HomeMy WebLinkAbout01723 ORD - 10/25/1944AN ORDINANCE
AUTHORIZING AND DIRECTING THE MAYOR AND
CITY CONTROLLER OF THE CITY OF CORPUS
CHRISTI, TEXAS, TO EXECUTE, FOR AND ON
BEHALF OF SAID CITY, AN AGREEMENT BY AND
BETWEEN THE CITY OF CORPUS CHRISTI, TEXAS,
AND J. W. BERMINGHAM FOR THE CONSTRUCTION
OF A REINFORCED CONCRETE AND MASCNRY FIRE
STATION IN LOUISIANA STREET PARK STRIP AT
THE CORNER OF LOUISLANA AND SEMTEENTH
STREETS, AND DECLARING AN EMERGENCY.
BE IT ORDAINED BY THE CM COUNCIL OF THE CITY OF CORPUS CHRISTI,
TEXAS:
SECTION 1. That the Mayor and City Controller of the
City of Corpus Christi, Texas, be, and they are hereby, authorized
be
and directed to execute, for and on behalf of said City, an agree
meat by and between the City of Corpus Christi, Texas, and J. W.
Bermingham for the construction of a reinforced concrete and
masonry fire station in Louisiana Street Park Strip at the corner
of Louisiana and Seventeenth Streets, a copy of which agreement is
attached hereto and made a part hereof, and reads as follows, to -wit:
s
0
AM IT EMM"n
Sealed proposals will be reoeived by the NSty of Corpus Christie
Texas, at the offioe of the City Seoretary. until^, 1,9- on _
Sor >tember 16 .19 44 • for the oonstruotlon of a reinforoad
onnorets and masonry fire station to be looated in the Louisiana Street
park strip at the eorn*r of Louisiana and Seventeenth streets in Corpus
Christi, Texas,
Copies of the planes speoifioations and other proposed oontrant
documents are on file in the offioe of t;ie City Engineers City Hall, 'Corpus
Christie Texas.
The City cf Oor ^ue Cb r. rtir 5'....- .. °eaerves the right to rejeet
any or all bids a .d tC wa:.va
arL,m. c. C,9FiL "J:9 CdRIS711, TEXAS
Iat insertion
and iaeertion
Addenda No. 1, Fire Station Specifications.
The depths of the footing stems or columns is not shown on the
plans or called for in the specifications. This depth shall be
12' below the natural grade.
The wall heaters shown on the plans are not described in the speoi-
fioations. There aPe two of these heaters, and shall be Day and
Night, or equal, bathroom type wall heaters vanted as called for
under sheet metal work, these specifications.
PROPOSAL
Place
Date
Proposal of J W Bermin'41&m
a corporation organized and operating under the laws of the state, of
a partnership consisting of
an individual trading as J W Berminrh m -
TD THE CITY OF CORPUS CHRISTI, TEXAS
The undersigned hereby proposes to furnish all materials and perform all work re-
cui-ed to
oonstruct a reinforced oonrete and masonry fiTe at°tion in Louiainne-
Street Park strip at the corner of Louisiana and Seventeenth atreeta-
All work is to be in strict accordance with the Plans and Specifications for the
following prices Eighteen thousand one hundred twenty -four doila and fifty -five oents
(18,124.55)
The undersigned agrees thate If awarded the contract# he will complete same in
calendar days. The underslgned.further declares that he
has visited the site and has carefully examined the Plans end Speoifiostions.
and Contract Documents.
Immediately upon receipt of notioe.of acceptance of this bide we will execute the
formal contract attached, and will deliver a Surety Bond for the faithful perform-
anoe of this contract.
Respectfully submitteds
BY
ADDRESS
A G R A S M E N T
THE STATE OF TEXAS
COUNTY OF NUECES
THIS AGREEMENT made and entered into this day of
. 19___, by and between the CITY OF CORPUS CHRISTI,
of the County of Nueoes. State of Texas. asting through its Mayor and City Con -
troller, thereunto duly authorised so to do, Party of the First Part, termed in
the Contraot Documents as the sOwnerfp and .
Bamiagmm
J W
arty of the Second Part, termed in the Contract Documents as the *Contractors.
WITNE SSE THs
WHEREAS, in oonsideration of the sums specified in the proposal to
be paid by the Owner to the Contractor at the time and in the manner hereinafter
provided, the said Contractor has agreed and does hereby agree to furnish labor.
tools, equipment. and material* and to oonstruot oompiete in every detail, to -wit: .
A reinforced concrete and masonry fire station in Lok"ssnnn c+,..,_+ i .vim_
at the corner of Louisiana and Seventeenth, Rt}pe +o -- - -
AND FOR SAID CONSIDERATION. it In further partioularly agreed be-
tween the parties to this agreements
1. That construction and installation of the above work for the
Owner shall be oompleted and ready for use within calendar days
from and inoluding the date specified in a written order from the Owner to the
Contraotor to oomm once work.
2. That said work and material for the project covered by the Con-
'_raot Documents shall be oompystsly installed and delivered to the .Owner within
`he time stated, olear and free from any and all liensp olaims and demands of ary
Kind for materials. equipment, supplies, labor, accidental death or otherwise.
3. That the full compensation to be paid the Contraotor by the
Owner shall be payable upon completion of the work and its aooeptanoe thereof
by the Owner,
4. That payment to the Contractor by the Owner shall be on a
semi - monthly basis, at which times certified estimates will be paid upon
approval. (See Article 25, General Conditions).
IN WITNESS WdEREOF. said parties hereto have hereunto not their
hands and seals at Corpus Christie Texas, the day and year first above written.
ATZST s
City Secretary
APPR D AS TO ,EQAL PORMs
City Attorney
ATTEST
CITY OF CORPUS CHRISTI. TEXAS
Party of the First Part (Owner)
By
A. C. XcCaughan. Mayor
By
City Controller
Party of the Seoond Part (Contractor)
By
Title
1
=f
THE OE1._.4L CONDITIONS OF THE CONTRACT Fv4 THE
CONSTRUCTION OF BUILDINGS
am of The American Institute Of Aro_hitea
This standard form of general conditions, fifth edlticn, has re-
ceived the approval of the Associated General Contractors of Am-
erioai the Contracting Plasterers' international Association; the
$eating, Piping and Air Conditioning Contractors National Aseooie-
tionj the National Building Granite Quarries Association, Inc.:
the National Eleotrioal Contractors Association= the Painting and
Decorating Contractors of Americas and the Producers' Council, Inc.
Fifth Edition, copyright 1915 - 1918 - 1926 - 1937 by the Ameri-
can Institute of Architects, Washingtons D. C. Reproduction of
the material herein or substantial quotation of its provisions
without permission of the American Institute of Arobiteots v=ow-'- ":
latex the copyright laws of the United States and will be subject
to legal proseoution.
INDEX TO THE ARTICLES OF THE GENERAL. CONDITIONS
1. Definitions.
23.Contraotor's Right to Stop Work or
2. Executions Correlation and Intent
Terminate Contract.
24,Applioatione for Payments.
of Documents,
3. Detail Drawings and Instructions.
25.Cert1fioatea Of Payment.
4, Copies Furnished.
26.Payments Withheld.
27.Contractor's Liability Insurance.
S. Shop Drawings.
6. Drawings and 8psoificatioas on
28.Owner'b Liability Insurancee
the work.
29.Firs Insurance.
7. Ownerahip of Drawings and Models.
30.Guaranty Bands.
8. Sample$.
31.Dmaages.
9, Materials, Appliances, Employees.
32. Liens*
lo.Royalties and Patents.
11.8urveys, Permits, Regulations.
33.Aesig=Ont.
34.Mutual Responsibility of Contraoto
12.Proteotlon of Work 4 Property.
35,Separate Contracts.
13.Inspeotion of Work.
14.Superintendenoss Supervision.
36.Subcontraots.
37.Relations of Contractor and Sub -
1560hangea in the Work.
18.Claime for Extra Cost.
contractor.
38.Arohiteot's Status.
170Deduotions for Uncorrected Work.
39.Architeot's Decisions.
le.Dslsys and Extension of Time.
40.Arbitration.
19,Correation of Work Before Final
41.Cash Allowances.
Payment.
20.Correction of Work After Final
4204e of Premises.
43,,Cutting, Patching and Digging.
Payment.
44 ■0leaning Up.
21.0wner's Right to do Work.
22.Owner's Right to Terminate Con-
tract.
ArtZ ja Definitions.
(w) The Contraot Doouments consist of the Agreement, the Gonerni l:o=i-
ditions of the Contract, the Drawings and Speoifioatiors,; .'r-
eluding all modifications thereof incorporated in the docolents
before their execution. These form the Contraot.
(b) The Owners the Contractor and the Architect are those mew,
such in the Agreement. They are treated throughout the
treat Documents as if each *are of the singular number arid rase
oulinb gander.
(o) The term 8uboontrastors as employed herein* includes only those
having a direct contract with the Contractor and it includes
one who furnishes material :#orked to a special design accord-
ing to the plans or specifications of this works but does not
Include one who merely furnishes material not so worked>
(d) Written notice shall be desm4id to have been duly served if de-
livered in person to the individual or to a member of the firm
or to an offloar of the co poration for whom it is intended,
or if delivered at or sent by registered mail to the lent b -asi..
noes address known to him i6O gives the notice.
