. How long the street will remain closed. 3. Procedures to be taken to maintain the flow of traffic. C. Construct temporary detours, including by-pass roads around construction, with adequately clear width to maintain the free flow of traffic at all times. Maintain barricades, signs, and safety features around the detour and excavations. Maintain barricades, signs, and safety features around the Work in accordance with all provisions of the latest edition of the Manual on Uniform Traffic Control Devices (MUTCD). D. Assume responsibility for any damage resulting from construction along roads or drives. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-83 Rev 5/2024 19.14 Area Access and Traffic Control A. Provide traffic control measures to assure a safe condition and to provide a minimum of inconvenience to motorists and the public. Provide all-weather access to all residents and businesses at all times during construction. Provide temporary driveways and/or roads of approved material during wet weather. Maintain a stockpile of suitable material on the Site to meet the demands of inclement weather. B. Schedule operations to minimize adverse impact on the accessibility of adjoining properties. Sequence construction to build driveways in half widths, construct temporary ramps, or any other measure required to maintain access to adjoining properties. C. Comply with the Owner's Uniform Barricading Standards and Practices. Copies of this document are available through the Owner's Public Works Department. Secure required permits from the Owner's Public Works Department. 19.15 Overhead Electrical Wires A. Comply with OSHA safety requirements regarding construction equipment working beneath overhead electrical wires. Prevent and pay for repairs for damage to existing overhead electrical wires or facilities. B. Provide for adequate safety with regard to overhead lines whether overhead lines are or are not shown in the Contract Documents. 19.16 Blasting A. Blasting is not allowed for any purpose. 19.17 Archeological Requirements A. Cease operations immediately and contact the Owner for instructions if historical or archaeological artifacts are found during construction. B. Conduct all construction activities to avoid adverse impact on the Sites where significant historical or archaeological artifacts are found or identified as an area where other artifacts could be found. 1. Obtain details for Working in these areas. 2. Maintain confidentiality regarding the Site. 3. Adhere to the requirements of the Texas Historical Commission. 4. Notify the OAR and the Texas Historical Commission. C. Do not disturb archaeological sites. 1. Obtain the services of a qualified archaeological specialist to instruct construction personnel on how to identify and protect archaeological finds on an emergency basis. 2. Coordinate activities to permit archaeological work to take place within the area. a. Attempt to archaeologically clear areas needed for construction as soon as possible. b. Provide a determination of priority for such areas. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-84 Rev 5/2024 D. Assume responsibility for any unauthorized destruction that might result to such Sites by construction personnel, and pay all penalties assessed by the State or Federal agencies for non-compliance with these requirements. E. Contract Times will be modified to compensate for delays caused by such archaeological finds. No additional compensation will be paid for delays. 19.18 Endangered Species Resources A. Do not perform any activity that is likely to jeopardize the continued existence of a threatened or endangered species as listed or proposed for listing under the Federal Endangered Species Act (ESA), and/or the State of Texas Parks and Wildlife Code on Endangered Species, or to destroy or adversely modify the habitat of such species. B. Cease Work immediately in the area of the encounter and notify the OAR if a threatened or endangered species is encountered during construction. OPT will implement actions in accordance with the ESA and applicable State statutes. Resume construction in the area of the encounter when authorized to do so by the OAR. 19.19 Cooperation with Public Agencies A. Cooperate with all public and private agencies with facilities operating within the limits of the Project. B. Provide a 48-hour notice to any applicable agency when work is anticipated to proceed in the vicinity of any facility by using Texas 811 at 811 and the Lone Star Notification Center at 1-800-669-8344. ARTICLE 20 — PROJECT COORDINATION 20.01 Work Included A. Administer Contract requirements to design and construct the Project. Provide documentation per the requirements of this Section. Provide information as requested by the OPT. 20.02 Document Submittal A. Provide documents in accordance with Article 24. B. Use the forms provided for Contract administration, applications for payment, document submittals, documentation of test results, equipment installation and documentation, and Project closeout. A digital copy of the required forms will be provided to the Design/Builder before or at the pre -construction conference. 20.03 Communication During Project A. The OAR is to be the first point of contact for all parties on matters concerning this Project. B. The OAR will coordinate correspondence concerning: 1. Documents, including Applications for Payment. 2. Clarification and interpretation of the Contract Documents. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-85 Rev 5/2024 3. Contract Modifications. 4. Observation of Work and testing. 5. Claims. C. The OAR will normally communicate only with the Design/Builder. Any required communication with Subcontractors or Suppliers will only be with the direct involvement of the Design/Builder. D. Direct written communications to the OAR at the address indicated at the pre -construction conference. Include the following with communications as a minimum: 1. Name of the Owner. 2. Project name. 3. Contract title. 4. Project number. 5. Date. 6. A reference statement. 20.04 Project Meetings A. Design Meeting 1. Provide and be prepared to discuss: a. Preliminary project schedule, including design and construction. B. Pre -Construction Conference: 1. Attend a pre -construction conference. 2. The location of the conference will be determined by the OAR. 3. The time of the meeting will be determined by the OAR but will be after the Notice of Award is issued and not later than 15 days after the Notice to Proceed is issued. 4. The OPT, Design/Builder's project manager and superintendent, representatives of utility companies, and representatives from major Subcontractors and Suppliers may attend the conference. 5. Provide and be prepared to discuss: a. Preliminary construction schedule per Article 27. b. Schedule of Values and anticipated Schedule of Payments per Article 17. c. List of Subcontractors and Suppliers. d. Design/Builder's organizational chart as it relates to this Project. e. Letter indicating the agents of authority for the Design/Builder and the limit of that authority with respect to the execution of legal documents, Contract Modifications, and payment requests. f. Payment and performance bonds. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-86 Rev 5/2024 C. Progress Meetings: 1. Attend meetings with the OAR and Owner. a. Meet on a monthly basis or as requested by the OAR to discuss the Project. b. Meet at the Site or other location as designated by the OAR. c. Design/Builder's superintendent and other key personnel are to attend the meeting. Other individuals may be requested to attend to discuss specific matters. d. Notify the OAR of any specific items to be discussed a minimum of 1 week prior to the meeting. 2. Provide information as requested by the OAR or Owner concerning this Project. Prepare to discuss: a. Status of overall Project schedule. b. Design/Builder's detailed schedule for the next month. c. Anticipated delivery dates for equipment. d. Coordination with the Owner. e. Status of documents. f. Information or clarification of the Contract Documents. g. Claims and proposed Modifications to the Contract. h. Field observations, problems, or conflicts. i. Maintenance of quality standards. 3. OAR will prepare minutes of meetings. Review the minutes of the meeting and notify the OAR of any discrepancies within 10 days of the date of the meeting memorandum. The minutes will not be corrected after the 10 days have expired. Corrections will be reflected in the minutes of the following meeting or as an attachment to the minutes. 20.05 Requests for Information A. Submit Requests for Information (RFI) to the OAR to obtain additional information or clarification of the Contract Documents. 1. Submit a separate RFI for each item on the form provided. 2. Attach adequate information to permit a written response without further clarification. OAR will return requests that do not have adequate information to the Design/Builder for additional information. Design/Builder is responsible for all delays resulting from multiple document submittals due to inadequate information. 3. A response will be made when adequate information is provided. Response will be made on the RFI form or in attached information. B. Response to an RFI is given to provide additional information and does not modify the Contract Documents. C. Use the Project Issues Log to document decisions made at meetings and actions to be taken in accordance with Paragraph 20.06. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-87 Rev 5/2024 D. Use the Action Item Log to document assignments for actions to be taken in accordance with Paragraph 20.06. 20.06 Decision and Action Item Log A. OAR will maintain a Project Decision Log to document key decisions made at meetings, telephone conversation or Site visits using the format provided: 1. Review the log prior to each regular meeting. 2. Report any discrepancies to the OAR for correction or discussion at the next monthly meeting. B. OAR will maintain an Action Item log in conjunction with the Project Decision Log to track assignments made at meetings, telephone conversation, or Site visits using the format provided: 1. Review the Action Item Log prior to each regular meeting. 2. Report actions taken subsequent to the previous progress meeting on items in the log assigned to the Design/Builder or through the Design/Builder to a Subcontractor or Supplier to the OAR. Report on status of progress 1 week prior to each progress meeting established in Paragraph 20.04 to allow OAR to update the log prior to the Progress meetings. 3. Be prepared to discuss the status at each meeting. C. Decisions or action items in the log that require a change in the Contract Documents will have the preparation of a Modification as an action item if appropriate. The Contract Documents can only be changed by a Modification. 20.07 Notification By Design/Builder A. Notify the OAR of: 1. Need for testing. 2. Intent to work outside regular working hours. 3. Request to shut down facilities or utilities. 4. Proposed utility connections. 5. Required observation by OAR or inspection agencies prior to covering Work. 6. Training. B. Provide notification a minimum of 2 weeks in advance in order to allow OPT time to respond appropriately to the notification. 20.08 Record Documents A. Maintain at the Site one complete set of printed Record Documents including: 1. Drawings. 2. Specifications. 3. Addenda. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-88 Rev 5/2024 4. Modifications. 5. Record Data and approved Shop Drawings. 6. Construction photographs. 7. Test Reports. 8. Clarifications and other information provided in Request for Information responses. 9. Reference standards. B. Store printed Record Documents and Samples in the Design/Builder's field office. 1. Record Documents are to remain separate from documents used for construction. 2. Provide files and racks for the storage of Record Documents. 3. Provide a secure storage space for the storage of Samples. 4. Maintain Record Documents in clean, dry, legible conditions, and in good order. 5. Make Record Documents and Samples available at all times for inspection by the OPT. C. Maintain a digital record of Specifications and Addenda to identify products provided in PDF format. 1. Reference the Record Data number, Shop Drawings number, and O&M manual number for each product and item of equipment furnished or installed. 2. Reference Modifications by type and number for all changes. D. Maintain a digital record of Drawings in PDF format. 1. Reference the Record Data number, Shop Drawings number, and O&M manual number for each product and item of equipment furnished or installed. 2. Reference Modifications by type and number for all changes. 3. Record information as construction is being performed. Do not conceal any Work until the required information is recorded. 4. Mark Drawings to record actual construction, including the following: a. Depths of various elements of the foundation in relation to finished first floor datum or the top of walls. b. Horizontal and vertical locations of underground utilities and appurtenances constructed and existing utilities encountered during construction. c. Location of utilities and appurtenances concealed in the Work. Refer measurements to permanent structures on the surface. Include the following equipment: 1) Piping. 2) Ductwork. 3) Equipment and control devices requiring periodic maintenance or repair. 4) Valves, unions, traps, and tanks. 5) Services entrance. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-89 Rev 5/2024 6) Feeders. 7) Outlets. d. Changes of dimension and detail. e. Changes by Modifications. f. Information in Request for Information or included in the Project Issues Log. g• Details not on the original Drawings. Include field verified dimensions and clarifications, interpretations, and additional information issued in response to RFIs. 5. Mark Drawings with the following colors: a. Highlight references to other documents, including Modifications in blue; b. Highlight mark ups for new or revised Work (lines added) in yellow; c. Highlight items deleted or not installed (lines to be removed) in red; and d. Highlight items constructed per the Contract Documents in green. 6. Submit Record Documents to OAR 30 days prior to Final Completion of the Project. E. Applications for Payment will not be recommended for payment if Record Documents are found to be incomplete or not in order. Final payment will not be recommended without complete Record Documents. ARTICLE 21— QUALITY MANAGEMENT 21.01 Design/Builder's Responsibilities A. Prepare and submit the Design/Builder's Quality Control Plan. B. Implement the Design/Builder's Quality Control Plan to control the quality of the Work and verify that the Work meets the standards of quality established in the Contract Documents. 1. Inspect products to be incorporated into the Project. Ensure that Suppliers have adequate quality control systems to ensure that products that comply with the Contract Documents are provided. 2. Integrate quality control measures into construction activities to produce Work which meets quality expectations of the Contract Documents. Inspect the Work of the Design/Builder, Subcontractors, and Suppliers. Correct Defective Work. 3. Provide and pay for the services of an approved professional materials testing laboratory acceptable to the OPT to provide testing that demonstrates that products proposed for the Project fully comply with the Contract Documents. 4. Provide facilities, equipment, and Samples required for quality control inspections and tests: a. Give the OAR adequate notice before proceeding with Work that would interfere with inspections or testing; General Conditions — Design/Build (LS) Corpus Christi Standards 007200-90 Rev 5/2024 b. Notify the OAR and testing laboratories prior to the time that testing is required, providing adequate lead time to allow arrangements for inspections or testing to be made; c. Do not proceed with any Work that would impact the ability to correct defects or Work that would require subsequent removal to correct defects until testing services have been performed and results of tests indicate that the Work is acceptable; d. Cooperate fully with the performance of sampling, inspection, and testing; e. Provide personnel to assist with sampling or to assist in making inspections and field tests; f. Obtain and handle Samples for testing at the Site or at the production source of the product to be tested; Provide adequate quantities of representative products to be tested to the laboratory at the designated locations; h. Provide facilities required to store and cure test Samples; i. Provide calibrated scales and measuring devices for the OPT's use in performing inspections and testing; j. Provide adequate lighting to allow OPT observations; and k. Make Contract Documents available to testing agencies when requested. 5. Provide safe access for all inspection and testing activities, including those to be conducted as part of the OPT's Quality Management Program. 6. Document Defective Work through Certified Test Reports and Defective Work Notices. Document that corrective actions have been taken to correct any defects and that corrected Work is in compliance with the Contract Documents. 7. Apply quality control measures to documentation provided for the Project. 