(a) The term eworke of the Contractor or Subcontractor includes Unoi—
or materials or both.
(f) All time limits stated in the Contract Documents are of the ea-
senoe of the Contraot.
(g) The law of the place of building shall govern the construction of
this Contract.
t !�.&s_ $sew Oakrrelatidn add Inteht of Doouoents.r the Contract
"1'T mente shall be signed in duplicate by the Owner and the Contra,o%er,
_n orris the Owner and the Contractor fail to alp the General CO1)c'.4i,)u;,
0.10 irge or Speoifloations, the Architect shall identify them.
The Contract Documents are complementary. and tidhat is oa:leu -7-
a;* any One shall be as. binding as if called for by all. The intention cP
.se documents is to include all labor and materials* equipment and tra':.s-
7oreation necessary for the proper execution of the work. It is not ixi --
tcnd:)ds however, that materials or work not covered by or properly infer-
au]e from any heading, branch, class or trade of the specifications Shq-0 1
be mnpplled unless distinctly se noted on the drawings. Materials or wc.rk
d. "a a7.i.oad
in words whioh so applied have a well-known technical or trade
nLcr.Ling shall be held to refer to such reoognised standards.
A,;_t,�•3 Detail �Draw -nice and Instructions.- -The Architect shall furnish
',vat'L reasonable promptness, additional instructions, by means of drawi:,rs
or otherwise, necessary for the proper execution of the work. All *u.,s
d--ew'ings and instructions shall be consistent with the Contract Doouman'cej-"
true developments thereof, and reasonably inferable therefroma
General Conditions. Fifth Edition. Page 8.
The work shall be executed in conformity therewith and the Con+r
tractor shall do no work without proper drawings and instruotions.
The Contractor and the Architects if either so requests, shall
;jointly prepare a schedule, subject to change from time to time in so-
cEcrdanoe with the progress of the work• fixing the dates at which the
vgri.ous detail drawings will be required, and the Architect shall furnish
tb.%u in accordance with that schedule. Under like oonditionas a sohe-
oule shall be preparede fixing the dates for the submission of shop drew -
tngs, for the beginning of manufacture and installation of materials and
for the completion of the various pasta of the work.
art. 4. Conies Furnishs$.—Unless otherwise provided.in the Contract
Documents the Architect will furnish to the Contractor, free of ohargee
all copies of drawings and specifications reasoriably necessary for the
execution of the work.
Art. S. Shop Drswings.- -The Contractor shall submit with such promptness
se to cause no delay in hie own work or in that of any other Contractor,
two copies of all shop or setting drawings and schedules required for the
work of the various trades, and the Architect shall pass upon them with
reasonable promptness* making desired corrections. including all necessary,
corrections relating to artistic effect. The Contractor shall make any
oorrections required by the Architect, file with him two corrected copies
and furnish such other copies as may bo "needed. The Architect's approval
of such drawings or schedules shall not relieve the Contractor from re-
aponsibility for deviations from drawings or specificationst unless he has
n writing called the Architect's attention to such deviations at the tim.o
of submission, nor shall it relieve him from responsibility for errors of
auy sort in shop drawinge or schedules.
6. Drawings and Specifications on the bfcrk.- -The Contraotor shall
',cep one copy of all drawings end app ifications on the work, in good ur33r,
mailable to the Architect and to his representatives.
dzt 7. Ownership of Drawings and Wde s. --All drawings, speoifiost-ioss
Wed copies thereof furnished by the Architect are his property. They Ara
not to be used on other work and, with the exception of the signed Coll( `ao;•
Set, are to be returned to him on request* at the completion of the Y, J:
,Cl models are the property of the Caner.
Art. 8. Samples.- -The Contractor shall furnish for approval all say,•
99 directed. The work shall be in accordance with approved sampleac
Art. P. 910grisls. Appli cos. holoyees.--Unlesa otherwise stipu'..atac;.,
the Contractor shall provide and pay for all materials. labor. waters
tools# equipment, light power. transportation and other facilities ne-
oessary for the execution and completion of the work*
Unless otherwise specified* all materialso shall be new and tio`'r`
workmanship and materials shall be of good quality. The Contractor r.hs2la
if requiredt furnish satisfactory evidence as to the kind and quality n-
materials.
The Contractor shall at all times enforoe strict discipline and
General Conditions. Fifth Edition. Fags 3,
good order among his employees, and shall not employ on the work any un-
fit person or any one not skilled in the work assigned to him*
Art, 10. Royalties IMd Patents. -.The Contractor shall pay all royalties
and lioonso fees. He shall defend all suits or claims for infringement
of any patent rights and shall save the Owner harmless from loss on sn-
count thereof, except that the Owner shall be responsible for all such
loss when a partioular process or the product of a particular manufacturer
or manufacturers is apecified, but if the Contractor has information that
the process or article specified is an infringement of a patent he shall
be responsible for such loss unless he promptly gives such information to
the Architect or Owner.
Ldz 11, Burrell, Permits and Rogglatione. --The Owner shall furnish all
surveys unless otherwise specified* Permits and licensee of a temporary
nature necessary for the prosecution of the work shall be secured and paid
for by the Contractor. Permits, licenses and easements for permanent
structures or permanent changes in existing facilities shall be scoured and
paid for.by the Owner, unless otherwise specified.
The Contractor shall give all notices and comply with all laws,
ordinances, rules and regulations bearing on the conduct of the work as
drawn and specified. If the Contractor observes that the drawings and
specifications are at variance therewith, he shall promptly notify the
Architect in writing, and any necessary changes ahall be adjusted as pro-
vided in the Contract for changes in the work. If the Contractor performs
any work knowing it to be contrary to ouch laws$ ordinances. rules and
regulations$ and without such notice to the Architect, he shall bear all
coats arising therefrom♦
Art. 12, Protectlon of stork and Property.- -The Contractor shall oontin -
uousiy. maintain adequate protection of all his work from damage and shall
protect the Owners property from injury or lose arising.in oonneotion
with this Contract. He shall make good wW such damage, injury or lees*
except such as may be directly due to errors in the Contract Documents or
caused by agents or employees of the Owner. He shoal adequately protect
adjacent property as provided by law and the Contract Documents.
The Contractor shall take all necessary precautions for the safety
of employees on the works and shall comply with all applicable . provisions
of Federal, State, and Municipal safety laws and building codes to pre-
vent accidents or injury to persons on, about or adjacent to the premises
where the work is being performed. He shall erect and properly maintain
at all times, as required by the conditions and progress of the works all
necessary safeguards for the protection of workmen and the public and
shall post danger signs warning against the hazards created by such featurca
of construction as protruding nails$ hod hoists, well holes$ elevator,
hatchways, scaffoldings window openings, stairways and falling materials;
and he shall designate a responsible member of his organization on the
work, whose duty shall be the prevention of accidents. The name and po-
sition of the person so designated shall be reported to the Architect 1,y
the Contractor.
In an emargenoy affecting the safety of life or of the work or o'
adjoining property, the Contractors without special instruction or auti.o -: -.
cation from the Architect or Owners is hereby permitted to act, at his
General Conditions. Fifth Edition. page 4.
discretion, to prevent such threatened loss or injury, and he shall so not,
without appeals if so instructed or authorized. Any compensation' claimed
by the Contractor on account of emergency work#, shall be determined by
agreement or Arbitrations
a �9 Ina 'Peetion o Yfor. «The Architect and his rpresentativas shall
at rt all times have &oases to the work wherever it is in preparation or pro-
gress and the Contractor shall provide proper feel in for such &*odds
and for inspection.
I£ the speoificationa, the At t Instructy ns# JoLwet ordinances
work a be
or any public authority require any p approveds
the Contractor shall give the prohiteot timely notice o£ its readiness for
inspections and if the inspection is be another authority than thee Arab ot
toot, of the date fixed for each inspection. Inspections by the
shall be promptly made, and where practicable at the source Of supply* If
itymueti, if required aovered Arohiatectsapproval p t y
be uncovered for examinationatthe
Ccntraotorsa expense-
Re-examination of questioned work may be ordered by the Architect
and if so ordered the work must be uncovered by the Contractor. If such
work be pay the cost of re-examination and replacement, If Rush t Owner
Rushr
Mobefou dl not
in aocordanoe with the Contract Documents the Oontr&ator shall pay suai►
cost, unless he shall show that the defeat in the work was caused by anothor
Contraotors and in that event the Owner shall pay Bush cost,
It 14. Bunarin *endanoee 8uoarvision.- -The Contractor shall keep his
work, during its progress► a Competent superifttandsnt and ntY
superintendent .hall
aeaiatanta, all satisfactory to the Architect. The
not be ohanged except with the consent of the Architects unless the sunar�
intandent proven to be unsatisfactory to the Contractor and oeases to be in
aenoee and all directions given tohhhis shallabe as binding aeoifigIvan to
shall be i:Y.a
each Case. ua'nr,
The Oontraolor shall give efficient supervision end the all
his beat skill and attention. He shall carefully study mP
drnwinge, speaifioations and other instructions and shall at once rencrL
to ths Architect
shall not any but hold responsible tforytheir existence or disoover'rc3n�,P4
�1r'vr_ 15* Chnn�es in the �tcrk.- -The Owners' without invalidating the
tract, may order extra work or make obanges by altering, adding to 1• U
dunf;ing from the works the Contraot Sum being adjusted accordingly. Fix
:Xohark stall claimmeforaextension of conditions aenadjustaO
ex *epc th.t any
at the time of ordering such change.
In giving instructions$ the Architect shall have authority to m&ke
minor oha:sges in the work, not involving extra cost, and otnincOnsiss ay
with the purposes of the building, but otherwise, except
endangering life or property, no extra work or'ohange shall be made unless
General Conditions. Fifth Edition. Page 5-
In pursuance of m written order frem.thf Owner signed cr countersigned by
the Architect, or a written order from the Architect stating that the Owner
has authorized the extra work or change, and no claim for an addition to
the contract sum shall be valid unless so ordered.
The value of any such extra work or change shall be determined in
one or more of the following wayst
(a) By estimate and acceptance in a lump sdm.
(b) By unit prices named in the contract or subsequently
agreed upon.
(o) By cost and percentage or by coat and a fixed fees
If none of the above methods is agreed upon, the Contractors pro-
vided he receives an order as anode, shall proceed with the work. In such
case and also under case (e), he shall keep and present in such form as
the Architect may direct, a correct account of the coot, together with
vouoherse In any case, the Architect shall certify to the amount, including
reasonable allowance for overhead and profit, due to the Contractor.
Pending final determination of value, payments on account of changes shall
be made on the Arehiteot's certificate.
Should conditions encountered below the surface of the ground be
at variance with the conditions indicated by the drawings and specifications
the contract sum shall be equitably adjusted upon claim by either party
made within a reasonable time after the first observance of the oonditionsa
Art. 16.- Claims for Extra Costs .-If the Contractor claims that any inatruo-
tions by drawings or otherwise-involve extra coat under this contract, he
shall give the Architect written notice thereof within a reasonable time
after the receipt -at.such.lnSttuotlonii Amd.ln any event before proceeding
to execute the work, except in emergency endangering life or property, and
-- the procedure shall then be as provided for changes is the work, No such
claim -shall be valid unless so made*
Art. 17, Deductions for Unoorrgpted Jjjt. - -If the Architect and Owner
doom it inexpedient to correct work injured or done not in accordance
with the Contract, an equitable deduction from the contract price shall
be made therefor*
Art. 18. Delays and FixtensiorLof Tine.» -If the Contractor be delayed at
any time in the progress of the work by any sot or neglect of the Owner
or the Architect, or of any employee of either. or by any separate Can -
tractor employed by the Owner, or by changes ordered in the work, or by
strikes, lookouts, fire, unusual delay in transportation, unavoidable
casualties or any causes beyond the Contractor's control, or by delay
authorized by the Architect pending arbitration, or by any cause which tize
Architect shall decide to justify the delay, then the time of oompletioa
shall be extended for such reasonable time as the Architect may decide.
No such extension shall be made for delay occurring more tha -n ssv° -a
days before claim therefor is made in writing to the Architect. In the
case of a continuing cause of delay* only one claim is necessary.
If no schedule. or agreement stating the dates upon which drawirgss
shall be furnished is made, than no claim for delay shall be allowed on
General Conditions. Fifth Edition, Page 64,
account of failure to furnish drawings until tyro weeks after demand for
such drawings and not then unless such claim be reasonable.
This article does not exclude the recovery of damages for delay by
either party under other provisions in the contract documents.
Art 19 Correction o ^f Work Before Final Paymont.r -The Contractor shall
promptly remove from the promisee all materials condemned by the Architect
as failing to conform to the Contract, Yhother incorporated in the work or
not, and the Contractor shall promptly replace and re- execute his own work
in accordance with the Contract and without expense to the Owner and shall
bear the expense of making good all work of other contractors destroyed or
damaged by such rimovsl or roplaaese to
If the Contractor does not remove such condemned work and materials
within a reasonable time, fixed by written noticed the Owner may remove
them and may store the material at the expense of the Contractor. If the
Contractor does not pay the expenses of such removal within ten dayst
time thereafter, the Owner may, upon ten days' written notice, sell such
materials at auction or at private sale and shall account for the net pro-
oeeds thereof, after deducting all the caste and expenses that should have
been borne by the Contractor.
Art 20, Correotion of Work After Final Payment .- Neither the final oerti-
fioats nor payment nor any provision in the Contract Documents shall re-
lieve the Contractor of responsibility for faulty materials or workmanship
and. "lose otherwise specified, he shall remedy any defeo$@ due thereto
and pay for any domage to other work resulting therefrom, which shalloppear
within a period of one year from the date of substantial completion. The
Owner shall give notice of observed defects with reasonable promptness.
All questions arising under this article shall be decided by the Arohi-
teot subject to arbitration.
Art, 21, The Ownarla BUM to Do WO -It the Contractor should neglect
to prosecute the work properly or fail to perform any provision of this
oontraot, the Owner, after three days' written notice to the Contractor
may, without prejudice to any other remedy he may have, make good such de-
fiaisnoiss and may deduct the cost thereof from the payment then or thera-
after due the Contractor, provided, however, that the Architect shall app_ov
both such action and the amount charged to the Contractor.
Art, 22 Owner's Right to 'a tints Contract,- -if the Contractor should
be adjudged a bankrupt, or if he should make a general assignment for the
benefit of his creditors, or if a receiver should be appointed on account
of his insolvency, or if he should persistently or repeatedly refuse or
should fail, except in oases for which extension of time is provided, to
supply enough properly skilled workmen or proper materials, or if he should
fail to make prompt payment to subcontractors or for material or labor,
or persistently disregard laws, ordinances or the instructions of the
Architeot, or otherwise be guilty of a substantial violation of any provisic'.1
of the contract, then the Owner, upon the certificate of the Architect
that sufficient cause exists to justify such action, may, without prejudice
or any'other right or remedy and after giving the Oontractor seven dayal
written notice* terminate the employment of the Contractor and take possession
General Conditions. Fifth Edition. Page 7,
of the promises and of all materials, tools and appliances thereon and
finish the work by vAhatever method he may deem expedient. In suoh onsa
t?aa C .)ntra.otor shall not be entitled to receive any further peymeat nrtil
tray ^ :rri -s finished. If the unpaid balonoe of the oontract pri4e ai ah
C,r- c j t.,,a, expense of finishing the work including ocmpersatior fr.r ,d-
e. i. ; -' o al. I rana.gerial and administrative services, such exoass aha'.l "J,•
pat,! '.v t.e Contractor. If such expanse shall exceed such unpnii ba ,
tns C.)YtrAotor shall pay the difference to the Owner. The ex; onsF, .- se -;3-
by the Ctiraer as herein provided# and the damage incurred through the ^.,•-
traotorla default, shall ba certified by the Arohiteot♦
Art, 23. Contractor's Right to 9topWerk or Tenminate Cent ^sot W - -Tf the
work should be stopped under an order of any court, or other pub is nut'aorjty,
for- a rcriod of three months, throuja no not or fault of the Cont --t:or or
of rryone employed by him, or if the Architect should fail to isms ..,:.y
oe -4ii Pio!Ate for payment within seven days after it is due, or if tha CWIIi,r
sh;,uld fail to pay to the Contractor within seven days of its maturil- - -Y r.:'d
presen'ation, any sum oertified by the Architect or awarded by arbit,:a_tu s,
then the Contractor may, upon seven dayaa written notice to the Ormcc• anc
the Arohiteot, stop work or terminate this contract and reoover fro:2 Vla,
Ca+ncr payment for all work executed and any lose sustained upon any plant
or materials and reasonable profit.•and damages#
it. 24. Auplioations for Payments. - -The Contractor shall submit to tae
Arohiteot an application for each payment, and# if required, receipts or
other vouohers, showing his payments for materials and labori including
payments to subcontractors as required by Art. 37.
If payments are made on valuation work done, such application shall
be submitted at least ten days before each payment falls dust and, if re-
quired, the Contractor shall, before the first application, submit to the
Architect a schedule of values of the various parts of the work, including
quantities, aggregating the total sum of the oontraot, divided so as to
facilitate payments to auboontmetors in accordance with Article 37 (e),
made out in such form as the Architect and the Contractor may agree upon,
and, if required, supported by such evidence an to its correctness as the
Arohiteot may direot. This schedule, when approved by the Architect, s'1e l
be used as a basis for certificates of payment, unless it be found t:,
'_n error.. In applying for payments, the Contractor shall srbmit a s,; .o,+r e !!�
based upon this sohedule, and, if required# itemized in such form ar,) s
ported by such evidence as the Architect may direct, showing his rl,'
the payment claimed.