8. Implement countermeasures to prevent future Defective Work. C. Perform tests as indicated in this and other Sections of the Specifications. Technical Specifications govern if any testing and inspection requirements of this Section conflict with the testing and inspection requirements of the technical Specifications. D. All verification testing is to be observed by the OAR or designated representative. E. Send test reports to the OAR. F. Provide an update on quality control activities at monthly progress meetings. G. Owner will withhold payment for Defective Work or Work that has not been tested or inspected in accordance with the Design/Builder's Quality Control Plan, the OPT's Quality Control Program, or the Contract Documents. H. Owner will withhold payment for additional testing fees incurred due to Design/Builder noncompliance with OPT's Quality Control Program, including retesting fees, standby time, cancellation charges, and trip fees for retesting or cancellations. g• General Conditions — Design/Build (LS) Corpus Christi Standards 007200-91 Rev 5/2024 I. Work performed that is connected or adjacent to Defective Work or Work that would have to be removed to correct Defective Work is also considered to be Defective. Design/Builder is responsible for all cost with replacing any acceptable Work that must be removed or might be damaged by corrective actions. 21.02 Quality Management Activities by OPT A. OPT will perform its own quality assurance tests independent of the Design/Builder's Quality Control Program. Assist the OPT and testing organizations in performing quality assurance activities per Paragraph 21.01. B. Quality assurance testing performed by the OPT will be paid for by the Owner, except for verification testing required per Paragraph 21.07. C. Quality assurance activities of the OPT, through their own forces or through contracts with consultants and materials testing laboratories are for the purpose of monitoring the results of the Design/Builder's Work to see that it is in compliance with the requirements of the Contract Documents. Quality assurance activities or non-performance of quality assurance activities by the OPT do not: 1. Relieve the Design/Builder of its responsibility to provide Work or furnish products that conform with the requirements of the Contract Documents; 2. Relieve the Design/Builder of its responsibility for providing adequate quality control measures; 3. Relieve the Design/Builder of its responsibility for damage to or loss of Work or products before OPT's acceptance; 4. Constitute or imply OPT's acceptance; and 5. Affect the continuing rights of the Owner after OPT's acceptance of the completed Work. D. Work is subject to OPT's quality assurance observations or testing at any time. Products which have been tested or inspected and approved by OPT at a supply source or staging area may be inspected or tested again by the OPT before, during or after incorporation into the Work and rejected if products do not comply with the Contract Documents. 21.03 Design/Builder's Use of OPT's Test Reports A. Design/Builder will receive copies of all test reports documenting OPT's quality assurance activities. Design/Builder is entitled to rely on the accuracy of these test results and use these as part of their quality control efforts. B. Design/Builder is to determine additional testing or inspections that may be required to implement the Design/Builder's Quality Control Plan. Include cost for additional testing and inspections required to meet Design/Builders quality control obligations, including the cost for correcting Defective Work in the Contract Price. 21.04 Documentation A. Provide documentation which includes: General Conditions — Design/Build (LS) Corpus Christi Standards 007200-92 Rev 5/2024 1. Design/Builder's Quality Management Plan that establishes the methods of assuring compliance with the Contract Documents. Submit this plan as a Shop Drawings per Article 25. 2. A Statement of Qualification for any proposed testing laboratories that includes a list of the engineers and technical staff that will provide testing services on the Project, descriptions of the qualifications of these individuals, list of tests that can be performed, equipment used with date of last certification, and a list of recent projects for which testing has been performed with references for those projects. 3. Provide Certified Test Reports for products to be incorporated into the Project. Provide reports to indicate that proposed products comply with the Contract Documents or indicate that proposed products do not comply with the Contract Documents and why it does not comply. Submit these test reports as part of a Shop Drawings submitted per Article 25. 4. Provide Certified Test Reports for inspection and testing required in this Section and in other Specification Sections. Provide reports to indicate that Work complies with the Contract Documents or indicate that Work does not comply with the Contract Documents and why it does not comply. Submit these test reports per Article 24. 21.05 Standards A. Provide testing laboratories that comply with the American Council of Independent Laboratories (ACIL) "Recommended Requirements for Independent Laboratory Qualifications." B. Perform testing per recognized test procedures as listed in the various Sections of the Specifications, standards of the State Department of Highways and Public Transportation, American Society of Testing Materials (ASTM), or other testing associations. Perform tests in accordance with published procedures for testing issued by these organizations. 21.06 Delivery and Storage A. Handle and protect test specimens of products and construction materials at the Site in accordance with recognized test procedures. Provide facilities for storing, curing, and processing test specimens as required by test standard to maintain the integrity of Samples. 21.07 Verification Testing for Corrected Defects A. Provide verification testing on Work performed to correct Defective Work to demonstrate that the Work is now in compliance with the Contract Documents. Document that Defective Work has been corrected and verify that the OAR closes the item in the Defective Work Register. B. Pay for verification testing. OPT may perform verification testing as part of their Quality Management Program and impose a Set-off to recover the cost for this testing. C. Conduct the same tests or inspections used to determine that the original Work was Defective. Different tests or methods may be used if approved by the OPT. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-93 Rev 5/2024 21.08 Test Reports A. Certified Test Reports are to be prepared for all tests. 1. Tests performed by testing laboratories may be submitted on their standard test report forms if acceptable to the OPT. These reports must include the following: a. Name of the Owner, Project title and number and Design/Builder; b. Name of the laboratory, address, and telephone number; c. Name and signature of the laboratory personnel performing the test; d. Description of the product being sampled or tested; e. Date and time of sampling, inspection, and testing; f. Date the report was issued; g. Description of the test performed; h. Weather conditions and temperature at time of test or sampling; i. Location at the Site or structure where the sample was taken; j. Standard or test procedure used in making the test; k. A description of the results of the test; I. Statement of compliance or non-compliance with the Contract Documents; and m. Interpretations of test results, if appropriate. 2. Submit reports on tests performed by Design/Builder, Subcontractors or Suppliers to the OAR. 3. OPT will prepare test reports on test performed by the OPT. B. Send test report to OAR within 24 hours of completing the test. Flag tests reports with results that do not comply with Contract Documents for immediate attention. C. Payment for Work may be withheld until test reports indicate that the Work is not Defective. 21.09 Defective Work A. Immediately correct any Defective Work or notify the OAR why the Work is not to be corrected immediately and when corrective action will be completed. B. No payment will be made for Defective Work. Remove Work from the Application for Payment if Work paid for on a previous Application for Payment is found to be Defective. 21.10 Limitation of Authority of Testing Laboratory A. The testing laboratory representatives are limited to providing testing services and interpreting the results of the test performed. B. The testing laboratory is not authorized to: 1. Alter the requirements of the Contract Documents; 2. Accept or reject any portion of the Work; General Conditions — Design/Build (LS) Corpus Christi Standards 007200-94 Rev 5/2024 3. Perform any of the duties of the Design/Builder; or 4. Direct or stop the Work. 21.11 Quality Control Plan A. Submit the Design/Builder's Quality Control Plan for approval as a Shop Drawing per Article 25. Use Design/Builder's Quality Control Plan Checklist provided to review the document before submitting and include a copy of the completed checklist with the Design/Builder's Quality Control Plan. Do not begin Work until the Design/Builder's Quality Control Plan is approved. Submit an interim plan covering only the portion of Work to be performed if the Design/Builder plans to begin Work prior to submitting the Design/Builder's Quality Control Plan for the Project. Do not begin Work on other parts of the Project until the Design/Builder's Quality Control Plan is approved or another interim plan covering the additional Work to be started is approved. B. Provide a Design/Builder's Quality Control Plan that incorporates construction operations at both the Site and production Work at remote locations and includes Work by Subcontractors and Suppliers. The Design/Builder's Quality Control Plan is to include: 1. A description of the quality control organization, including an organization chart showing lines of authority to control the quality of Work; 2. Documentation describing name, qualifications (in resume format), duties, responsibilities, and level of authority of the Quality Control Manager; 3. The name, qualifications (in resume format), duties, responsibilities, and authorities of other persons assigned a quality control function; 4. Procedures for scheduling, reviewing, certifying, and managing documentation, including documentation provided by Subcontractors and Suppliers; 5. Control, verification, and acceptance testing procedures for each specific test. Include: a. Name of tests to be performed, b. Specification paragraph requiring test, c. Parameters of Work to be tested, d. Test frequency, e. Persons responsible for each test, and f. Applicable industry testing standards and laboratory facilities to be used for the test; 6. Integrate the OPT quality assurance testing into the Design/Builder's Quality Control Plan, specifically identifying the tests or inspections in Paragraph 21.11.B.5 that will be provided by the OPT as part of their Quality Management Program; 7. Procedures for tracking and documenting quality management efforts; 8. Procedures for tracking Defective Work from initial identification through acceptable corrective action. Indicate how documentation of the verification process for deficiencies will be made; 9. Reporting procedures; and General Conditions — Design/Build (LS) Corpus Christi Standards 007200-95 Rev 5/2024 j• 10. The name of the proposed testing laboratories along with documentation of qualifications per Paragraph 21.04. C. The Quality Control Manager must have authority to reject Defective Work and redirect the efforts of the Design/Builder's Team to prevent or correct Defective Work. D. Notify the OAR of any changes to the Design/Builder's Quality Control Plan or quality control personnel. E. Meet with the OPT seven days after Design/Builder's Quality Control Plan is submitted and before start of construction to discuss the Design/Builder's Quality Control Plan and expedite its approval. 21.12 Implement Design/Builder's Quality Control Plan A. Perform quality control observations and testing as required in each Section of the Specifications and where indicated on the Drawings. B. Include the following phases for each definable Work task. A definable Work task is one which is separate and distinct from other tasks, has separate control requirements, may be provided by different trades or disciplines, or may be Work by the same trade in a different environment. 1. Planning Phase: Perform the following before beginning each definable Work task: a. Review the Contract Drawings. b. Review documents and determine that they are complete in accordance with the Contract Documents. c. Check to assure that all materials and/or equipment have been tested, submitted, and approved. d. Examine the work area to assure that all required preliminary Work has been completed and complies with the Contract Documents. e. Examine required materials, equipment, and Sample Work to assure that they are on hand, conform to Shop Drawings and Record Data, and are properly stored. f. Review requirements for quality control inspection and testing. g• Discuss procedures for controlling quality of the Work. Document construction tolerances and workmanship standards for the Work task. h. Check that the portion of the plan for the Work to be performed incorporates document review comments. i. Discuss results of planning phase with the OAR. Conduct a meeting attended by the Quality Control Manager, the OAR, superintendent, other quality control personnel as applicable, and the foreman responsible for the Work task. Instruct applicable workers as to the acceptable level of workmanship required in order to meet the requirements of the Contract Documents. Document the results of the preparatory phase actions by separate meeting minutes prepared by the Quality Control Manager and attached to the quality control report. Do not move to the next phase unless results of investigations required for the planning phase indicate that requirements have been met. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-96 Rev 5/2024 2. Work Phase: Complete this phase after the Planning Phase: a. Notify the OAR at least 24 hours in advance of beginning the Work and discuss the review of the planning effort to indicate that requirements have been met. b. Check the Work to ensure that it is in full compliance with the Contract Documents. c. Verify adequacy of controls to ensure full compliance with Contract Documents. Verify required control inspection and testing is performed. d. Verify that established levels of workmanship meet acceptable workmanship standards. Compare with required Sample panels as appropriate. e. Repeat the Work phase for each new crew to work on -site or any time acceptable specified quality standards are not being met. 3. Follow-up Phase: Perform daily checks to assure control activities, including control testing, are providing continued compliance with contract requirements: a. Make checks daily and record observations in the quality control documentation. b. Conduct follow-up checks and correct all deficiencies prior to the start of additional Work tasks that may be affected by the Defective Work. Do not build upon nor conceal Defective Work. c. Conduct a review of the Work with the OPT one month prior to the expiration of the correction period. Correct defects as noted during the review. C. Conduct additional planning and Work phases if: 1. The quality of on -going Work is unacceptable; 2. Changes are made in applicable quality control staff, on -site production supervision or crews; 3. Work on a task is resumed after a substantial period of inactivity; or 4. Other quality problems develop. ARTICLE 22 — FINAL RESOLUTION OF DISPUTES 22.01 Senior Level Negotiations A. Each party is required to continue to perform its obligations under the Contract Documents pending the final resolution of any dispute arising out of or relating to the Contract Documents, unless it would be impossible or impractical under the circumstances then present. B. All negotiations pursuant to Article 22 are confidential and shall be treated as compromise and settlement negotiations for purposes of applicable rules of evidence. C. Before invoking mediation, Owner and Design -Builder agree that they first shall try to resolve any dispute arising out of or related to the Contract Documents through discussions directly between those senior management representatives within their respective organization who have overall managerial responsibility for similar projects. Owner and Design -Builder agree that this step shall be a condition precedent to the use of any other alternative dispute resolution process. If the parties' senior management representatives cannot resolve the General Conditions — Design/Build (LS) Corpus Christi Standards 007200-97 Rev 5/2024 dispute within 60 calendar days after a party delivers a written notice of appeal of a claim under Article 13, the parties shall proceed with mediation. 22.02 Mediation A. In the event that Owner and/or Design/Builder contend that the other has committed a material breach of the Contract or the parties cannot reach a resolution of a claim or dispute pursuant to Paragraph 22.01, as a condition precedent to filing a lawsuit, either party may request mediation of the dispute with the following requirements: 1. The request for mediation shall be in writing and shall request that the mediation commence not less than 30 calendar days or more than 120 calendar days following the date of the request, except upon agreement of the parties. 2. In the event Owner and Design/Builder are unable to agree to a date for the mediation or to the identity of the mediator within 30 calendar days following the date of the request for mediation, all conditions precedent shall be deemed to have occurred. 3. Owner and Design/Builder are to each pay one-half of the mediator's fees and costs. Venue for any mediation or lawsuit filed under this Contract shall be in Nueces County, Texas. Any agreement reached in mediation shall be enforceable as a settlement in any court having jurisdiction thereof. 