If payments are made an account of materials delivered and au'.1,.::.;;
stored at the site but not inoorporated in the work, they shell, If r. :-
quired by the Arohiteot, be conditional upon submission by the C "ontraator
of 'bills of sale or such other procedure as will establish the LAmor'c t]tle
to such material or otherwise adequately protect the Owners interost;,
Art.. 25. CertiPi,�atea oP Pevmentas. --If the Contraotor has made applioation
ws above, the Arohiteot shall, not later than the data %awn each payment
falls due, issue to the Contractor a certificate fdr such amount as he
deoides to be properly due.
General Conditions. -Fifth Edition. Page 8,
Yo certificate issued nor payment made to the Contractors nor par-
tial or entire use or occupancy of the work by the Orrneri shall be an
nooeptance of any work or materials not In accordance with this oontraot.
The making and acceptance of the final payment shall oonstitute a waiver
of all claims by the Owners other than those arising from unsettled liens,
from faulty work appearing after final payment or from requirement of ti:e
speoifioationss and off all claims by the Contractor, except those pre -
viously made and still unsettled.
Should the Owner fail tapay the sum named in any oertifioat�, o the
Architect or in any award by. arbitration, upon demand whah due. the vcy
tractor, shall receive* in addition to the sum named in the certifi.uate,
Interest thereon at the legal rate in farce at the place of building.
Payments Withheld.- -The Architect may withhold on on account
of subsequently discovered evidence* nullify the whole or a part of any
certificate to such extent as may be necessary to protect the Owner from
loss on a000unt ofi
IL) Detective work not remedied.
b) Claims filed or reasonable evidence indicating probable
filing of claims.
(o) Failure of the Oontraotor to make payments properly to
subcontractors or for material or labor,,
(d) A reasonable doubt that the contract can be completed fcr
the balance then unpaid.
(e) Damage to another Contractor,
When the above grounds are removed payment shall be made for
amounts withheld bsoause of themb
art. 2]`. gontraotorla Liability . -The Contractor shall maintain
such iaeuranoe as will protect him fr�ims under workmaills oompehsat <_cn
cots and from any other claims for damages for personal injury@ including
deaths which may arise from operations under this Contract, whether
such operations be by himself or by any subcontractor or anyone direotl•
or indirectly employed by either of them* Certificates of such insurc.ros
shall be filed with the Owners if he so requires and shall be subjeot t;
his approval for adequacy of protection.
Art. 88, Owner's Liability Insurances -The Owner shall.be responsible
and at his option may maintain such insurance as will protect him from nts
contingent liability for damages fox personal injury,, including deaths
which may arise from operations underthis oontraot*
Art. 29, FJU In Ehnoe. The Owner shall effect and maintain fire insur-
anoo upon the entire structure on which the work of this oontraot is to be
done to one hundred per cent of the insurable value thereof, including
items of labor and materials connected therewith whether in or adjacent
to the structure insured, materials in place or to be used as part of the
permanent construction including surplus materials, shanties, protective
fences, bridges, or temporary structures. miscellaneous materials and
supplies incident to the works and such soaffoldingss stagingp, toIreres
General Conditions. Fifth Edition. Page 9.
forms, and equipment as are not owned or rented by the contractor, the Goat
of v4ioh is included in the cost of the work. EX=SIOYSv This insurance
does not cover any tools owned by mechanics, any tools, equipment, soaf-
foldinga, stagings, towers, and forms owned or rented by the Contractor,
the capital value of wfiich Is not included in the cost of the work, or any
cook shanties$ bunk houses or other structures erected for housing the
workmen„ The loss$ if any, is to be made adjustable with and payable to
the Owner as Trustee for vdvom it may concern, except in such oases as
may require payment of all or a proportion of said insurance to be made to
a mortgages as his interests may appear.
The Contractor, on his written request$ shall be named jointly
with Owner in all policies$ all of which shall be open to his inspection.
If the Owner fails to show them on request, or if he fails to effect or
maintain insurance as above$ the Contractor may insure his own interest
and charge the cost thereof to the Owner. If the Contractor is damaged
by failure of the Owner to maintain such insurance, he may recover as
stipulated in the contract for recovery of damages•
If required in writing by any party in interest. the Owner as
Trustee shall, upon the occurrence of loss, give bond for the proper per-
formance of his duties, He shall deposit any money received from insurance
in an account separate from all his other funds and he shall distribute it
In accordance with such agreement as the parties in Interest may reach, or
under an award of arbitrators appointed, one by the Owner, another by
joint action of the other parties in interest* all other procedure being sa
provided elsewhere in the contract for Arbitration. If aft6r loss no
special agreement is made, replacement of injured work shall be ordered and
executed as provided for changes in the work.
The Trustee shall have power to adjust and settle any loss with the
Insurers unless one of the Contractors interested shall object in writing
-within threc working days of the occurrence of loss, and thereupon arbl�
trators shall be chosen as above. The Trustees shall in that case make
settlement with the insurers in accordance with the directions of such
arbitrators$ who shall also, if distribution by arbitration is required.
direct such distribution.
Art. 30. Guaranty Bonds. --The Owner shall have the right. prior to the
signing of the Contract• to require the Contractor to furnish bond cover-
ing the faithful performance of the Contract and the payment of all obli-
gations arising thereunders in such form as the Owner may prescribe and with
such sureties as he may approve. If such bond is required by instructions
given previous to the submission of bids, the premium shall be paid by the
Contractor; if subsequent thereto, it shall be paid by the Owner.
Art. 314 Damaeea. - -If either party to this Contract should suffer damage
In any manner because of any wrongful act or neglect of the other party or
of anyone employed by him, then he shall be reimbursed by the other party
for such damage.
Claims under this clause shall be made in writing to the party
liable within a reasonable time at the first observance of such damage and
not later than the time of final payment, except as expressly stipulated
otherwise in the case of faulty work or materials, and shall be adjusted
by agreement or arbitration.
General. Conditions. Fifth Edition. Page 10.
Art, U. Liensa-..Neither the final payment nor any part of the retained
percentage shall become due until the Contractor, if required# shall de-
liver to the Omer a oomplete release of all liens arising out of this
Contract, or receipts in full in lieu thereof and, if required in either
oase._ an affidavit that so far as he has knowledge or information the
releases and receipts include all the labor and material for which a lien
could be filed; but the Contractor may, if any subcontractor refuses to
furnish a release or receipt in full, furnish a bond satisfactory to the
Owner, to indemnify him against any lien- If any lien remain unsatisfied
after all payments are made. the Contractor shall refund to the Owner all
moneys that the latter may be compelled to pay in discharging such a lien,
Including all costs and a reasonable attornsy'a fee,
Art. 33, Assir- mant. -- Neither party to the Contract shall assign the Con-
tract or sublet it as a yihole without the written consent of the otherr
nor shall the Contractor assign any moneys due or to became due to him
hereunder. without the previous written consent of the Owner.
AArt 34 Mutual Responsibility of Contractors. -- Should the-Contractor
cause damage to any separate contractor on the work the Contractor agreess
upon due notice, to settle with such contractor by agreement or arbitra-
tions. if he will so settle- If such separate contractor sues the Owner
on account of any damage alleged to have been so sustained► the Owner shall
notify the Contractor, who shall defend such proceedings at the Owner's
expense and, if any judgment against the Owner arise therefrom, the Con-
tractor shall pay or satisfy it and pay all costs incurred by the Owner.
Art 35 Separate Contracts. --The Owner reserves the right to let other
contracts in connection with this work. The Contractor shall afford other
contractors reasonable opportunity for the introduction and storage of
their materials and the exeoution of their work, -and shall proper4 con -
neat and coordinate his work with theirs,.
If any part of the Contraotor's work depends for proper execution
or results upon the work of any other oontraotor,.the Contractor shall
inspect and promptly report to the Architect any defects in such work that
render it unsuitable for such proper execution and results, Hie failure
so to inspect and report shall constitute an accaptanoe of the other con-
tractor's work as fit and proper for the reception of his work, except as
to defects which may develop in the other contractor's work after the
execution of his work...
To insure the proper execution of his subsequent work the Contractor
shall measure work already in place and shall at once report to the Arohi-
toot any discrepancy between the executed work and the drawings,
Art. 36. Subcontracts. The Contractor shall, as soon as practicable after
the execution of the contracts notify the Architect in writing of the names
of subcontractors proposed for the principal parts of the work and for
such others as the Architect may direct and shall not employ any that the
Architect may within a reasonable time object to as incompetent or unfit,
If the Contractor has submitted before execution of the contract
a list of subcontractors and the change of any name on such list is required
General CondiQions. Fifth Edition. Page 11.
in writing by the Owner after such exeoution. the contract price shall
be increased or diminished by the difference in cost occasioned by such
change.
The Architect shall, on requestt furnish to any subcontractor, where -
ever praotioeble, evidence of the amounts certified on his account.
The Contractor agrees that he is as fully responsible to the Owner
for the aots and omissions of his subcontractors and of persons either.
directly or indirectly employed by them, as he is for the aots and omissions
of persons directly employed by him*
Nothing contained in the contract documents shall create any con -
traotual relation between any subcontractor and the Owner.
Art, 37. Relations of Contractor and Subcontractor.- -The Contractor
agrees to bind every Subcontractor and every Subcontraotor agrees to be
bound by the terms of-the Agreement. the General Conditions, the Drawings
and Specifications as far as applicable to his work. including the follow-
ing provisions of this article, unless specifically noted to the contrary
in a subcontract approved in writing as adequate by the Owner or Architect.