4. Nothing in this Contract shall be construed as consent to a lawsuit. No provision of the Contract shall waive any immunity or defense. ARTICLE 23 — MINORITY/MBE/DBE PARTICIPATION POLICY 23.01 Policy A. It is the policy of the City of Corpus Christi that maximum opportunity is afforded minorities, women, low income persons and Minority/Disadvantaged Business Enterprises (M/DBE) to participate in the performance of contracts awarded by the City of Corpus Christi in support of Equal Employment Opportunity goals and objectives. In accordance with such policy, the City has established goals, as stated herein, both for minority and female participation by trade and for Minority Business Enterprise. 23.02 Definitions A. Minority/Disadvantaged Business Enterprise: A business enterprise that is owned and controlled by one or more minority person(s) or socially and economically disadvantaged individual(s). Minority/Disadvantaged person(s) must collectively own, operate and/or actively manage, and share in payments from such an enterprise in the manner hereinafter set forth: 1. Owned: a. For a sole proprietorship to be deemed a minority business enterprise, it must be owned by a minority person. b. For an enterprise doing business as a partnership, at least 51 percent of the assets or interest in the partnership property must be owned by one or more minority person(s). General Conditions — Design/Build (LS) Corpus Christi Standards 007200-98 Rev 5/2024 c. For an enterprise doing business as a corporation, at least 51 percent of the assets or interest in the corporate shares must be owned by one or more minority person(s). 2. Controlled: a. The primary power, direct or indirect, to manage a business enterprise rests with a minority person(s). 3. Share in Payments: a. Minority partners, proprietors, or stockholders of the business enterprise must be entitled to receive 51 percent or more of the total profits, bonuses, dividends, interest payments, commissions, consulting fees, rents, procurement, and subcontract payments, and any other monetary distribution paid by the business enterprise. B. Minority: Minority persons include Blacks, Mexican -Americans and other persons of Hispanic origin, American Indians, Alaskan Natives, and Asians or Pacific Islanders. For the purposes of this policy, women are also considered as minorities. C. Socially and economically disadvantaged individual: Any individual who is a citizen (or lawfully admitted permanent resident) of the United States and who has been subjected to racial or ethnic prejudice or cultural bias within American society because of his or her identity as a member of a group and without regard to his or her individual qualities. The social disadvantage must stem from circumstances beyond the individual's control. D. Female Owned Business Enterprise: A sole proprietorship that is owned and controlled by a woman, a partnership at least 51 percent of whose assets or partnership interests are owned by one or more women, or a corporation at least 51 percent of whose assets or interests in the corporate shares are owned by one or more women. E. Joint Venture: A joint venture means an association of two or more persons, partnerships, corporations, or any combination thereof, founded to carry on a single business activity which is limited in scope and direction. The degree to which a joint venture may satisfy the stated MBE goal cannot exceed the proportionate interest of the MBE as a member of the joint venture in the Work to be performed by the joint venture. For example, a joint venture which is to perform 50 percent of the Work itself and in which a minority joint venture partner has a 50 percent interest, shall be deemed equivalent to having minority participation in 25 percent of the Work. Minority members of the joint venture must have financial, managerial, or technical skills in the Work to be performed by the joint venture. 23.03 Goals A. The goals for participation by minorities and Minority Business Enterprises expressed in percentage terms for the Design/Builder's aggregate work force on all construction Work for the Contract award shall be: 1. Minority participation goal is 45%. 2. Minority Business Enterprise participation goal is 15%. B. These goals are applicable to all the construction work (regardless of federal participation) performed under the Contract Documents, including approved Change Orders. The hours of General Conditions — Design/Build (LS) Corpus Christi Standards 007200-99 Rev 5/2024 minority employment must be substantially uniform throughout the length of the Contract and in each trade. The transfer of minority employees from contractor to contractor or from project to project for the sole purpose of meeting the Design/Builder's percentage is prohibited. 23.04 Compliance A. Upon completion of the Project, a final breakdown of MBE participation, substantiated by copies of paid invoices, shall be submitted by the Design/Builder to the OAR. B. Make bi-weekly payroll submittals to the OAR. The Design/Builder is to indicate the percent of minority and female participation, by trade, which has been utilized on the Project. Along with the request for final payment on the Project, the Design/Builder will indicate, in writing, the overall participation in these areas which have been achieved. The OAR may withhold monthly or final payments to the Design/Builder for failure to submit bi-weekly payrolls in a timely fashion or to submit overall participation information as required. ARTICLE 24 — DOCUMENT MANAGEMENT 24.01 Work Included A. Submit documentation as required by the Contract Documents and as reasonably requested by the OPT. 24.02 Quality Assurance A. Submit legible, accurate, complete documents presented in a clear, easily understood manner. Documents not meeting these criteria will be returned without review. 24.03 Design/Builder's Responsibilities A. Review documents prior to submitting. Make certifications as required by the Contract Documents and as indicated on forms provided. B. Provide a Schedule of Documents to list the documents that are to be submitted. C. Incorporate the dates for processing documents into the Progress Schedule required by Article 27. 1. Provide documents in accordance with the schedule so construction of the Project is not delayed. 2. Allow a reasonable time for the review of documents when preparing the Progress Schedule. 3. Schedule submittal of documents to provide all information for interrelated Work at one time. 4. Allow adequate time for processing documents so construction of the Project is not delayed. 24.04 Document Submittal A. Submit documents through the OAR. Send all documents in digital format for processing. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-100 Rev 5/2024 1. Submit all documents in Portable Document Format (PDF). a. Create PDF documents from native format files unless files are only available from scanned documents. b. Rotate pages so that the top of each document appears at the top of the monitor screen when opened in PDF viewing software. c. Submit PDF document with adequate resolution to allow documents to be printed in a format equivalent to the document original. Documents are to be scalable to allow printing on standard 8-1/2 x 11 or 11 x 17 paper. d. Submit color PDF documents where color is required to interpret the document. e. Create or convert documents to allow text to be selected for comments or searched using text search features. Run scanned documents through Optical Character Recognition (OCR) software if necessary. f. Flatten markups in documents to prevent markups made by Design/Builder from being moved or deleted. Flatten documents to allow markup recovery. Use software to reduce file size using default settings except the option for "Drop Metadata." Uncheck the "Drop Metadata" box when reducing file size. h. Add footers to each document with the Project name. 24.05 Document Numbering A. Assign a number to the documents originated to allow tracking of the documents during the review process. 1. Assign the number consisting of a prefix, a sequence number, and a letter suffix. Prefixes shall be as follows: g• Prefix Description Originator AP Application for Payment Design/Builder CO Change Order OAR CP Change Proposal Design/Builder CTR Certified Test Report Design/Builder FO Field Order OAR NBC Notification by Design/Builder Design/Builder PD Photographic Documentation Design/Builder RCP Request fora Change Proposal OAR RD Record Data Design/Builder RFI Request for Information Design/Builder SD Shop Drawing Design/Builder SCH Schedule of Progress Design/Builder 2. Issue sequence numbers in chronological order for each type of document. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-101 Rev 5/2024 3. Issue numbers for resubmittals that have the same number as the original document followed by an alphabetical suffix indicating the number of times the same document has been sent to the OAR for processing. For example: SD 025 A represents Shop Drawing number 25 and the letter "A" designates that this is the second time this document has been sent for review. 4. Clearly note the document number on each page or sheet of the document. 5. Correct assignment of numbers is essential since different document types are processed in different ways. B. Include reference to the Drawing number and/or Specification Section, detail designation, schedule, or location that corresponds with the data on the document transmittal forms. Other identification may also be required, such as layout drawings or schedules to allow the reviewer to determine where a particular product is to be used. 24.06 Document Requirements A. Furnish documents as indicated below or in individual Specification Sections. Submit documents per the procedures described in the Contract Documents. B. Submit documents per the Specification Section shown in the following table: Document Type Section Application for Payment Article 17 Change Proposal Article 12 Certified Test Report Article 25 for approval of product Article 21 to demonstrate compliance Notification by Design/Builder Article 20 Photographic Documentation Article 28 Progress Schedules Article 27 Record Data Article 26 Request for Information Article 20 Shop Drawing Article 25 Schedule of Values Article 17 Substitutions Article 11 Suppliers and Subcontractors Articles 20 and 26 ARTICLE 25 — SHOP DRAWINGS 25.01 Work Included A. Shop Drawings are required for those products that cannot adequately be described in the Contract Documents to allow fabrication, erection, or installation of the product without additional detailed information from the Supplier. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-102 Rev 5/2024 B. Submit Shop Drawings as required by the Contract Documents and as reasonably requested by the OPT to: 1. Record the products incorporated into the Project for the Owner; 2. Provide detailed information for the products proposed for the Project regarding their fabrication, installation, commissioning, and testing; and C. Design/Builder's responsibility for full compliance with the Contract Documents is not relieved by the review of Shop Drawings, Samples, or mockups. Contract modifications can only be approved by Change Order or Field Order. 25.02 Quality Assurance A. Submit legible, accurate and complete documents presented in a clear, easily understood manner. Shop Drawings not meeting these criteria will be rejected. B. Demonstrate that the proposed products are in full and complete compliance with the design criteria and requirements of the Contract Documents or will be if deviations requested per Paragraph 25.10 are approved. C. Furnish and install products that fully comply with the information included in the document submittal. 25.03 Design/Builder's Responsibilities A. Provide Shop Drawings in accordance with Schedule of Documents required by Article 24. B. Include Shop Drawings in the Schedule of Documents required by Article 24 to indicate the Shop Drawings to be submitted and proposed dates that the product will be incorporated into the Project. C. Incorporate the dates for processing Shop Drawings into the Progress Schedule required by Article 27. 1. Submit Shop Drawings in accordance with the schedule so construction of the Project is not delayed. 2. Schedule document submittals to provide all information for interrelated Work at one time. 3. Allow adequate time for ordering, fabricating, delivering, and installing product so construction of the Project is not delayed. D. Complete the following before submitting a Shop Drawing or Sample: 1. Prepare Shop Drawing Review and coordinate the Shop Drawing or Sample with other Shop Drawings and Samples and with the requirements of the Work and the Contract Documents; 2. Determine and verify specified performance and design criteria, installation requirements, materials, catalog numbers, and similar information with respect to Shop Drawings and Samples; 3. Determine and verify the suitability of materials and equipment offered with respect to the indicated application, fabrication, shipping, handling, storage, assembly, and installation pertaining to the performance of the Work; and General Conditions — Design/Build (LS) Corpus Christi Standards 007200-103 Rev 5/2024 4. Determine and verify information relative to Design/Builder's responsibilities for means, methods, techniques, sequences, and procedures of construction, and safety precautions and programs incident thereto. E. Determine and verify: 1. Accurate field measurements, quantities, and dimensions are shown on the Shop Drawings; 2. Location of existing structures, utilities, and equipment related to the Shop Drawing have been shown and conflicts between the products existing structures, utilities, and equipment have been identified; 3. Conflicts that impact the installation of the products have been brought to the attention of the OPT; 4. Shop Drawings are complete for their intended purpose; and 5. Conflicts between the Shop Drawings related to the various Subcontractors and Suppliers have been resolved. F. Review Shop Drawings prior to submitting to the OAR. Certify that all Shop Drawings have been reviewed by the Design/Builder and are in strict conformance with the Contract Documents as modified by Addenda, Change Order, Field Order, or Contract Amendment when submitting Shop Drawings except for deviations specifically brought to the OPT's attention on an attached Shop Drawing Deviation Request form in accordance with Paragraph 25.09. G. Fabrication or installation of any products prior to the approval of Shop Drawings is done at the Design/Builder's risk. Defective products may be rejected at the Owner's option. H. Payment will not be made for products for which Shop Drawings or Samples are required until these are reviewed by the OAR. 25.04 Shop Drawing Requirements A. Provide adequate information in Shop Drawings and Samples so Owner can: 1. Select colors, textures or other aesthetic features. 2. Compare the proposed features of the product with the specified features and to ensure that the product does, in general, conform to the Contract Documents. 3. Compare the performance features of the proposed product with those specified to ensure that the product does, in general, conform to the performance criteria specified in the Contract Documents. 4. Review required certifications, guarantees, warranties, and service agreements for compliance with the Contract Documents. B. Include a complete description of the product to be furnished, including: 1. Type, dimensions, size, arrangement, and operational characteristics of the product; 2. Weights, gauges, materials of construction, external connections, anchors, and supports required; 3. All applicable standards such as ASTM or Federal specification numbers; General Conditions — Design/Build (LS) Corpus Christi Standards 007200-104 Rev 5/2024 4. Fabrication and installation drawings, setting diagrams, manufacturing instructions, templates, patterns, and coordination drawings; 5. Mix designs for concrete, asphalt, or other materials proportioned for the Project; and 6. Complete and accurate field measurements for products which must fit existing conditions. Indicate on the document submittal that the measurements represent actual dimensions obtained at the Site. C. Submit Shop Drawings that require coordination with other Shop Drawings at the same time. Shop Drawings requiring coordination with other Shop Drawings will be rejected until a complete package is submitted. 25.05 Special Certifications and Reports A. Provide all required certifications with the Shop Drawings as specified in the individual Specification Sections: 1. Certified Test Reports (CTR): A report prepared by an approved testing agency giving results of tests performed on products to indicate their compliance with the Specifications. This report is to demonstrate that the product when installed will meet the requirements and is part of the Shop Drawing. Field tests may be performed by the Owner to determine that in place materials or products meet the same quality as indicated in the CTR submitted as part of the Shop Drawing. 2. Certification of Local Field Service (CLS): A certified letter stating that field service is available from a factory or supplier approved service organization located within a 300 mile radius of the Site. List names, addresses, and telephone numbers of approved service organizations on or attach it to the certificate. 3. Certification of Adequacy of Design (CAD): A certified letter from the manufacturer of the equipment stating that they have designed the equipment to be structurally stable and to withstand all imposed loads without deformation, failure, or adverse effects to the performance and operational requirements of the unit. The letter shall state that mechanical and electrical equipment is adequately sized to be fully operational for the conditions specified or normally encountered by the product's intended use. 25.06 Warranties and Guarantees A. Provide all required warranties, guarantees, and related documents with the Shop Drawing. The effective date of warranties and guarantees will be the date of acceptance of the Work by the Owner. B. Identify all Extended Warranties, defined as any guarantee of performance for the product or system beyond the 1-year correction period described in the General Conditions. Issue the warranty certificate in the name of the Owner. Provide a Warranty Bond for Extended Warranties if required by Contract Documents. C. Provide a copy of all warranties in a separate document in accordance with Article 29. 25.07 Shop Drawing Submittal Procedures A. Submit Shop Drawings to the OAR. Send all documents in digital format for processing. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-105 Rev 5/2024 1. Provide all information requested in the Shop Drawing submittal form. Do not leave any blanks incomplete. If information is not applicable, enter NA in the space provided. The Shop Drawing submittal form is to be the first document in the file submitted. 2. Submit all documents in Portable Document Format (PDF). a. Create PDF documents from native format files unless files are only available from scanned documents. b. Rotate pages so that the top of each document appears at the top of the monitor screen when opened in PDF viewing software. c. Submit PDF document with adequate resolution to allow documents to be printed in a format equivalent to the document original. Documents are to be scalable to allow printing on standard 8-1/2 x 11 or 11 x 17 paper. d. Submit color PDF documents where color is required to interpret the Shop Drawing. Submit Samples and color charts per Paragraph 25.08.A. e. Create or convert documents to allow text to be selected for comments or searched using text search features. Run scanned documents through Optical Character Recognition (OCR) software if necessary. f. Flatten markups in documents to prevent markups made by Design/Builder from being moved or deleted. Flatten documents to allow markup recovery. g. Use software to reduce file size using default settings except the option for "Drop Metadata." Uncheck the "Drop Metadata" box when reducing file size. h. Add footers to each document with the Project name. 3. Submit each specific product or class of material separately so these can be tracked and processed independently. Do not submit Shop Drawings for more than one product in the same Shop Drawing. 4. Submit items specified in the Contract Documents separately unless they are part of an integrated system. 5. Define abbreviations and symbols used in Shop Drawings. a. Use terms and symbols in Shop Drawings consistent with the Contract Drawings. b. Provide a list of abbreviations and their meaning as used in the Shop Drawings. c. Provide a legend for symbols used on Shop Drawings. 6. Mark Shop Drawings to reference: a. Related Specification Sections, b. Drawing number and detail designation, c. Product designation or name, d. Schedule references, e. System into which the product is incorporated, and f. Location where the product is incorporated into the Project. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-106 Rev 5/2024 B. Use the following conventions to markup Shop Drawings for review: 1. Make comments and corrections in the color blue. Add explanatory comments to the markup. 2. Highlight items in black that are not being furnished when the Supplier's standard drawings or information sheets are provided so that only the products to be provided are in their original color. 3. Make comments in the color yellow where selections or decisions are required, but such selections do not constitute a deviation from the Contract Documents. Add explanatory comments to the markup to indicate the action to be taken. 4. Make comments in the color orange that are deviation requests. Include the deviation request number on the Shop Drawing that corresponds to the deviation request on the Shop Drawing Deviation Request form. Include explanatory comments in the Shop Drawing Deviation Request form. 5. Mark dimensions with the prefix FD to indicate field verified dimensions on the Shop Drawings. C. Submit a Change Proposal per Article 12 to request modifications to the Contract Documents, including those for approval of "or equal" products when specifically allowed by the Contract Documents or as a substitution for specified products or procedures. D. Designate a Shop Drawing as requiring priority treatment in the comment section of the Shop Drawing submittal form to place the review of the Shop Drawing ahead of other Shop Drawings previously delivered. Shop Drawings are typically reviewed in the order received unless Design/Builder requests that a different priority be assigned. Priority Shop Drawings will be reviewed before other Shop Drawings for this Project already received but not yet reviewed. Use of this priority designation for Shop Drawings may delay the review of Shop Drawings previously submitted, pushing the processing of Shop Drawings beyond the 14-day target. Design/Builder is responsible for delays resulting from the use of the priority designation status on Shop Drawings. E. Complete the certification required by Paragraph 25.03. 25.08 Sample and Mockup Submittal Procedures A. Submit color charts and Samples for every product requiring color, texture, or finish selection. 1. Submit color charts and Samples only after Shop Drawings for the products have been approved. 2. Deliver all color charts and Samples at one time. 3. Provide Samples of adequate size to clearly illustrate the functional characteristics of the product, with integrally related parts and attachment devices. 4. Indicate the full range of color, texture, and patterns. 5. Deliver color charts and Samples to the field office and store for the duration of the Project General Conditions — Design/Build (LS) Corpus Christi Standards 007200-107 Rev 5/2024 6. Notify the OAR that color charts and Samples have been delivered for approval using the Notification by Design/Builder form. 7. Submit color charts and Samples not less than 30 days prior to when these products are to be ordered or released for fabrication to comply with the Project schedule. 8. Remove Samples that have been rejected. Submit new Samples following the same process as for the initial Sample until Samples are approved. 9. Dispose of Samples when related Work has been completed and approved and disposal is approved by the OAR. At Owner's option, Samples will become the property of the Owner. B. Construct mockups for comparison with the Work being performed. 1. Construct mockups from the actual products to be used in construction per detailed Specification Sections. 2. Construct mockups of the size and in the area indicated in the Contract Documents. 3. Construct mockups complete with texture and finish to represent the finished product. 4. Notify the OAR that mockups have been constructed and are ready for approval using the Notification by Design/Builder form. Allow 2 weeks for OPT to approve of the mockup before beginning the Work represented by the mockup. 5. Remove mockups that have been rejected. Construct new mockups following the same process as for the initial mockup until mockup is approved. 6. Protect mockups until Work has been completed and accepted by the OPT. 7. Dispose of mockups when related Work has been completed and disposal is approved by the OAR. 25.09 Equal Non Specified Products A. Design/Builder may submit other manufacturers' products that are in full compliance with the Specification where Specifications list one or more manufacturers followed by the phase "or equal" or "or approved equal." 1. Submit a Shop Drawing as required by this article to document that the proposed product is equal or superior to the specified product. 2. Prove that the product is equal. It is not the OPT's responsibility to prove the product is not equal. a. Indicate on a point by point basis for each specified feature that the product is equal to the Contract Document requirements. b. Make a direct comparison with the specified manufacturer's published data sheets and available information. Provide this printed material with the Shop Drawing. c. The decision of the OPT regarding the acceptability of the proposed product is final. 3. Provide a typewritten certification that, in furnishing the proposed product as an equal, the Design/Builder: General Conditions — Design/Build (LS) Corpus Christi Standards 007200-108 Rev 5/2024 a. Has thoroughly examined the proposed product and has determined that it is equal or superior in all respects to the product specified. b. Has determined that the product will perform in the same manner and result in the same process as the specified product. c. Will provide the same warranties and/or bonds as for the product specified. d. Will assume all responsibility to coordinate any modifications that may be necessary to incorporate the product into the construction and will waive all claims for additional Work which may be necessary to incorporate the product into the Project which may subsequently become apparent. e. Will maintain the same time schedule as for the specified product. 25.10 Requests for Deviation A. Submit requests for deviation from the Contract Documents for any product that does not fully comply with the Contract Documents. B. Submit requests for deviation using the Shop Drawing Deviation Request form provided. Identify each deviation request as a separate item. Include all requested deviations that must be approved as a group together and identify them as a single item. C. Include a description of why the deviation is required and the impact on Contract Price or Contract Times. Include the amount of any cost savings to the Owner for deviations that result in a reduction in cost. D. Submit as a Change Proposal prior to submitting the Shop Drawing if the deviation will result in a change in Contract Price or Contract Times. E. A Modification must be issued by the OAR for approval of a deviation. Approval of a requested Shop Drawing deviation by the OAR on the Shop Drawings Deviation Request form indicates approval of the requested deviation only on its technical merits as generally conforming to the Contract Documents. Deviations from the Contract Documents can only be approved by a Modification. 25.11 OAR Responsibilities A. Shop Drawings will be received by the OAR. OAR will log the documents and review per this Article for general conformance with the Contract Documents. 1. OAR's review and approval will be only to determine if the products described in the Shop Drawing or Sample will, after installation or incorporation into the Work, conform to the information given in the Contract Documents and be compatible with the design concept of the completed Project as a functioning whole as indicated by the Contract Documents. 2. OAR's review and approval will not extend to means, methods, techniques, sequences, or procedures of construction or to safety precautions or programs incident thereto. 3. OAR's review and approval of a separate item as such will not indicate approval of the assembly in which the item functions. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-109 Rev 5/2024 25.12 Resubmission Requirements A. Make all corrections or changes in the documents required by the OAR and resubmit. 1. Revise initial drawings or data and resubmit as specified for the original document. 2. Highlight or cloud in green those revisions which have been made in response to the previous reviews. This will include changes previously highlighted or clouded in yellow to direct attention to items requiring selections or decisions by the OAR or highlighted or clouded in orange for a requested deviation from the Contract Documents. 3. Highlight and cloud new items in yellow where selections or decisions are required, but such selections do not constitute a deviation from the Contract Documents. Add explanatory comments to the markup to indicate the action to be taken. 4. Highlight and cloud new items in orange that are deviation requests. Include the deviation request number on the Shop Drawing that corresponds to the deviation request on the Shop Drawing Deviation Request form. Numbering for these new items is to start with the next number following the last Shop Drawing deviation requested. Include explanatory comments in the Shop Drawing Deviation Request form. B. Pay for excessive review of Shop Drawings. 1. Excessive review of Shop Drawings is defined as any review required after the original review has been made and the first resubmittal has been checked to see that corrections have been made. 2. Review of Shop Drawings or Samples will be an additional service requiring payment by the Design/Builder if the Design/Builder submits a substitution for a product for which a Shop Drawing or Sample has previously been approved, unless the need for such change is beyond the control of Design/Builder. 3. A Set-off will be included in each Application for Payment to pay costs for the additional review by the Owner on a monthly basis. 4. Need for more than one resubmission or any other delay for review of Shop Drawings will not entitle the Design/Builder to an adjustment in Contract Price or an extension of Contract Times. ARTICLE 26 — RECORD DATA 26.01 Work Included A. Submit Record Data as required by the Contract Documents and as reasonably requested by the OPT. Provide Record Data for all products unless a Shop Drawing is required for the same item. B. Submit Record Data to provide documents that allow the Owner to: 1. Record the products incorporated into the Project for the Owner; 2. Review detailed information about the products regarding their fabrication, installation, commissioning, and testing; and 3. Provide replacement or repair of the products at some future date. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-110 Rev 5/2024 C. Design/Builder's responsibility for full compliance with the Contract Documents is not relieved by the receipt or cursory review of Record Data. Contract modifications can only be approved by Change Order or Field Order. D. Provide various reports or other documents that Contract Documents require for record purposes. 26.02 Quality Assurance A. Submit legible, accurate, and complete documents presented in a clear, easily understood manner. Record Data not meeting these criteria will be rejected. 26.03 Design/Builder's Responsibilities A. Submit Record Data in accordance with Schedule of Documents required by Article 24. B. Include Record Data in the Schedule of Documents required by Article 24 to indicate the Record Data to be submitted, the dates on which documents are to be sent to the OAR for review, and proposed dates that the product will be incorporated into the Project. C. Complete the following before submitting Record Data: 1. Prepare Record Data and coordinate with Shop Drawings or Samples, other Record Data, and with the requirements of the Work and the Contract Documents; 2. Determine and verify specified performance and design criteria, installation requirements, materials, catalog numbers, and similar information; 3. Determine and verify the suitability of materials and equipment offered with respect to the indicated application, fabrication, shipping, handling, storage, assembly, and installation pertaining to the performance of the Work; and 4. Determine and verify information relative to Design/Builder's responsibilities for means, methods, techniques, sequences, and procedures of construction, and safety precautions and programs incident thereto. D. Determine and verify: 1. Accurate field measurements, quantities, and dimensions are shown on the Record Data; 2. Location of existing structures, utilities, and equipment related to the Record Data have been shown and conflicts between the products existing structures, utilities, and equipment have been identified; 3. Conflicts that impact the installation of the products have been brought to the attention of the OPT; 4. Record Data are complete for their intended purpose; and 5. Conflicts between the Record Data related to the various Subcontractors and Suppliers have been resolved. E. Review Record Data prior to submitting to the OAR. Certify that all Record Data has been reviewed by the Design/Builder and is in strict conformance with the Contract Documents as modified by Addenda, Change Order, Field Order, or Contract Amendment when submitting Record Data. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-111 Rev 5/2024 26.04 Record Data Requirements A. Include a complete description of the material or equipment to be furnished, including: 1. Type, dimensions, size, arrangement, model number, and operational parameters of the components; 2. Weights, gauges, materials of construction, external connections, anchors, and supports required; 3. All applicable standards such as ASTM or Federal specification numbers; 4. Fabrication and installation drawings, setting diagrams, manufacturing instructions, templates, patterns, and coordination drawings; 5. Mix designs for concrete, asphalt or other materials proportioned for the Project; and 6. Complete and accurate field measurements for products which must fit existing conditions. Indicate on the document submittal that the measurements represent actual dimensions obtained at the Site. 26.05 Special Certifications and Reports A. Provide all required certifications with the Record Data as specified in the individual Specification Sections: 1. Certified Test Reports (CTR): A report prepared by an approved testing agency giving results of tests performed on products to indicate their compliance with the Specifications. This report is to demonstrate that the product when installed will meet the requirements and is part of the Record Data. Field tests may be performed by the Owner to determine that in place materials or products meet the same quality as indicated in the CTR submitted as part of the Record Data. 26.06 Warranties and Guarantees A. Provide all required warranties, guarantees, and related documents with the Record Data. The effective date of warranties and guarantees will be the date of acceptance of the Work by the Owner. B. Identify all Extended Warranties, defined as any guarantee of performance for the product or system beyond the 1 year correction period described in the General Conditions. Issue the warranty certificate in the name of the Owner. Provide a Warranty Bond for Extended Warranties if required. C. Provide a copy of all warranties in a separate document in accordance with Article 29. 