This does not apply to minor subcontracts.
The Subcontractor agrees.-
(a) To be bound to the Contractor by the terms of the Agreamentr
General Conditions* Drawings and Speoifications, and to assume toward him
all the obligations and responsibilities that he# by those documentse
assumes toward the Owner.
(b) To submit to the Contractor applications for payment in such
reasonable time as to enable the Contractor to apply for payment under
Article 24 of the General Conditions.
- (o) To make all claims for extras• for extensions of time and for
damages for delays or otherwise, to the Contractor in the manner provided
In the General Conditions for like claims by the Contractor upon the
Owner, except that the time for making claims for extra cost is one week.
The Contractor agrees --
(d) To be bound to the Subcontractor by all the obligations that
the Owner assumes to the Contractor under the Agreement, General Conditions,
Drawings and Specification• and by all the provisions thereof affording
remedies and redress to the Contractor from the Owner.
(e) To pay the Suboontraotor, upon the payment of oertificates,
if issued under the schedule of values described in Article 24 of the
General Conditions, the amount allowed to the Contractor on account of the
Subcontractor's work to the extent of the Subcontractor's interest therein.
(f) To pay the Subcontractor. upon the payment of certificates* if
issued otherwise than as in (a), so that at all times his total payments
shall be as large in proportion to the value of the work done by him as
the total amount certified to the Contractor is to the value of the work
done by him.
(g) To pay the Subcontractor to such extent as may be provided by
General Conditions. Fifth Sditions. Page 12.
the Contract Dooweents or the subcontraet, if either of these provides for
earlier or larger payments than the above.
(h) To pay the Subcontractor on demand for his work or materie.,la
as Car ae executed and fixed in place, less the retained pereerta so at
tha time the certificate should issue, even though the Arohitect fF-i:.e to
ise-le -.t for any cause not the fault of the Subcontractor.
(;j) To pay the Subcontractor a just share of any fire i.na ":nnoe money
rsoeivoe, by him, the Contractor, under article 89 of the General Gor;„;iticrs,
To ask* Ao demand for liquidated damageY or penal 11,19LY
in ary sum in oness of susk amount as no. be SpecIfioally named in t.Le
subcontract.
(1) That no claim for services rendered or materials furnished by
the Contractor to the Subcontractor shall be valid amore written notio3
thmrc:o_° in given by the Contractor to the Subcontractor during tha first
ten days of the calendar month fallowing that in which the claim originated.
(m) To give the Suboon+,_aotor an opportunity to be present Wid to
rub!-it ev'Aenoe in any arbi.trct,lon involving his rights,
(:) To name as arbitrator under ar'itration proceedings as provided
it the General Conditions the person nomirated by the Suboontractor, if
tha 602.6 oaa9e of dispute is the work, materialst rights or responsibili.-
tiaz oi' tae Suboontraototl or, if of the Subcontractor and any other sub -
acns: jointly, to name as such arbitrator the person upon whom ' ey
The Contractor and the subcontractor agree that—
(o) In the batter of arbitration, their rights and obligations
and all procedure shall be analogous to those set forth in this o::nt_na'j�
Nothing.in this article shall create any obligation on th9
of the Cwner to pay to Or to see to the payment of any sums to any G:b-
oon4;raotor.
rat- 33._m2hiteot "d Status._- The.Arohitedt shall have general supervision
fs..�'_ di:eotion of the world He is the agent of the Owner only to the Fr.-
tent provided in the Contrast Documents and when in speoial instances ba
is Lut!.ortyed by the Owner so to aotj and in such instances ha snail,
upe)n raruast, show the Contractor written authority. He has OLOAhoaits to
etc, t`.a rzrk whenever such stoppage may be necessary to inmuro ti,P cad=
exa:.ut'.on of the Contract.
As the Architect is, in the first instance. the interpreter of the
oondittuns of the Contract and the judge of its performance. he shall
aid) neither with the Owner nor with the Contractor, but shall use his
pc-v"-,,s •miss the contract to enforce its faithful performance by both.
In case of the termination of the employment of the Arohiteete the
Cwnor ohail appoint a capable and reputable Architect, against whom the
Qoni:ragtor makes no reasonable objection, whose status under the oontreot
sha'i he 'hat of the former Architect; any dispute in connection with such•. -_._..
apa,,in'.ment to be subject to arbitration.
General Conditions. Fifth Edition. Page 13.
Arto $4. Arohitectes Dwlsicros.- -The Architect shall, within a reasonable
timed make decisions on all oloims of the owner or Ocatraotor and on all
other matters relating to the execution and progress of the work or the
Interpretation of the Ooatraet Dopuunts-
The Arohit"V a deoisionsg in matters relating to artistic effect,
shall be final, if within the teams of the poatraet Document"
Except as above or as otherwise expressly provided in the Contract
Documents# all the Architeatts decisions are subject to arbitration.
1f, however, the Architect fails to reader a decision within tether
days after the parties have presented their evidence, either party may
demand arbitration. If the Architect renders a decision after arbitration
proceedings have been initiated, such decision may be entered as a ik d e
bat shall not disturb or interrupt am& proceedings except where
oision is acceptable to the parties concerned.
&,.t_ 40_ Arbitration._411 disputes♦ olaims or questions subject to ar-
bitration under this contract shall be submitted to arbitration in eo-
cordanoe with the provisions, then obtaining- of the Standard Foam of
Arbitration Procedure of The American Institute of Arohiteots. and this
agreement shall be specifically enforceable under the prevailing arbitra-
tion laws and judVeat upon the award rendered may be entered in the
highest court of the forum, state or federale having jurisdiction. It is
mutually agreed that the decision of the arbitrators shall be acondiittn�
preoodent ay v to any right of legal motion that either party m
the other.
The Contractor shall not cause a delay of the work during any ar-
bitration procee ding, except by agreement with the Owner.
Notice of the demand for arbitration of a dispute shall be filed
in writing with the Architect and the other party to the contract. If the
arbitration is an appeal from the Architect's decision, the d®and.therefor
shall be made within ten days of its receipt; in any other case the demand
for arbitration shall be made within a reasonable time after the dispute
has arisen; in no case, however, shall the demand be made later than the
time of final payment, except as otherwise expressly stipulated in the
contract.
The arbitrators, if they deem that the case requires it, are au-
thorised to award to the party chose contention is auetainedo such sums
as they or a majority of them shall doom proper to oompensate it for the
time and expense incident to the proceeding ands if the arbitration was de-
manded without reasonable cause, they may also award damages for delay.
The arbitrators shall fix their own compensation. unless otherwise provided
by agreement, sad shall "sees the posts and charges of the proceeding upon
either or both parties.
Art 41 Cssh Allowances. --The Contractor shall include in the contract
sum all allowances named in the Contract Documents and shall cause the work
so covered to be done by such contractors and for such sums as the Architect
may direct, the contract am being adjusted in conformity therewith. The
Contractor declares that the contract sum includes such sumo for r � s
and profit on account of cash allowances as he deems proper.
for expenses or profit other than those included in the contract sum shall
General Conditions. Fifth Edition. Page lb.
be allowed. The Contractor shall net be required to employ for any such
work persons igainst wham bs has a reasonable objection.
Art. 48. IIse of Presiacs. «The Contractor ahall cenflae his apparatus,
the storage of saterlals and the operation or his workmen to limits in-
dieated by two ordinances• posits or direetions of She Architect and
shall not unreasonably arAunbe!r the premises with his saterialgf
The ddbtraotor shall not lead or persit nay part of the structure
to be loaded with a might that will cndangsr its safety.
The Contractor shall sOoree the Architset *s iestrustions rogarding
signs* advertiseasmta* fires and asokipp
Art 43. Cuttitu. 'b-4-1142- end Ditg -the QOnttor mall de all cutting-
Art.
or patching of his work. that idoy be required to sake its ss►eral
parts oome together properly Nut fit It to resolve, or be received by work
of ether sontreators Shorn upulAS or reasonably implied by* the Drawings
and Specifications for the completed strtotarei and he shall sake, good after
them as the Architect ww .direst.
Any oo/t caused by detective or ill -timed work shall be borne by
the party responai�►ls therefori
i$►c Contrkotol..d all not ifidanger ady work by cutting, digging or
otherwise, and :ehal not i it .or, alter the j"rk of oW other oontraotor save
with the oonsent bf %hi Arehitestl
A�, 446 A— lj� .:�%1e iontisetoi sball at _all times keep the premises
free, Prot aeou�wlatio" of t'Aste;gaterial or rubbish caused by his amployees
or world and at the-baaplii4iin or. this work be shall move: ail hie-rubbish
from ate about the bailding end all,h1b t6016 scaffolding and surplus
materials and shall Jeave his.ugrk «btock.oleank or its equivalent► unless
more exactly ypeeiriedt tit baeo of dispute the Owner may remove the rub-
bish.and charge the cost to the several bodtraotors as the Architect shall
detoftins t6 be just&
Osnsr4 Conditions• Fifth Edition. Page 15.