26.07 Record Data Submittal Procedures A. Submit Record Data through the OAR. Send all documents in digital format for processing. 1. Provide all information requested in the Record Data submittal form. Do not leave any blanks incomplete. If information is not applicable, enter NA in the space provided. The Record Data submittal form is to be the first document in the file. 2. Submit all documents in Portable Document Format (PDF). General Conditions — Design/Build (LS) Corpus Christi Standards 007200-112 Rev 5/2024 a. Create PDF documents from native format files unless files are only available from scanned documents. b. Rotate pages so that the top of each document appears at the top of the monitor screen when opened in PDF viewing software. c. Submit PDF document with adequate resolution to allow documents to be printed in a format equivalent to the document original. Documents are to be scalable to allow printing on standard 8-1/2 x 11 or 11 x 17 paper. d. Submit color PDF documents where color is required to interpret the Record Data. e. Create or convert documents to allow text to be selected for comments or searched using text search features. Run scanned documents through Optical Character Recognition (OCR) software if necessary. f. Flatten markups in documents to prevent markups made by Design/Builder from being moved or deleted. Flatten documents to allow markup recovery. Use software to reduce file size using default settings except the option for "Drop Metadata." Uncheck the "Drop Metadata" box when reducing file size. h. Add footers to each document with the Project name. 3. Submit each specific product, class of material, or product separately so these can be tracked and processed independently. Do not submit Record Data for more than one system in the same Record Data. g• 4. Submit items specified in different Specification Sections separately unless they are part of an integrated system. 5. Define abbreviations and symbols used in Record Data. a. Use terms and symbols in Record Data consistent with the Contract Drawings. b. Provide a list of abbreviations and their meaning as used in the Record Data. c. Provide a legend for symbols used on Record Data. 6. Mark Record Data to reference: a. Related Specification Sections, b. Drawing number and detail designation, c. Product designation or name, d. Schedule references, e. System into which the product is incorporated, and f. Location where the product is incorporated into the Project. B. Submit a Change Proposal per Article 12 to request modifications to the Contract Documents, including those for approval of "or equal" products when specifically allowed by the Contract Documents or as a substitution for specified products or procedures. Deviations from the Contract Documents can only be approved by a Modification. C. Complete the certification required by Paragraph 26.03. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-113 Rev 5/2024 26.08 OAR's Responsibilities A. Record Data will be received by the OAR, logged, and provided to Owner as the Project record. 1. Record Data may be reviewed to see that the information provided is adequate for the purpose intended. Record Data not meeting the requirements of Paragraph 26.02 may be rejected as unacceptable. 2. Record Data is not reviewed for compliance with the Contract Documents. Comments may be returned if deviations from the Contract Documents are noted during the cursory review performed to see that the information is adequate. 3. Design/Builder's responsibility for full compliance with the Contract Documents is not relieved by the review of Record Data. Contract modifications can only be approved by a Modification. B. OAR may take the following action in processing Record Data: 1. File Record Data as received if the cursory review indicates that the document meets the requirements of Paragraph 26.02. Document will be given the status of "Filed as Received" and no further action is required on that Record Data. 2. Reject the Record Data for one of the following reasons: a. The document submittal requirements of the Contract Documents indicate that the document submitted as Record Data should have been submitted as a Shop Drawing. The Record Data will be marked "Rejected" and "Submit Shop Drawing." No further action is required on this document as Record Data and the Record Data process will be closed. Resubmit the document as a Shop Drawing per Article 25. b. The cursory review indicates that the document does not meet the requirements of Paragraph 26.02. The Record Data will be marked "Rejected" and "Revise and Resubmit." Design/Builder is to resubmit the Record Data until it is acceptable and marked "Filed as Received." When Record Data is filed, no further action is required, and the Record Data process will be closed. c. The Record Data is not required by the Contract Documents nor is the Record Data applicable to the Project. The Record Data will be marked "Rejected" and "Cancel - Not Required." No further action is required, and the Record Data process will be closed. C. Design/Builder is to resubmit the Record Data until it is acceptable and marked "Filed as Received." ARTICLE 27 — PROGRESS SCHEDULE 27.01 Requirements A. Prepare and submit a Progress Schedule for the Work and update the schedule on a monthly basis for the duration of the Project. B. Provide schedule in adequate detail to allow Owner to monitor progress and to relate document processing to sequential activities of the Work. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-114 Rev 5/2024 C. Incorporate and specifically designate the dates of anticipated submission of documents and the dates when documents must be returned to the Design/Builder into the schedule. D. Assume complete responsibility for maintaining the progress of the Work per the schedule submitted. E. Schedule Work based upon a six day work week. 27.02 Document Submittal A. Submit Progress Schedules in accordance with Article 24. B. Submit a preliminary schedule within 10 days after the Notice of Award. The schedule is to be available at all project meetings. C. Submit a detailed schedule at least 10 days prior to the first payment request. D. Submit Progress Schedule updates monthly with Applications for Payment to indicate the progress made on the Project to that date. Failure to submit the schedule may cause delay in the review and approval of Applications for Payment. 27.03 Schedule Requirements A. Schedule is to be in adequate detail to: 1. Assure adequate planning, scheduling, and reporting during the execution of the Work; 2. Assure the coordination of the Work of the Design/Builder and the various Subcontractors and Suppliers; 3. Assist in monitoring the progress of the Work; and 4. Assist in evaluating proposed changes to the Contract Times and Project schedule. B. Provide personnel with 5 years' minimum experience in scheduling construction work comparable to this Project. Prepare the schedule using acceptable scheduling software. C. Provide the schedule in the form of a computer generated critical path schedule which includes Work to be performed on the Project. It is intended that the schedule accomplish the following: 1. Give early warning of delays in time for correction. 2. Provide detailed plans for the execution of the Work in the form of future activities and events in sequential relationships. 3. Establish relationships of significant planned Work activities and provide a logical sequence for planned Work activities. 4. Provide continuous current status information. 5. Allow analysis of the Design/Builder's program for the completion of the Project. 6. Permit schedules to be revised when the existing schedule is not achievable. 7. Log the progress of the Work as it actually occurs. D. Prepare a time scaled CPM arrow or precedence diagram to indicate each activity and its start and stop dates. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-115 Rev 5/2024 1. Develop Milestone dates and Project completion dates to conform to time constraints, sequencing requirements and Contract completion date. 2. Use calendar day durations while accounting for holidays and weather conditions in the projection of the duration of each activity. 3. Clearly indicate the critical path for Work to complete the Project. E. Provide a time scaled horizontal bar chart which indicates graphically the Work scheduled at any time during the Project. The chart is to indicate: 1. Complete sequence of Work by activity; 2. Identification of the activity by structure, location, and type of Work; 3. Chronological order of the start of each item of Work; 4. The activity start and stop dates; 5. The activity duration; 6. Successor and predecessor relationships for each activity; 7. A clearly indicated single critical path; and 8. Projected percentage of completion, based on dollar value of the Work included in each activity as of the first day of each month. F. Provide a schedule incorporating the Schedule of Documents provided in accordance with Article 24 indicating: 1. Specific date each document is to be delivered to the OAR. 2. Specific date each document must be received in order to meet the proposed schedule. 3. Allow a reasonable time to review documents, taking into consideration the size and complexity of the document, other documents being processed, and other factors that may affect review time. 4. Allow time for re -submission of each document. Design/Builder is responsible for delays associated with additional time required to review incomplete or erroneous documents and for time lost when documents are submitted for products that do not meet Specification requirements. 27.04 Schedule Revisions A. Revise the schedule if it appears that the schedule no longer represents the actual progress of the Work. 1. Submit a written report if the schedule indicates that the Project is more than 30 days behind schedule. The report is to include: a. Number of days behind schedule; b. Narrative description of the steps to be taken to bring the Project back on schedule; and c. Anticipated time required to bring the Project back on schedule. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-116 Rev 5/2024 2. Submit a revised schedule indicating the action that the Design/Builder proposes to take to bring the Project back on schedule. B. Revise the schedule to indicate any adjustments in Contract Times approved by Modification. 1. Include a revised schedule with Change Proposals if a change in Contract Times is requested. 2. OPT will deem any Change Proposal that does not have a revised schedule and request for a change in Contract Times as having no impact on the ability of the Design/Builder to complete the Project within the Contract Times. C. Updating the Project schedule to reflect actual progress is not considered a revision to the Project schedule. D. Applications for Payment may not be recommended for payment without a revised schedule and if required, the report indicating the Design/Builder's plan for bringing the Project back on schedule. 27.05 Float Time A. Define float time as the amount of time between the earliest start date and the latest start date of a chain of activities on the construction schedule. B. Float time is not for the exclusive use or benefit of either the Design/Builder or Owner. C. Where several subsystems each have a critical path, the subsystem with the longest time of completion is the critical path and float time is to be assigned to other subsystems. D. Contract Times cannot be changed by the submission of a schedule. Contract Times can only be modified by a Change Order or Contract Amendment. E. Schedule completion date must be the same as the Contract completion date. Time between the end of construction and the Contract completion date is float time. ARTICLE 28 — VIDEO AND PHOTOGRAPHIC DOCUMENTATION 28.01 Work Included A. Provide a video recording of the Site prior to the beginning of construction. 1. Record the condition of all existing facilities in or abutting the construction area (right- of-way) including but not limited to streets, curb and gutter, utilities, driveways, fencing, landscaping, etc. 2. Record after construction staking is complete but prior to any clearing. 3. Provide one copy of the recording, dated and labeled to the OAR before the start of construction. Provide additional recording as directed by the OAR if the recording provided is not considered suitable for the purpose of recording pre-existing conditions. B. Furnish an adequate number of photographs of the Site to clearly depict the completed Project. 1. Provide a minimum of ten different views. 2. Photograph a panoramic view of the entire Site. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-117 Rev 5/2024 3. Photograph all significant areas of completed construction. 4. Completion photographs are not to be taken until all construction trailers, excess materials, trash, and debris have been removed. 5. Employ a professional photographer approved by the OAR to photograph the Project. 6. Provide one aerial photograph of the Site from an angle and height to include the entire Site while providing adequate detail. C. All photographs, video recordings, and a digital copy of this media are to become the property of the Owner. Photographs or recordings may not be used for publication, or public or private display without the written consent of the Owner. 28.02 Quality Assurance A. Provide clear photographs and recordings taken with proper exposure. View photographs and recordings in the field and take new photographs or recordings immediately if photos of an adequate print quality cannot be produced or video quality is not adequate. Provide photographs with adequate quality and resolution to permit enlargements. 28.03 Document Submittal A. Submit photographic documentation as Record Data in accordance with Article 24. B. Submit the video recording as Record Data in accordance with Article 24. 28.04 Photographs A. Provide photographs in digital format with a minimum resolution of 1280 x 960, accomplished without a digital zoom. B. Take photographs at locations acceptable to the OAR. C. Provide two color prints of each photograph and a digital copy on a DVD of each photograph taken. D. Identify each print on back with: 1. Project name. 2. Date, time, location, and orientation of the exposure. 3. Description of the subject of photograph. E. Submit photographs in clear plastic sheets designed for photographs. Place only one photograph in each sheet to allow the description on the back to be read without removing the photograph. F. Final photographs are to include two 8-by-10-inch glossy color prints for each of ten photographs selected by the OAR. These photographs are in addition to normal prints. 28.05 Video Recording A. Provide digital format that can be played with Windows Media Player in common format in full screen mode. B. Identify Project on video by audio or visual means. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-118 Rev 5/2024 C. Video file size should not exceed 400 MB. D. Video resolution shall be 1080p. E. The quality of the video must be sufficient to determine the existing conditions of the construction area. Camera panning must be performed while at rest, do not pan the camera while walking or driving. Camera pans should be performed at intervals sufficient to clearly view the entire construction area. F. Recording shall be labeled with construction stationing and stationing should be called out, voice recorded, in the video. G. The entire construction area recording shall be submitted at once. Sections submitted separately will not be accepted. H. Pipeline projects should be recorded linearly from beginning to end. ARTICLE 29 — EXECUTION AND CLOSEOUT 29.01 Substantial Completion A. Notify OAR when Design/Builder considers the entire Work substantially complete and request a Certificate of Substantial Completion. B. OPT is to inspect the Work within 30 days after Design/Builder's notification to determine if the Work is substantially complete. OAR, within 120 days after receipt of Design/Builder's notification, is to either issue the Certificate of Substantial Completion which sets the date of Substantial Completion or notify Design/Builder of the reasons the Project is not considered to be substantially complete. Owner's issuance of the Certificate of Mechanical Completion is not material to the completion of the Work and is not a condition precedent to Design/Builder's performance under the Contract Documents. C. The OPT and Design/Builder are to meet to discuss Owner's use or occupancy of the Work following Substantial Completion. Items to be discussed at this meeting include: 1. Review of insurance policies with respect to the end of the Design/Builder's coverage, and confirm the transition to coverage of the Work under a permanent property insurance policy held by Owner; 2. Owner's assumption of responsibility for security, operation, protection of the Work, maintenance, and utilities upon Owner's use or occupancy of the Work; 3. Design/Builder's obligations for operations and maintenance during performance and acceptance testing; 4. Design/Builder's access to the Site to complete punch list items; and 5. Procedures for correction of Defective Work during the 1-year correction period. 