STATE OF TIEW
COUNTY OF ,NMES I
811OV+ ALL USX BY THESE PRESSUTS 1 That was
of the City
of . and State of . as prinaipal sae,
authorized under
the laws of the State of Texas to eat as surety on bonds for prinoipals, are
hold and firmly bound unto the Oity of Corpus Ohristi, Texasv and to the pub»
oontraotora. worlenen* laborers* meohanios and furnishers of materials as their
Interact may appear, all of whom shall have the right to sue upon this bond,
in the penal am
lawful ourrenoy of the United States of Amerioat for the payment of which*
wall and truly to be made* we do hereby band ourselves* our heirs* executors*
administrators* and sucoessors, jointly and severally and firmly by these
presents{
THE CONDITION OF THIS BOND IS SUCH THAT. MSEREAS* The above bounden
has on the Of„�_�a
entered into a oontraot with the City of Corpus Christi* Texas* for
furnishing all materials, equipment, labors supervision and other aeoessories
neoessary for the oonstruotion of oertain improvements. as -more partioularly
designated in said Agreement and Speoifioations hereto attmohed.
NOW. THEREFORE. If the above bounden
shell and will faithfully perform said agreements and shall and will In all
respeots duly and faithfully observe and perform all and singular the Gove+
naata, conditions and agreements in and by said contraot agreed and oovenantad,
by the eaid to be observed and performedt
and a000rd°_ng to the true intent and meaning Of said Agreement and the Plana
and spso'_finationa hereto annexed, and as well during any period of sxteneior:
of said oontraot that may be granted on the part of`the City of Corpus Chris',:'
Texas* as during the original term of s*ime1 and shall well and truly pay 0.11
suboontre3tc rag workmen, laborers, meohanias and furnishers of material all
monsys to them owing by said
oontraots, work, labor and material done and furnished for the oonstruotion
of suoh improvements for the City of Corpus Christi* Texas* then this cbiA-
getion shall be and booms null and void{ Otherwise to main in full force
and effoot*
IN WITNESS rSHEOP, The said
has hereunto set his hand, and the said surety has ..used treae Fravvlt3 to
be 3xeouted by its duly authorised agent and offioeri and its ooT- IPotnke
seal to be hereunto affixed at this
# VAL �
OONTUBTOR
WITNESS
Q SEAL L
ADDRESS
ATTEST&
OF PERSON EAEOUTIhG .
- — t TY
ADDRESS
T?TLE
ExcRVA,IG dliD GRADING
Wcrk under this heading shall be done eubjeot to the General Conditions
written for the entire speciFioatioiisa whother attaohed hereto or note
and thle Contractor is notif±ed to refer thereto and will be responsible
fcr,:.l.l me Lkilremants made therein.
BQOpEe This Contractor shall Ow%vato for
R11 footings, stepst torraeoss slabse
ditohtsr and all ether sonerets pertinent to,the foundation of this build-
ing. This Contracter shall excavate all ditches for utilities as.noted
on the plans. Also, this Contractor shall do all baokfilling necessary on
the above excavations.
FOMINGBs Exeavato for all piore with .a msohani-
sal sxoevator and ream for footings
as indicated on the foundation ploh, The bottom of the footing exoavatien
shall be clean and free from loosi dirt*
BACUP111i Exosse material from the wwavatisns
shall be used to bring the fill under
the building to the level indicated on the plans. ;dyers excavations art
made for beamst baokfill with soil from this exoavation and tamp in not
lass than 1 21 layers.
All other excavations for pipe#,Ote.. shall be 5aekfilled with soil and
tamped as indicated in the above paragrapho
GRADING: Any grating lines thmm on plans are
for referot'" only. This Contract
does not include rasgh or finish grading. Me -to rk will be done by others
under a separate contract. Any excess ao`.;.. this Contractor has after book-
filling and leveling under buildings wO..1 t,y :7t4ck'p1IO4 w+hsre directed by
the Architea +.
BEHM MARK A benoh mark will be sot by the Archi-
tect for elevation reference, pinish
floor elevation will be set in relation to this bench marko
Fire "ion gpe Moations. Page 1.
Co^, Ca 1 way
,I tfork under this heading shall consist
of all labor and mmat*rialS necessary
for the placing of the sonerste work indloated on the plans and called for
aredeall Inoludeff finish ooneratefindinated oonersto floor joleta, slabs#
the plane.
C�9E All Oament shall oonform to the 49tandOA
A"T,
ape „ifioations and Tests for Portland
Cement* of the American Society for Testing
Materials—Send shall be Olean and sharp# free
from dirt,.loam and other foreign
materials. It ohs11 bs uniformly graded between the limits of a A and
0100 sieve.
G Gravel .hail be Olean washed Sravole
tt�
ranging In also from 1IN to 1 *• uni'
lormly graded within these limits- It shall contain ra clay balls. dirt
er other foreign material which will be detrimental to the strength o! the
finleh concrete.
All water ured In mixing concrete
WATER, aha']. an r0ezonable Clean and free
from any injurious impurities. The ancul't a.” was "�,9 - to bs used ir. mixing all
oonorc�ta shall be sa ,Grail. as possible in orc:ar to maintaj•n a 'workable mix.
The mixes• is to be fitted with a repeated foruoaoh �sucoessive batch. deter• so that th*
mine3 quantity of rater may be rep
MIRING AND PLACIAGI All mixer.; of concrete s6e11 be done
with a c eos-.anioal batch mixer of the
typo approved by the Arshiteat. The concrete shell be mixed in the Gr�
orateoshall remain in the mixer for approximately two minutes Concrete
shall be placed in the forms as rapidly ae possible after leaving afthe mixer.
and no concrete shall be used rhioh haste concrete shall be thoroughly
period of thirty minutes. In pleoingg eel so as
rammed and spaded into all corners and around all reinforcing at Ixturs, free from all
void4 eliminate
At leasttfour hours as all produce allowed between pouring vertical and
voidsnntal members and ooasl�.raatien joints shall be made as directed by the
Arch rohit iteoi; e
Reinforcing steel shall be m&JAfAO-
STULI
tared from now billet stook and shall
conform to the A.S.T.M- speoifioetione for mild re info ro: u� �d� ":
reinforcing steel s! all be proparly sat and thou nef bolts 6121 reialaroed.
with wire ties of eie3s shown on t::6 Plana- 5p
steel ahall be as indicated on the detpilso
Fire Station SD9Oif'"'tions' Page ?r*
FOR6iSs All lumber used for forms shall be dry
Southern Yellow Fine or equally suitable
Matoriale Forma shall be constructed so as to stand tamping and hole Aheir
a]i rmerts No oorArete shall be placed in forms ur_til oheaked by
tw:..
STRUCTURAL 0011URMTEs Al structural concrete shall be SW
tact high early strength. This_son-
orete shall be reinforced and placed as shown.
GONCRETE FWORBs Where tile occurs as a finish floor
materialo screed off slab and rough"
surface to receive grout incidental to setting tile.
Finish all other slabs with a monolithic finish in the following manners
Dust a mixture of (1) part of cement to (1) part of clean sharp sand using
about OW of this mixture to the square, As soon as dry enough to pormito
float aurface smooth to insure complete bond with slab. Trowel smooth.
Give surface a second trowelling, leaving surface with hard smooth finishe
free from blemishes, and trowel marks.
After slab has set* cover with lraft paper and keep moist for at least
seven days.
FLAGSTONgs 16hers f+.agstone is indicated, pro -oast
random ,tize oonerote slabs aw thick
with float finish. Pour with sonoreto ac epec Vi3d above. After initial
act has taken plaaa, brace surface and hose off loose material in order to
expose surface of larger aggregate.
EXPANSION JOINTS Provide expansion joint around slab in
Garage Room. This joint also occurs
around stub oolumn piercing center of this slab. This joint to be lfae
asphalt impregnated oeloEas 86 vide. ,loop top flush with aurfaos•of finished
slab•
Fire Station Speeifioationse Page S.
0 A R P ENT Rr L J o I Nany AND Fd ILLWORA
Work under this heading includes all wood frruaVie materialp door and window
framer, the fabrioation and manufacture of all oebirebs, shelves* doors*
windows* soreens* insulationo and all other items indicated as wood on the
plaa3'
QUAL17r OF UATERWAs The various grades and kind of lumber
herein apeoified shall be furnished in
strict aocordanoe with the grading laws of the Lumber YanUfasturerwz Assasi+
ation under vitas* 4upervie4r& sash particular kind of lumber is SaWfaotar+ode
All framing lumber* exoept where spesified otherwise* shall b0 642 yellow
pine as manufactured by a Class A Vill. All lumber used in the building
shall be straight and true and no wedging or scabbing will be permitted to
straighton lumber vhieh would otherwise be defective. Any lumber contain.
ing loose knots* bark or showing signs of d000mpositioa will not be permitted
under W circumstances. All lumber shall be of sizes noted on the drawings
or specified herein.
DCORB& Install door and zeroes frames w der
tailed* manufactured from clear yellow
pine and cypress--exterior framme& of cypress and interior freass or pine.
1�INDOirSe Install awning type sash complete with
screen as detailed. The sash are to be
Of cypress and shall be secured from the Bate City lash and Door Co.* no
Lauderdale. Florida.