29.02 Partial Utilization A. Owner may use or occupy substantially completed parts of the Work which are specifically identified in the Contract Documents, or which OPT and Design/Builder agree constitutes a separately functioning and usable part of the Work prior to Substantial Completion of the General Conditions — Design/Build (LS) Corpus Christi Standards 007200-119 Rev 5/2024 Work. Owner must be able to use that part of the Work for its intended purpose without significant interference with Design/Builder's performance of the remainder of the Work. 29.03 Final Inspection A. Notify the OAR when: 1. Work has been completed in compliance with the Contract Documents; 2. Equipment and systems have been tested per Contract Documents and are fully operational; 3. Final Operations and Maintenance Manuals have been provided to the Owner and all operator training has been completed; 4. Specified spare parts and special tools have been provided; and 5. Work is complete and ready for final inspection. B. OPT will visit the Site to determine if the Project is complete and ready for final payment within 30 days after the notice is received. C. OAR will notify the Design/Builder that the Project is complete or will notify the Design/Builder that Work is Defective. D. Take immediate steps to correct Defective Work. Notify the OAR when Defective Work has been corrected. OPT will visit the Site to determine if the Project is complete and the Work is acceptable. OAR will notify the Design/Builder that the Project is complete or will notify the Design/Builder that Work is Defective. E. Submit the Request for final payment with the closeout documents described in Paragraph 29.05 if notified that the Project is complete, and the Work is acceptable. 29.04 Reinspection Fees A. Owner may impose a Set-off against the Application for Payment in accordance with the General Conditions to compensate the OPT for additional visits to the Project if additional Work is required. 29.05 Closeout Documents Submittal A. Record Documents per Article 20. B. Warranties and bonds. C. Equipment installation reports on equipment. D. Shop Drawings, Record Data, and other documents as required by the Contract Documents. E. Evidence of continuing insurance and bond coverage as required by the Contract Documents. F. Final Photographs per Article 28. 29.06 Transfer of Utilities A. If applicable to the Project, transfer utilities to the Owner when the Certificate of Substantial Completion has been issued and the Work has been occupied by the Owner. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-120 Rev 5/2024 B. Submit final meter readings for utilities and similar data as of the date the Owner occupied the Work. 29.07 Warranties, Bonds and Service Agreements A. Provide warranties, bonds, and service agreements required by the Contract Documents. B. The date for the start of warranties, bonds, and service agreements is established per the Contract Documents. C. Compile warranties, bonds, and service agreements and review these documents for compliance with the Contract Documents. 1. Provide a log of all equipment covered under the 1-year correction period specified in the Contract Documents and all products for which special or extended warranties or guarantees are provided. Index the log by Specification Section number on forms provided. Include items 2.e through 2.g below in the tabulation. 2. Provide a copy of specific warranties or guarantees under a tab indexed to the log. Each document is to include: a. A description of the product or Work item; b. The firm name with the name of the principal, address, and telephone number; c. Signature of the respective Supplier or Subcontractor to acknowledge existence of the warranty obligation for extended warranties and service agreements; d. Scope of warranty, bond, or service agreement; e. Indicate the start date for the correction period specified in the Contract Documents for each product and the date on which the specified correction period expires. f. Indicate the start date for extended warranties for each product and the date on which the specified extended warranties period expires. g. Start date, warranty or guarantee period, and expiration date for each warranty, bond, and service agreement; h. Procedures to be followed in the event of a failure; and i. Specific instances that might invalidate the warranty or bond. D. Submit digital copies of the documents to the OAR for review. E. Submit warranties, bonds, and service agreements within 10 days after equipment or components are placed in service. ARTICLE 30 — TEMPORARY FACILITIES AND CONTROLS 30.01 Work Included A. Provide temporary facilities, including OPT's field office and the Design/Builder's field offices, storage sheds, and temporary utilities needed to complete the Work. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-121 Rev 5/2024 B. Install and maintain temporary Project identification signs. Provide temporary on -site informational signs to identify key elements of the construction facilities. Do not allow other signs to be displayed. 30.02 Quality Assurance A. Provide a total electrical heating and cooling system for the OPT's field office capable of maintaining the following conditions: 1. Heating: Minimum 75 degrees ID temp at 10 degrees ambient. 2. Cooling: Minimum 75 degrees ID temp at 105 degrees ambient. 3. Relative humidity: 48 to 54 percent. B. Inspect and test each service before placing temporary utilities in use. Arrange for all required inspections and tests by regulatory agencies and obtain required certifications and permits for use. 30.03 Delivery and Storage A. Arrange transportation, loading, and handling of temporary buildings and sheds. 30.04 Job Conditions A. Locate buildings and sheds at the Site as indicated or as approved by the OPT. B. Prepare the Site by removing trees, brush, or debris and performing demolition or grubbing needed to clear a space adequate for the structures. C. Pay for the utilities used by temporary facilities during construction. D. Provide each temporary service and facility ready for use at each location when the service or facility is first needed to avoid delay in the performance of the Work. Provide OPT's field office complete and ready for occupancy and use within 7 days of the Notice to Proceed. E. Maintain, expand as required, and modify temporary services and facilities as needed throughout the progress of the Work. F. Remove services and facilities when approved by the OAR. G. Operate temporary facilities in a safe and efficient manner. 1. Restrict loads on temporary services or facilities to within their designed or designated capacities. 2. Provide sanitary conditions. Prevent public nuisance or hazardous conditions from developing or existing at the Site. 3. Prevent freezing of pipes, flooding, or the contamination of water. 4. Maintain Site security and protection of the facilities. 30.05 Options A. Construction offices may be prefabricated buildings on skids or mobile trailers. B. Storage sheds may be prefabricated buildings on skids or truck trailers. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-122 Rev 5/2024 30.06 Temporary Field Offices A. The Design/Builder must furnish the OPT with a field office at the Site for projects that are over $1m or over 6 months. The field office must contain at least 120 square feet of useable space. The field office must be air-conditioned and heated and must be furnished with an inclined table that measures at least 30 inches by 60 inches and two chairs. The Design/Builder shall move the field office on the Site as required by the OAR. There is no separate pay item for the field office. B. Furnish a field office of adequate size for Design/Builder's use. Provide conference room space for a minimum of 10 people. C. Other trades may provide their own offices only when space is available at the Site, and the OPT agrees to its size, condition, and location. D. No monthly partial payments will be processed until OPT's field office facilities are completed and approved. 30.07 Temporary Storage Buildings A. Furnish storage buildings of adequate size to store any materials or equipment delivered to the Site that might be affected by weather. 30.08 Temporary Sanitary Facilities A. Provide sanitary facilities at the Site from the commencement of the Project until Project conclusion. Maintain these facilities in a clean and sanitary condition at all times and comply with the requirements of the local health authority. On large sites, provide portable toilets at such locations that no point in the Site shall be more than 600 feet from a toilet. B. Use these sanitary facilities. Do not use restrooms within existing or Owner -occupied buildings. 30.09 Temporary Heat A. Provide heating devices needed to protect buildings during construction. Provide fuel needed to operate the heating devices and attend the heating devices at all times they are in operation, including overnight operations. 30.10 Temporary Utilities A. Provide the temporary utilities for administration, construction, testing, disinfection, and start-up of the Work, including electrical power, water, and telephone. Pay all costs associated with furnishing temporary utilities. 1. Provide a source of temporary electrical power of adequate size for construction procedures. a. Use existing power systems where spare capacity is available. Provide temporary power connections that do not adversely affect the existing power supply. Submit connections to the OAR for approval prior to installation. b. Provide electrical pole and service connections that comply with Laws and Regulations and the requirements of the power company. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-123 Rev 5/2024 2. Provide telephone service to the Site and install telephones inside the Design/Builder's and the OPT's field office. 30.11 Water for Constructions A. Provide temporary water. Potable water may be purchased from the Owner by obtaining a water meter from the Owner and transporting water from a water hydrant. Non -potable water may be used for hydraulic testing of non -potable basins or pipelines. Include the cost of water in the Contract Price. B. Design/Builder must comply with the City of Corpus Christi's Water Conservation and Drought Contingency Plan as amended (the "Plan"). This includes implementing water conservation measures established for changing conditions. The OAR will provide a copy of the Plan to Design/Builder at the pre -construction meeting. The Design/Builder will keep a copy of the Plan on the Site throughout construction. 30.12 Location of Temporary Facilities A. Locate temporary facilities in areas approved by the OAR. Construct and install signs at locations approved by the OAR. Install informational signs so they are clearly visible. 30.13 Project Identification and Signs A. If signs are required, the Owner will furnish two Project signs to be installed by the Design/Builder. The signs must be installed before construction begins and will be maintained throughout the Project period by the Design/Builder. The locations of the signs will be determined in the field by the OAR. 30.14 Temporary Lighting A. Provide temporary lighting inside buildings once buildings are weatherproof. B. Provide lighting that is adequate to perform Work within any space. Temporary lights may be removed once the permanent lighting is in service. C. Provide portable flood lights at any time that Work will be performed outside the structure at night. Provide adequate lighting at any location Work is being performed. 30.15 Drinking Water A. Provide all field offices with potable water. Provide a dispenser and cooling apparatus if bottled drinking water is provided. B. Pay for water services and maintain daily. 30.16 Construction Fence A. Install and maintain a construction fence around the Site and off -site storage yards. Fence must be a minimum 6 feet high chain link construction unless shown otherwise. Provide gates with padlocks. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-124 Rev 5/2024 30.17 Removal of Temporary Facilities A. Remove temporary buildings, sheds, and utilities at the conclusion of the Project and restore the Site to original condition or finished in accordance with the Drawings. B. Remove informational signs upon completion of construction. C. Remove Project identification signs, framing, supports, and foundations upon completion of the Project. 30.18 Maintenance and Janitorial Service A. Provide janitorial service (sweeping/mopping) for the OPT's field office on a weekly basis or as requested. Empty trash receptacles daily or as needed. B. Maintain signs and supports in a neat, clean condition. Repair damage to structures, framings, or signs. C. Repair any damage to Work caused by placement or removal of temporary signage. D. Service, maintain, and replace, if necessary, the OPT's field office computer equipment throughout the Project as required by the OPT including replacement cartridges for all office equipment. ARTICLE 31— TEMPORARY CONTROLS 31.01 Work Included A. Provide labor, materials, equipment, and incidentals necessary to construct temporary facilities to provide and maintain control over environmental conditions at the Site. Remove temporary facilities when no longer needed. B. Construct temporary impounding works, channels, diversions, furnishing and operation of pumps, installing piping and fittings, and other construction for control of conditions at the Site. Remove temporary controls at the end of the Project. C. Provide a Storm Water Pollution Prevention Plan (SWPPP) as required by Texas Pollutant Discharge Elimination System (TPDES) General Permit No. TXR150000 for stormwater discharges from construction activities as applicable to the nature and size of the Project. Comply with all requirements of the Texas Commission on Environmental Quality (TCEQ) and Laws and Regulations. File required legal notices and obtain required permits prior to beginning any construction activity. D. Provide labor, materials, equipment, and incidentals necessary to prevent stormwater pollution for the duration of the Project. Provide and maintain erosion and sediment control structures as required to preventive sediment and other pollutants from the Site from entering any stormwater system including open channels. Remove pollution control structures when no longer required to prevent stormwater pollution. 31.02 Quality Assurance A. Construct and maintain temporary controls with adequate workmanship using durable materials to provide effective environmental management systems meeting the requirements of the Contract Documents and Laws and Regulations. Use materials that General Conditions — Design/Build (LS) Corpus Christi Standards 007200-125 Rev 5/2024 require minimal maintenance to prevent disruption of construction activities while providing adequate protection of the environment. B. Periodically inspect systems to determine that they are meeting the requirements of the Contract Documents. 31.03 Document Submittal A. Provide documents requiring approval by the OPT as Shop Drawings in accordance with Article 25. B. Provide copies of notices, records, and reports required by the Contract Documents or Laws and Regulations as Record Data in accordance with Article 26. 31.04 Standards A. Provide a SWPPP that complies with all requirements of TPDES General Permit No. TXR150000 and any other applicable Laws and Regulations. B. Perform Work to comply with the City of Corpus Christi Code of Ordinances, Part III, Chapter 14, Article X - titled "STORM WATER QUALITY MANAGEMENT PLANS" and any other applicable Laws and Regulations. 31.05 Permits A. As applicable, submit the following to the TCEQ and the Operator of any Municipal Separate Storm Sewer System (MS4) receiving stormwater discharges from the Site: 1. Notice of Intent (NOI) at least 48 hours prior to beginning construction activity. Construction activity may commence 24 hours after the submittal of an electronic NOI. 2. Notice of Change (NOC) letter when relevant facts or incorrect information was submitted in the NOI, or if relevant information in the NOI changes during the course of construction activity. 3. Notice of Termination (NOT) when the construction Project has been completed and stabilized. B. Post a copy of the NOI at the Site in a location where it is readily available for viewing by the general public and as required by Laws and Regulations prior to starting construction activities and maintain the posting until completion of the construction activities. C. Maintain copies of a schedule of major construction activities, inspection reports, and revision documentation with the SWPPP. 31.06 Stormwater Pollution Control A. Comply with the current requirements of TPDES General Permit as set forth by the TCEQ for the duration of the Project as applicable to the nature of the work and the total disturbed area: 1. Develop a SWPPP meeting all requirements of the TPDES General Permit. 2. Submit of a Notice of Intent to the TCEQ. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-126 Rev 5/2024 3. Develop and implement appropriate Best Management Practices as established by local agencies of jurisdiction. 4. Provide all monitoring and/or sampling required for reporting to the TCEQ. 5. Submit reports to the TCEQ as required as a condition of the TPDES General Permit. 6. Submit copies of the reports as Record Data in accordance with Article 26. 7. Retain copies of these documents at the Site at all times for review and inspection by the OPT or regulatory agencies. Post a copy of the permit as required by Laws and Regulations. 