ADJUSTABLE LOWERS (or JALOUSIES)& Install as shown. These are manufat-
turgid by the above named zonoern.
EITCHEN CABINSTB&
Install cabinet as shoes On details.
This cabinet shall be built to zoom•
aodate the the drain and splash.
LINEN CABFW. a
Install 1.1non cabinet az detailed.
HOES STORAGE RACE IN GARAGE ROCUI
Provide shelves as shown in apparatus
room. These shelves are to aoocmmodate
rolled lengthen of fire how.
WOOD BASE
Provide 40 wood base with base shoe
in kitohen and wherever wood frame
wall occurs.
CLOSE. TMVISSs
Preric3 'O 11noal re"t off' 18" shelves
febrioa'`ed f'rLa o: -ar yellow pine or
fir in o'.oswts No, (a) and (11),
Lairs .station Page G.
SHEETROCKi Apply 1 /8e sheetrook to all ceiling
surfaces over stripping as indicated.
Also apply sheetrook to wall surfaces where wood framing occurs as indicated
on plans.
OVERHEAD DOORS; Provide two (p) Kinnear DeLuxe Model
R.'. -Top overhead doors where indicated
on plans, Thees doors are to be manufaotured from clear fir or cypress and
are to be oom_rlete with hardware and &;.tompeJo cpenero Jamb arrangement at
junction of a'Lono and tile to be av reoommendad by manufacturer.
A002, FRAkITNGt Frame roof as shaven with Nor 8 yellow
pins. Wood sheathing on deck over
save projeotion to be #3 yellow pine or fir, center match, laid straight
and true with uniform joint.
Facia piece an ends of lookouts is to be of Heart Cypress.
Provide screen and stops for oornioa vent as shown.
WOOD VIALLS ABOVE AND BELOW VIND00a Provide framing of No. 8 yellow pine
as shown for wood walls. Cover studs
with lb# asphalt felt and apply No. 1 vae «joint pine shiplap.
Provide 4 x 8 pins beam over rear entry as shown.
INSUTATIONs Insulate roof of entire building with
to rook wool. Install between joists
and tack into place as dlrsoted,
GLAZINO AND CAULKIN0s Glaze all sash and doors where indicated
With double strength Be grade window
glass.
Caulk around all openings$ behind screen stop at cornice where it touches
stone wall; at point where siding butte to scrte jambi and at all other
points where necessary in order to secure weathartight and invest proof
joints between various materials. Use Horne Vuleatex or equal gun grade
caulking compound*
HAWYAREI Allow the sum of one hundred dollars
($100.00) for finish hardware• The
hardware is to be selected by the Architect.
MIFRORSt Provide 1/48 plate glass mirror on
wall of dormitory as indioated. This
mirror to be 81 -06 x 0$ 00 attached to wall with 6 screws, each screw
covered with approved type rosette* Edges of this mirror to have gasket
of rubber or cork in order to insure t;ght fit with wall:
Provide 1 /4• plate glass mirror as indicated Over Poel-es on wall of toilet,
stall in tollg�l roft. This mirror to be attaohac: w_ta t scraw's and gasket
Fire Station Specifications- Page 5.
as for mirror mentioned above. Size of mirror to be 21 -0e x 4t-00 (set
horlsoAtally).
MEDICINE CABINSTBS Install two (2) medicine cabinets in
toilet room where showA. These o abinots
are to be Lawoo 0999 or equals metal cabinets, complete with mirror. Set
at height directed by the Architect-
MKAL TSRESHOLDSt Provide metal thresholds OIL all outer
81 a dosi•s„ Type of threshold that
Contractor proposes trePsrabUtthat us asVthrsshoids be providrdi It notes
before use. It is p
available, cast iron may be substituted.
SMVBB ON TOILET PARTITION Provide shelves sh this partition as
TOZL$T AOCii� indiooted. fabricate from 3/0 yellow
IN pine and sover.tops of shelves Vith
%hits earrara structural glass. Hang two (2) towel racks as tarnished by
plumbing Contractor to underside of bottom shelf.
Install It Gypsum Board $ heathing on
0178IN DEC&INGi roof deok. Nail phis sheathing to root
deok with 10 ponny S vanised boxing nails on approximately 12" centers*
pill joints and any sui'faes imperfections with Gypsum plaster or inn ofd
plaster. Deck must present 0900th unbroken surfsaa for app
built -up root.
81re station Specifications. Page g.
9 A a ON R Y W O R K
SCOPE) This work includes all stones hollow
tile and glazed structural tile as
shown on the drawings.
STONES Stone exterior wall to be sawn face
Austin Shoji Stone in approximately
equal quantities of 5.1/46 and 5'e heights laid random ashlar pattern with
1 /2e mortar joints. Stone Anal be laid in mill lengths wing as long a
run as is possible. Race joints to concave section.
TILES 11hore the walls are shown, use smooth
faced 5 x 8 x 12 load bearing tile to
form wall thickness as indicated. Rake all joints and wipe tile face clean
to receive paints (See Paint Spec ifioationso) There glazed structural tile
occurs# use 5 x 6 x 12 tile glazed one face on stretchers and glazed two
faces on outside corners. Lay complete with cove base section to member
with floor tile.
Split all the to work around concrete and steel structural members in order
to provide uninterrupted tile wall surface.
MORT,LRs Mortar for stone and hollow tile shall
be composed of one part Portland cement*
one part lime putty and 5 -1/2 to 6 parts sand or, at the option of the Con.
traotor, one part masonry cement and three parts sand. The mortar shall
be used so that it will be in place before the initial setting of the 00-
sent has taken place. Retespering of mortar in which the cement has started
to set will not be permitted.
WOOD BASE IN RITCHEAs Provide wood blocks at floor in kitchen
walls for nailing 4e wood base.
WEEP HOLESr Provide weep holes for space behind
stone at top of beam supporting name.
Insert porcelain insulating tubes on 38.0w canters around entf.re building,
WORMANSHIPs All beds on whioh stone and hollow the
are to be laid shall be clean and wetted
properly and, unless directed otherwiset all store and the shall be wetted
thoroughly before being laid. Stone and tile work aha:.l be built level,
squaret plumb and true. All bolts, anonors9 plags, ties and other metal
work shall be placed in position, where praotiomblev as the work progresses.
Chases of approved dimensions shall be provided in walla vkiere necessary.
All head joints shall be filled eompletely with fresh mortar. Bed joints
shall be full, flat and of uniform thioknese, not furrowsde Cross joints
shall be obtained by applying a full bed of mortar on the entire and of the
stretcher or on the entire edge of the headers as the case requires, and
Fire Station Speoifioations. Page 7e
then shoving the unit tightly against the units already laid. Tile shall
be laid with horizontal joints lave'!. s-id the vertioal joints staggered.
Joints shall be reasonably uniform in thloknase, being not more than 1 /2e
thiok. Care shall be taken to preserve the interrupted mortar joint in
laying the tile. Mhere anchors, bolts, and other tins, built-in as the work .
progressess 000ur within the oelle of tiles, suoh tires shall be filled with
1 to a to 4 conarete or with 1 to 4 Portland oement mortar.
BAWN STONE HEAD AND SILL IN
GANAGE WINDOW Cs
ULL TIES&
tile oourss as noted an plans.
Provide sawn shell sc)na shapes as
indioated on details.
Provide wall ties of 1 /4e bars bent
as detaildd. Install every fourth
LINTMAs Lintels dot otherwise shown shall be
farmed of hollow tile filled solid
With 1 to A to 4 eonarate With not less than two 3/4s round deformed full-
length rdinforoing bars. They shall be built on the ground and allowed to
met for at least six days before being moved. The lintels shall be straight
and true and shall have a lust 80 bearing at eaoh ends
STOA1 SILLS. Where windows odour in stone wails
provide shell stone sill as shown.
FOUNDATION VENTS- Install es x 180 marooned oast iron
vents am manufaotured by Alm* Iron
Worku Catalog No. 85. Loestion of theme vents indioated on elevations.
TU S BASES Lay one ooerse of a x 8 x IS glazed
Peas strubtural tile at floor level
to form base. Hold bank 1/42 from face of wall above. This ocoure in all
rooms emept the kitohelu
APPROVAL OF SAMPLES. The Oontraotor shall submit for approv al
and aooeptanoe samples of tile proposed
to be used before execution of any of the work under this heading.
CLEANINOe All stone work and the work shall be
thoroughly cleaned and left free of
exoses mortar, paint, or f6ftl n matter.
NOT&s Glazed structural tiie odours as soainsoat V-O' high in garage robto,
and in toilet room.
Fire Station Speoifisations. Page Bo
T I L E AND L I N O L E U M
SCOPES This work includes tile on toilet
room floort tile drain and Splash in
kitchen on eabinets, and liaoleas floor in the kitchen.
TOILET ROOM FLOORS Lair la hexagonal oer.-mic the on floor
of -�cilst sco.. This floor occurs ale*
in showers. provide 34 curb in door of show ,)r stallsv shim shall be glazed
white tile• This the floor shall member vrith vcva'bace of wall tile.