8. Assume sole responsibility for implementing, updating, and modifying the TPDES General Permit per Laws and Regulations for the SWPPP and Best Management Practices. B. Use forms required by the TCEQ to file the Notice of Intent. Submit the Notice of Intent at least 2 days prior to the start of construction. Develop the SWPPP prior to submitting the Notice of Intent. Provide draft copies of the Notice of Intent, SWPPP, and any other pertinent TCEQ submittal documents to Owner for review prior to submittal to the TCEQ. C. Return any property disturbed by construction activities to either specified conditions or pre - construction conditions as set forth in the Contract Documents. Provide an overall erosion and sedimentation control system that will protect all undisturbed areas and soil stockpiles/spoil areas. Implement appropriate Best Management Practices and techniques to control erosion and sedimentation and maintain these practices and techniques in effective operating condition during construction. Permanently stabilize exposed soil and fill as soon as practical during the Work. D. Assume sole responsibility for the means, methods, techniques, sequences, and procedures for furnishing, installing, and maintaining erosion and sedimentation control structures and procedures and overall compliance with the TPDES General Permit. Modify the system as required to effectively control erosion and sediment. E. Retain copies of reports required by the TPDES General Permit for 3 years from date of Final Completion. 31.07 Pollution Control A. Prevent the contamination of soil, water, or atmosphere by the discharge of noxious substances from construction operations. Provide adequate measures to prevent the creation of noxious air -borne pollutants. Prevent dispersal of pollutants into the atmosphere. Do not dump or otherwise discharge noxious or harmful fluids into drains or sewers, nor allow noxious liquids to contaminate public waterways in any manner. B. Provide equipment and personnel and perform emergency measures necessary to contain any spillage. 1. Contain chemicals in protective areas and do not dump on soil. Dispose of such materials at off -site locations in an acceptable manner. 2. Excavate contaminated soil and dispose at an off -site location if contamination of the soil does occur. Fill resulting excavations with suitable backfill and compact to the density of the surrounding undisturbed soil. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-127 Rev 5/2024 3. Provide documentation to the Owner which states the nature and strength of the contaminant, method of disposal, and the location of the disposal site. 4. Comply with Laws and Regulations regarding the disposal of pollutants. C. Groundwater or run-off water which has come into contact with noxious chemicals, sludge, or sludge -contaminated soil is considered contaminated. Contaminated water must not be allowed to enter streams or water courses, leave the Site in a non -contained form, or enter non -contaminated areas of the Site. 1. Pump contaminated water to holding ponds constructed by the Design/Builder for this purpose, or discharge to areas on the interior of the Site, as designated by the OAR. 2. Construct temporary earthen dikes or take other precautions and measures as required to contain the contaminated water and pump to a designated storage area. 3. Wash any equipment used for handling contaminated water or soil within contaminated areas three times with uncontaminated water prior to using such equipment in an uncontaminated area. Dispose of wash water used to wash such equipment as contaminated water. 31.08 Earth Control A. Remove excess soil, spoil materials, and other earth not required for backfill at the time of generation. Control stockpiled materials to eliminate interference with Design/Builder and Owner's operations. B. Dispose of excess earth off the Site. Provide written approval from the property owner for soils deposited on private property. Obtain approval of the Owner if this disposal impacts the use of Site or other easements. 31.09 Ozone Advisory Days A. Do not conduct roofing, priming, or hot -mix paving operations, except for repairs, on days the City Engineer has notified Design/Builder that an ozone advisory is in effect. An extension of time will be allowed for each day for which priming or hot mix paving was scheduled, crews were prepared to perform this Work and the City Engineer issued ozone alert prevents this Work. 31.10 Management of Water A. Manage water resulting from rains or ground water at the Site. Maintain trenches and excavations free of water at all times. B. Lower the water table in the construction area by acceptable means if necessary to maintain a dry and workable condition at all times. Provide drains, sumps, casings, well points, and other water control devices as necessary to remove excess water. C. Provide continuous operation of water management actions. Maintain standby equipment to provide proper and continuous operation for water management. D. Ensure that water drainage does not damage adjacent property. Divert water into the same natural watercourse in which its headwaters are located, or other natural stream or General Conditions — Design/Build (LS) Corpus Christi Standards 007200-128 Rev 5/2024 waterway as approved by the Owner. Assume responsibility for the discharge of water from the Site. E. Remove the temporary construction and restore the Site in a manner acceptable to the OAR and to match surrounding material at the conclusion of the Work. 31.11 Dewatering A. This item is considered subsidiary for all dewatering methods other than "well pointing" to the appropriate items where dewatering is needed to keep the excavation dry and shall include all costs to provide a dry foundation for the proposed improvements. B. Storm water that enters an excavation can be pumped out as long as care is taken to minimize solids and mud entering the pump suction and flow is pumped to a location that allows for sheet flow prior to entering a storm water drainage ditch or storm water inlet. C. An alternative to sheet flow is to pump storm water to an area where ponding occurs naturally without leaving the designated work area or by a manmade berms) prior to entering the storm water system. Sheet flow and ponding is to allow solids screening and/or settling prior to entering a storm water conduit or inlet. D. Storm water or groundwater shall not be discharged to private property without permission. It is the intent that Design/Builder discharges groundwater primarily into the existing storm water system, provided that the quality of groundwater is equal to or better than the receiving stream. E. Testing of groundwater quality is to be performed by the Design/Builder, at the Design/Builder's expense, prior to commencing discharge and shall be retested by the Design/Builder, at the Design/Builder's expense, a minimum of once a week. Design/Builder shall coordinate with the Owner on all testing. Tests will also be performed as each new area of construction is started. F. Another option for disposal of groundwater by Design/Builder would include pumping to the nearest wastewater system. If discharging to temporary holding tanks and trucking to a wastewater or wastewater plant, the costs for these operations shall be negotiated. Other groundwater disposal alternatives or solutions may be approved by the OAR on a case by case basis. G. Prior to pumping groundwater from a trench to the wastewater system the Design/Builder shall contact Wastewater Pre-treatment Coordinator at 826-1817 to obtain a "no cost" permit from the Owner's Waste Water Department. Design/Builder will pay for any water quality testing or water analysis cost required. The permit will require an estimate of groundwater flow. Groundwater flow can be estimated by boring a hole or excavating a short trench then record water level shortly after completion, allow to sit overnight, record water level again, pump hole or trench dry to a holding tank or vacuum truck then record how long it takes to fill to original level and overnight level. 31.12 Disposal of Highly Chlorinated or Contaminated Water A. Dispose of water used for testing, disinfection, and line flushing. Comply with Owner's requirements and Laws and Regulation regarding the disposal of contaminated water, including water with levels of chlorine, which exceed the permissible limits for discharge into wetlands or environmentally sensitive areas. Comply with the requirements of all regulatory General Conditions — Design/Build (LS) Corpus Christi Standards 007200-129 Rev 5/2024 agencies in the disposal of all water used in the Project. Do not use the Owner's wastewater system for disposal of contaminated water. 31.13 Windstorm Certification A. All affected materials and installation shall comply with Texas Department of Insurance Requirements for windstorm resistant construction for design wind speed as required by the current version of the International Building Code (IBC). When applicable, Design/Builder shall be responsible for contracting with a licensed structural engineer in the State of Texas to perform all inspections and provide documentation for windstorm certification to the Texas Board of Insurance. The Design/Builder shall be responsible for providing all necessary design/assembly documentation for all new windows, doors, louvers, etc. to the windstorm engineer/inspectors required to conform with the requirements of the Texas Department of Insurance. 31.14 Constructing, Maintaining and Removing Temporary Controls A. Construct temporary controls in accordance with Laws and Regulations. B. Maintain controls in accordance with regulatory requirements where applicable, or in accordance with the requirements of the Contract Documents. C. Remove temporary controls when no longer required, but before the Project is complete. Correct any damage or pollution that occurs as the result of removing controls while they are still required. ARTICLE 32 — MISCELLANEOUS 32.01 Computation of Times A. Exclude the first day and include the last day when determining dates for a period of time referred to in the Contract Documents by days. The last day of this period is to be omitted from the determination if it falls on a Sunday or a legal holiday. B. All references and conditions for a Calendar Day Contract in the Contract Documents apply for a Fixed Date Contract. A Fixed Date Contract is one in which the calendar dates for reaching Substantial Completion and/or final completion are specified in lieu of identifying the number of days involved. 32.02 Owner's Right to Audit Design/Builder's Records A. By execution of the Contract, Design/Builder grants Owner the right to audit, examine, inspect and/or copy, at Owner's election at all reasonable times during the term of this Contract and for a period of four (4) years following the completion or termination of the Work, all of Design/Builder's written and electronically stored records and billings relating to the performance of the Work under the Contract Documents. The audit, examination or inspection may be performed by an Owner designee, which may include its internal auditors or an outside representative engaged by Owner. Design/Builder agrees to retain its records for a minimum of four (4) years following termination of the Contract, unless there is an ongoing dispute under the Contract, then, such retention period must extend until final resolution of the dispute. As used in these General Conditions, "Design/Builder written and General Conditions — Design/Build (LS) Corpus Christi Standards 007200-130 Rev 5/2024 electronically stored records" include any and all information, materials and data of every kind and character generated as a result of the work under this Contract. Examples of Design/Builder written and electronically stored records include, but are not limited to: accounting data and reports, billings, books, general ledgers, cost ledgers, invoices, production sheets, documents, correspondence, meeting notes, subscriptions, agreements, purchase orders, leases, contracts, commitments, arrangements, notes, daily diaries, reports, drawings, receipts, vouchers, memoranda, time sheets, payroll records, policies, procedures, Subcontractor agreements, Supplier agreements, rental equipment proposals, federal and state tax filings for any issue in question, along with any and all other agreements, sources of information and matters that may, in Owner's sole judgment, have any bearing on or pertain to any matters, rights, duties or obligations under or covered by any Contract Documents. B. Owner agrees to exercise the right to audit, examine or inspect Design/Builder's records only during regular business hours. Design/Builder agrees to allow Owner and/or Owner's designee access to all of the Design/Builder's Records, Design/Builder's facilities, and current or former employees of Design/Builder, deemed necessary by Owner or its designee(s), to perform such audit, inspection or examination. Design/Builder also agrees to provide adequate and appropriate work space necessary for Owner or its designees to conduct such audits, inspections or examinations. C. Design/Builder must include this Paragraph 30.02 in any Subcontractor, supplier or vendor contract. 32.03 Independent Contractor A. Design/Builder is to perform its duties under this Contract as an independent contractor. The Design/Builder's Team and their personnel are not considered to be employees or agents of the Owner. Nothing in this Contract is to be interpreted as granting Design/Builder's Team the right or authority to make commitments for the Owner. This Contract does not constitute or create a joint venture, partnership or formal business organization of any kind. 32.04 Cumulative Remedies A. The duties and obligations imposed by these General Conditions and the rights and remedies available to the Owner or Design/Builder by these General Conditions are in addition to, and are not a limitation of, the rights and remedies which are otherwise imposed or available by: 1. Laws or Regulations; 2. Special warranties or guarantees; or 3. Other provisions of the Contract Documents. B. The provisions of this Paragraph 30.04 are as effective as if repeated specifically in the Contract Documents in connection with each particular duty, obligation, right and remedy to which they apply. 32.05 Limitation of Damages A. Owner is not liable to Design/Builder for claims, costs, losses or damages sustained by Design/Builder's Team associated with other projects or anticipated projects. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-131 Rev 5/2024 B. Design/Builder waives claims for consequential damages, incidental or special damages arising out of or relating to this Contract, whether the damages are claimed in contract, tort or on any other basis. 32.06 No Waiver A. The failure of Owner to enforce any provision of this Contract does not constitute a waiver of that provision or affect the enforceability of that provision or the remainder of this Contract. 32.07 Severability A. Any provision or part of the Contract Documents held to be void or unenforceable under any Law or Regulation shall be deemed stricken, and all remaining provisions shall continue to be valid and binding upon Owner and Contractor, who agree that the Contract Documents shall be reformed to replace such stricken provision or part thereof with a valid and enforceable provision that comes as close as possible to expressing the intention of the stricken provision. 32.08 Survival of Obligations A. Representations, indemnifications, warranties, guarantees and continuing obligations required by the Contract Documents survive completion and acceptance of the Work or termination of the Contract. 32.09 No Third Party Beneficiaries A. Nothing in this Contract can be construed to create rights in any entity other than the Owner and Design/Builder. Neither the Owner nor Design/Builder intends to create third party beneficiaries by entering into this Contract. 32.10 Assignment of Contract A. This Contract may not be assigned in whole or in part by the Design/Builder without the prior written consent of the Owner. 32.11 No Waiver of Sovereign Immunity A. The Owner has not waived its sovereign immunity by entering into and performing its obligations under this Contract. B. This Contract is to perform a governmental function solely for the public benefit. 32.12 Controlling Law A. This Contract is governed by the laws of the State of Texas without regard to its conflicts of laws. Venue for legal proceedings lies exclusively in Nueces County, Texas. Cases must be filed and tried in Nueces County and cannot be removed from Nueces County, Texas. 32.13 Conditions Precedent to Right to Sue A. Notwithstanding anything herein to the contrary, Design/Builder will have at least 90 days to give notice of a claim for damages as a condition precedent to the right to sue on the General Conditions — Design/Build (LS) Corpus Christi Standards 007200-132 Rev 5/2024 Contract, subject to the contractual Claims and Alternative Dispute Resolution processes set forth herein. 32.14 Waiver of Trial by Jury A. Owner and Design/Builder agree that they have knowingly waived and do hereby waive the right to trial by jury and have instead agreed, in the event of any litigation arising out of or connected to this Contract, to proceed with a trial before the court, unless both parties subsequently agree otherwise in writing. 32.15 Attorney Fees A. The Parties expressly agree that, in the event of litigation, all parties waive rights to payment of attorneys' fees that otherwise might be recoverable, pursuant to the Texas Civil Practice and Remedies Code Chapter 38, Texas Local Government Code §271.153, the Prompt Payment Act, common law or any other provision for payment of attorney's fees. 32.16 Compliance with Laws A. Comply with the Americans with Disabilities Act of 1990 as amended (ADA) and Texas Architectural Barriers Act and all regulations relating to either statute. B. No qualified person shall on the basis of race, color, religion, national origin, gender, age or disability be excluded from participation in, be denied the benefits of, or be subjected to discrimination under any program or activity which receives or benefits from federal financial assistance. C. Comply with all applicable federal, state and city laws, rules and regulations. D. Each applicable provision and clause required by law to be inserted into the Contract shall be deemed to be enacted herein, and the Contract shall be read and enforced as though each were physically included herein. 32.17 Enforcement A. The City Manager or designee and the City Attorney or designee are fully authorized and will have the right to enforce all legal rights and obligations under the Contract without further authorization from City Council. 32.18 Subject to Appropriation A. Funds are appropriated by the Owner on a yearly basis. If for any reason, funds are not appropriated in any given year, the Owner may direct immediate suspension or termination of the Contract with no additional liability to the Owner. If the Design/Builder is terminated or suspended and the Owner requests remobilization at a later date, the Design/Builder may request payment for reasonable demobilization/remobilization costs. Such costs shall be addressed through a Change Order to the Contract. Under no circumstances may a provision or obligation under this Contract be interpreted as contrary to this paragraph. General Conditions — Design/Build (LS) Corpus Christi Standards 007200-133 Rev 5/2024 32.19 Contract Sum A. The Contract Sum is stated in the Contract and, including authorized adjustments, is the total maximum not -to -exceed amount payable by Owner to Design/Builder for performance of the Work under the Contract Documents. Design/Builder accepts and agrees that all payments pursuant to this Contract are subject to the availability and appropriation of funds by the Corpus Christi City Council. If funds are not available and/or appropriated, this Contract shall immediately be terminated with no liability to any party to this Contract. 32.20 Design/Builder's Guarantee as Additional Remedy A. The Design/Builder's guarantee is a separate and additional remedy available to benefit the Owner. Neither the guarantee nor the expiration of the guarantee period will operate to reduce, release or relinquish any rights or remedies available to the Owner for any claims or causes of action against the Design/Builder or any other individual or entity. 32.21 Notices A. Any notice required to be given to Owner under any provision in this Contract must include a copy to OAR by mail or e-mail. 32.22 Public Information A. The requirements of Subchapter J, Chapter 552, Texas Government Code, may apply to this contract, and Contractor agrees that the contract can be terminated if Contractor knowingly or intentionally fails to comply with a requirement of that subchapter. END OF SECTION General Conditions — Design/Build (LS) Corpus Christi Standards 007200-134 Rev 5/2024 Performance Specification Guidelines General Section Guidelines • A maximum allowance of 2% payment for bonds and insurance will be granted based on the receipt of documentation of actual costs. • The Bidder shall furnish satisfactory evidence of the rate or rates paid for all bonds and insurance. Bonds & Insurance • The Bidder will be reimbursed for the actual cost of unique insurance as required and obtained specifically for this Project, not including the routine and general company insurance policies that are maintained for the course of conducting normal business operations. • The Bidder will be reimbursed for the actual cost of project specific bonds and insurance, not to exceed the bid amount or the verifiable costs of Project specific bonds and insurance incurred by the Bidder. • The Traffic Control Plan shall be prepared in accordance with the City of Corpus Christi requirements and/or other applicable standards. Traffic Control • TCP shall include signage types, barrels/barricades/other devices called out by type, detour routes with temporary signage/speed bumps/pavement markings, and other details or notes as needed to convey Contractor responsibilities. Seeding • The work shall include providing and installing temporary seeding for erosion control as specified in the City Standard Specifications. • As per City of Corpus Christi's Infrastructure Design Manual, a storm water pollution prevention plan or pollution control plan shall be developed and implemented prior to any ground water discharges to the storm water system. Storm Water Pollution Prevention Plan • The plan's objectives are to limit erosion and scour of the storm water system and minimize the Total Suspended Solids (TSS) and other forms of contamination and prevent any damage to the storm water system. • Protection of inlets and other areas where disturbance may occur required. DB Industrial Park Roadway Imps Design Criteria Package Page 1 of 8 Street Improvements Section Guidelines • In accordance with the City of Corpus Christi IDM, the pavement design report shall be prepared and signed by, or under the supervision of, a professional engineer registered in the State of Texas and shall be based on the provided geotechnical report. • The pavement shall be designed with a minimum of thirty years' service life. • With a Street Classification of Local (nonresidential) traffic the traffic load is the cumulative expected 18-Kip equivalent single axle loads (ESAL) for the service life. Pavement Design • A minimum 18-Kip ESAL of 1,000,000 and a reliability level of R-80. • For all arterials, collectors, and non- residential local streets (based on zoning) the engineer shall evaluate the existing ADT and traffic type distribution and use the greater of the 30-year projection of the field verified ESAL or the ESAL value established in this Table. • For City of Corpus Christi projects, the Traffic Engineer will provide a traffic count for design purposes. • Roadbed soil having a plasticity index (P.I.) greater than 20 shall be treated with lime to reduce the P.I. below 20. Existing Concrete • The Bidder may utilize the existing concrete along the roadway area to support the pavement design. Temporary Pavement Markings • The Bidder may utilize flaggers, temporary buttons, and or temporary signs during construction to provide guidance for travelers. Pavement Markings • City of Corpus Christi standards shall be used to replace all pavement markings and traffic buttons removed during construction process. • Texas Manual on Uniform Traffic Control Devices shall be used to determine sign placement and types of signs needed to meet requirements based on design. Signs • The Bidder shall remove and replace all/any sign that is not supported by a triangular slip base and shall verify that any sign within project limits is on a triangular slip base as per City of Corpus Christi Standards. DB Industrial Park Roadway Imps Design Criteria Package Page 2 of 8 Driveways • • • • • Corpus Christi City standards are to be used for driveways. Driveways shall have the appropriate cross slope per Texas Accessibility Standards (TAS). A 1.5-3.5% slope from the curb, flattening down to a 1 %-1.5% slope, and tying back to 9.5% to match existing elevation is recommended, not meeting the exact minimum and maximum requirements will ensure room to maneuver if necessary. The recommended slopes may be altered, but the ultimate design and constructed slopes shall not surpass the allowable slopes as per Texas Department of Transportation's guidelines. All curb ramps shall be places at a minimum distance of 5-feet away from any driveway. • As per City of Corpus Christi IDM, the road cross -slope from the crown to the gutter shall be a consistent 2% minimum the maximum acceptable cross -slope on new construction or full depth reconstruction is 4%. Roadway Slope • Crown to crown transitions is required at intersections and valley gutters are not permitted. • A 1.5 - 3.5% slope is recommended, not meeting the exact minimum and maximum requirements will ensure room to maneuver if necessary. • All fencing that is in the path of construction Fencing shall be removed and reinstalled, not before giving the property owner a proper notice. ADA Improvements Section Guidelines • As per City of Corpus Christi IDM, sidewalks shall be designed per the Street Classifications and Street Design Standards in Chapter 6 of the IDM. • A minimum of one 5' tied sidewalk or 4' untied sidewalk accessible path shall be Sidewalk incorporated to each roadway in accordance with the Corpus Christi Standards to meet pedestrian accommodations and geometric design standards. • Bus Stops shall be designed to RTA standards such that they do not encroach DB Industrial Park Roadway Imps Design Criteria Package Page 3 of 8 into the required sidewalk passage area per TAS. • City of Corpus Christi Pedestrian Curb Ramp standards are to be used for curb ramps. • A 2-foot truncated dome area, with a 6-foot maximum length ramp or 2-foot minimum length ramp, a 5-foot x 5-foot landing, and a 2-foot tie-in should be provided wherever an accessible route crosses (penetrates) a curb. Curb Ramps • Submit registrations & plans to TDLR through a RAS • Schedule final RAS inspection to confirm TAS/ADA compliance & verify RAS closes out paperwork with TDLR for project closeout. • Curb Ramps shall be in accordance with the Texas Accessibility Standards (TAS). • All curb ramps shall be places at a minimum distance of 5-feet away from any driveway, and/or inlet. • City of Corpus Christi standards and Texas Cross Walk Manual on Uniform Traffic Control Devices shall be used to determine crosswalk requirements needed based on design. • City of Corpus Christi standards and Texas Stop Bar Manual on Uniform Traffic Control Devices shall be used to determine stop bar requirements based on design. Gas Improvements Section Guidelines Gas Line Trench • As per City of Corpus Christi requirements the Bidder/Contractor shall identify any gas lines within project limits prior to construction. • Notify the City of any gas lines and provide trenching and backfill if required. Stormwater Improvements Guidelines • It is the Bidder's responsibility to correctly identify the existing storm system to perform a drainage study to improve the existing drainage at the project site without damaging the adjunct areas. Stormwater Study • As per City of Corpus Christi IDM requirements Storm Water facilities associated with transportation projects shall be designed using the level of protection based on the City's Urban Transportation Plan definitions of road classifications. DB Industrial Park Roadway Imps Design Criteria Package Page 4 of 8 • • • • • • Use software tools commonly used for storm sewer design. Tailwater elevations shall be determined through appropriate tailwater calculations, Known water surface elevations for the flood interval, FEMA FIRMs, City Storm water maps, or other resources deemed acceptable by the City Engineer. A Light Industrial Zone requires a 5-year design storm to be contained within conveyance system design and not pond across the roadway at inlets higher than the curb line. A 100-year design storm must not indicate ponding above the finished floor elevation of the adjacent habitable structures. Lastly, the Bidder shall verify that the 5-year hydraulic grade line does not surpass the top of the proposed inlet top. • Utilizing the performed drainage study the Bidder shall identify, remove, and replace all non -compliant inlets in accordance with the City of Corpus Christi Standards. • Using the Light Industrial Zone criteria the Inlet Demolition and Replacement Inlet type, size, and spacing shall be properly designed to not exceed the ponding extents or depths as described in City of Corpus Christi Chapter 3. • All curb ramps shall be places at a minimum distance of 5-feet away from any inlet. Storm Line Demolition • Bidder/ Contractor shall be responsible for identifying and removing all storm lines non -compliant with the City of Corpus Christi Standards. • As per City of Corpus Christi IDM Chapter 3, the storm line should be designed to convey the level of protection required based on the 5-year storm study results. Storm Line Design • Pipe material shall be reinforced concrete pipe (RCP), or reinforced concrete box (RCB) under roadway pavement. • The minimum SW pipe size is 18" regardless of location. • Minimum RCP size under pavement is 18" for lateral lines or trunk lines. • Minimum RCP box is 3'x2'. Wastewater Improvements Guidelines Clay Line Replacement • Bidder/Contractor shall be responsible for identifying any non -compliant wastewater DB Industrial Park Roadway Imps Design Criteria Package Page 5 of 8 • • line, as well as removing and replacing the existing line. Size, length, material, etc. shall be properly designed as described in City of Corpus Christi IDM Chapter 5. As standard practice, the removal and replacement of wastewater lines shall be done from manhole to manhole. • As per City of Corpus Christi Standards Fiberglass Manholes Section 027205, Fiberglass manholes shall be fabricated in accordance with ASTM D3753- "Standard Specification for Glass - Fiber -Reinforced Polyester Manholes and Wet wells," latest edition. • MH covers in pavement shall be HS-20 traffic -rated. Wastewater Manholes • MH covers in certain locations may be required to be bolted covers. • The minimum pipe diameter for a WW line shall be 8-in. 6-in. and larger WW lines are only allowed for commercial properties. Wastewater Lines • WW lines shall be placed a minimum of 3-ft. of cover below the pavement section, other finished grade, or natural ground. • Maximum depth for 8-in. through 12-in. dia. WW lines shall be 20 feet. • Maximum depth for large diameter WW lines is 30 feet. Water Improvements Guidelines • As per City of Corpus Christi IDM, all water line mains shall be located within public ROW. • The existing water line shall be replaced and upsized. • Size, length, material, etc. shall be properly designed as described in City of Corpus Christi Standards Chapter 4. Waterlines • No dead-end mains shall be allowed in the distribution system, unless authorized by the Executive Director of Water Utilities. • Grid mains shall not exceed either of the two following lengths: 6,000 feet or a length that would, by fluid hydraulics, render the line incapable of producing the flows and pressures required. • Distribution mains shall not exceed either of the two following lengths: 3,000 feet or a length that would, by fluid hydraulics, render the line incapable of producing the flows and pressures required. DB Industrial Park Roadway Imps Design Criteria Package Page 6 of 8 • • • Tapping Sleeves and Valves shall be used to tie into the existing mains whenever possible to reduce the possibility of service interruptions and contamination. Utilities PVC and DI are the only allowed pipe materials for water distribution. Parallel Utilities - no utilities shall be installed parallel to and above or below within 18-inches horizontally from the outer edge of the water main and parallel on either side of the line for the entire length of the water line. • Bidder shall cap and grout to abandon any existing AC line unless it is in conflict with any other utilities. AC Line Water Replacement • All removal work, transportation, filing of correct paperwork and disposal of the asbestos -cement (AC) pipe shall comply with all local, state, and federal regulations and requirements. • As per City of Corpus Christi IDM, In Light Industrial zones all fire hydrants shall be of the traffic -model type, equipped with safety break -away couplings on both the hydrant barrel and the stem. Couplings and Fittings • Break -away couplings shall be designed to break away to protect other parts of the hydrant during traffic collisions but weakened steel or cast-iron bolts shall not be acceptable for break -away barrel couplings. • In accordance with the City of Corpus Christi's Infrastructure Manual, water valves shall be in the public right of way. • Unless otherwise specified, all valves in the water distribution system shall open left (counterclockwise), parallel to the main, and shall be non -rising stem valves. Water Valves • Valves that are placed in roadways, shall be outside of the wheel -path, typically in the middle of the traffic lane between the two - wheel paths within that lane. • Valves shall be located near fire hydrant assemblies when possible. • The maximum spacing between valves shall be no more than 600-feet on center, and the minimum number of valves in the immediate proximity of a 'tee' shall be 2, and in the immediate proximity of a 'cross' shall be 3. DB Industrial Park Roadway Imps Design Criteria Package Page 7 of 8 • All valves must be AWWA-approved for use in domestic drinking water systems. • As per City of Corpus Christi IDM, In Light Industrial zones fire hydrants shall conform to AWWA standard. Fire hydrants shall be installed in UEs or in public ROW, at street intersections or on streets between property lines to avoid future driveway conflicts. • Fire hydrants shall be installed between the curb and sidewalk nearest the property Fire Hydrants lines and accessible to the Fire Department during routine maintenance or emergencies. • The fire hydrants shall be located with a maximum spacing of 300 LF on center as measured along the centerline of the street. • Water valves between fire hydrants and the main waterline shall be installed in accordance with the City of Corpus Christi Standards. Signature: EGisa Si Wa Email: elisas@cctexas.com Signature: Tessica Pauitt Email: jessicap6@cctexas.com Signature: Geld 7A Email: gilberts2@cctexas.com Signature: 3—a�&1�-1' Email: sarahb@cctexas.com DB Industrial Park Roadway Imps Design Criteria Package Page 8 of 8