TILE DRAIN AND SPLASHi Lay 1.a hexago:zel ceramic the an deck
with 2 x 6 glazed white nosing. Splash
to be 4 x 4 T&Ite glared tile with Ea bull noses scat joints with white
cement.
LINOLEUM FLOOR IN EITCH39i Lay standard Snip linolaea on floor
of kitchen. Lay 15# felt OR Slab
with linsleua paste end assent linoleum to felt- Set base shoe over lino -,
leus. Glean and wax floor with Armstrong's Linwlaus Tax.
Tna SZLLBs Provide quarry tile sill is window
and louver openings in toilet r*aas.
Bull nano tile splash around masonry to form sill in kitchen windc*$a
Fire Station Speoifiaations. page 8.
s008Rs This work includes complete bonded
roots fleshings vents for heatersr
hood over rsngs• and gravel guard.
install Barrett's 20 -Year Bonded Built -
ROOF'S
Up Root with gravel surfsoe. Install
26 gauge galvanised iron gravel guard as detailed. landironnasrdiash
Intersection of root and stone W11 'Kith 26 gauge ga vaniz
rooted..
VENTB� Provide 40 weatherproof s roof hoodfor the
!flashing and d �
hot water heater, the two wall heaters and the Suspended heater in the
garage space. Vent for heating unit in Closet Nos 10 to be 50 round trans
lte pipe complete with flashing and head as above.
Provide 9' x 41 • 26 gauge galvanized iron hood over kitchen range. Vent
to roof with 6e round pipe fladh and provide as rotary ventilator above
roof.
Fire station Speolft— tions. Page 10s
PA I_NT I4G
SCOPES This work inoludes all painting, filling,
etc., necessary for the satisfactory
completion of the finish on all wood, metal, tile and sheetrook surtaoes,
OENERALs All materials used for this work will
be Pittsburg or equal first grade paint.
PREPARATORY VDRBs All surfaces to be painted shall be in
proper condition before the work is be-
gun; that is, the surfaces shall be perfectly dry, clean and smooth. In case
any work is detective or unsuitable for finishing, the painting contractor
shall notify the Architect of the fact in writing. If the Architect is not
so notified* the painting contractor will be held solely responsible.
MATSRIALSr All materials coming under the painting
contract shall be delivered to the build+
ing in unbroken paokages, bearing the brand and manufacturer's name. Such
materials should be used without any adulteration, and only with such thinning
as called for in the manufacturer's specifications, In the case of sealed
packages. the seal should not be broken until the contents are to be used.
Materials must be at all times subject to the inspection and approval of
the Architect,
PATCHIRCM Carefully patch and finish all work in-
ured from vuhatever 09498 to the satis-
faction of the Architect► At completion of the vuork's the entire work should
be in perfect condition acceptable to the Architect.
PUTTYa *Al nail holes, cracks* eta., must be
filled with linseed oil and lead putty.
CLEANINGS At the completion of the workp remove
all surplus materialo rubbish. eta.
Clean off all paint@ sto., from the floors, glass, walls, .too, and leave
the premises in perfect condition scceptable to the Architect.
EXTERIOR VOOVIOR&S All exterior woodwork stall receive
one coat of primer and two ooats of
gas -proof paint, color to be @*looted by the Architect.
INTERIOR WOONORB AND METALS All interior woodwork and metal shall
be given one coat of undarooater. $and
down with 00 sandpaper. Second coat shall be 1/2 underooater and 1/2 enamel
of elightly different color, well sanded. Third and fourth coats shall be
nemj_gioss enamel, flowed on as it comes from the container. The surface
Is to be uniform in gloss, finish and color and to be free from all brush
marks.
Fire Station SpecifioaUons. Pap 11.
GALVANIZED GRAVEL GUARDS AND Paint galvanised gravel guards and ex-
EXTERIOR MWALi terior metal with one (1) coat of
metal primer and two (2) coats' Of
Portland cement metal paint#
SFiISTY.O Z CGILI9084 Tape and fill all seems with shestrook
joint systemo sand seems down until
invisible on surface. Textone all ceilings and paint with tom (2) coats
of Ta::tc:ite or equal# except ceiling of garage• toilet room end rear entry#
whioh shall have two (2) coats of IkIlhide.
TILe,',+"s Paint interior smooth faced the walls
with two (2) coats of Portland cement
masonry paint# color of this paint to be selected by the Architect. (Two
(p,) coats or Wallhide paint nay be substituted for the above mentioned paint
If desired by the Paint Coltrooter).
Fire station Speoifiostions. Page 12e
j L& 2 T R 10 A L W O L F
The work to be done under this contract includes the furnishing of all -
labor. materials* equipment and services necessary for and reasonably i —
oidental to the proper completion of all electric wiring aF shorn on tha
drawings and herein spooifledo snoepting only work or materials specified
or noted as being done or furnished by others.
In general, this consists of the installation of a system of lighting. wiring"
and ecr_neotions from the service entrance to all parts throughoutc and empty
oonduit for fire swarm system and telephone circuits. This also inoludes
underground service f rqn north side of Louisiana Street.
CODES AND PSMITSr !This Contractor shall Purnish and ino
stall the materials £or the completion
of this work in strict accordance with the National Electric Code and the
Electric Ordinance of the City of Corpus (bristle Texas, unless specifioally
stated otherwise herein.
The Contractor shall give all requisite notioeso obtain and pay for all
permits and pay for all deposits and foes necessary for 'Cho installation
of the work under this contract, including all expenses. deposits, fees.
permitse sto., necessary for the inspection and approval of the work.
TYPE OF SCRVICEs Underground service will be supplied
from the Power Company's mains and will
be 220 volt* single phAseo split to 110 at panel into three wire grounded
neutral system.
This Contractor shall cooperate with the Power Company in the looating and
setting of their motoring equipment.
SERVICE ENTRANCE- Thid Contractor shall extend the under-,
ground service from the termination
of the Power Company's service wires into the building through a earvioe
entrance approved by the Power Company and the governing codes,
SWITCHES AND PANEL HOARD- This Contractor shall furnish and in-
stall where shown one No -Fuso Lead
Panel made up of 0 single pelf 15 ampere circuits. This pa:lel shall be
mounted at loostlon as shown. No substitute shall be used.
Place disconnect switch in service load between lead panel and meter* Run
eervioe lead from this switch to Closet Now 10 for service to heating unit
and suspended heater in garage. Provide furred safety swltohos a000rding to
governing codes.
TYPE OF WIRING& All wires for lighting, oonvsnienoo
outlets, heater circuitst telephone
and alarm circuits. and switches shall be run in rigid galvanised conduit.
Piro Station Speetfioations* Page 12. -.. .::uw.- - "g o..
UATERIALSt All materials shall be of mannfaoturerhs
first line grades approved design, and
meeting the requirements of the governing 004661, Any materials not satis-
factory to the Architect shall be replaced by this Contractor at his own
expense.
All outlet boxes and switch boxes shall be of galvanized steel (or steel
plated). They shall be equipped with readily removable knockouts and so
Installed that the switch plates and other dovioes attached to them match
and fit the adjacent finish. Fixture studs shall be provided in outlet
boxes and cull be securely fastened in an approved manner. If after the
finishing is complete, e'W of the outlet boxes or switch boxes project or
rsoess too fare they shall to reset at this coatraotor's expense.
ell fittings shall.be of an approved design, weatherproof and eadnium
plated. All connections suit be made with the approved fittings.
LIOSTtXG OUTLSTSh Outlets_ shall be installed as shown, '
an plane and shall be properly centered
with respect to paneling and other interior finish, Outlet boxes 4" in
diameter and 1-5/84 deep shall be installed at all lighting outlets and
equipped with 3/8" fixture atuds. All outlet boron shall be securely
fastened.
WALL sWITCHM Wall switches shall be installed singly
or in gates as shown on the planse
located 4'rOe above the finished floort unless otherwise speoified, and ooa-
noted Be as to provide the :.ndioated control of outlets,
All switches shall be of the flush tumbler square handle type, single pole.
of 15 ampere 125 volt rating, at least equivalent to Hubbell's. Color.ef_
switches to be as selected by Architect. switch plates shall be of genuine
Bakelite construction equal to Hubbell's best grade.
COMMENDS OUTLET81 Sxoept as otherwise noted, all rem
oeptaoles shall be standard flush
duplex type rated at 15 80mpero and 185 volts# adapted to receive a standard
"rang plug. 1io plugs for these receptacles to be furnished under this
contract except as notedi plates shall be equal in design and oonetruotlon
to switch plates.
Provide one outlet in Living Room for radio antenna and ground connection.
Run eritenua lead to roof. Antenna to be installed by others.
FIRE ALARM CIRCUITS: Provide two le empty conduits for fire
alarm circuits. Entrance of this oir.
ouit is shown on Mechanical Pion. This conduit will be installed under the
direction of the Fire Department of the City of Corpus Christit Texas.
Fire Station speoifiestions. Page 13.
TELEPHONE OIRCUITe Provide 1 %$0 empty conduit as shore'► on
Mechanical Plan. This installation
shall meet the requirements of the local Telephone Compapy.
VAPOR PROOF LIQHTS✓I
The fixtures in the,toilet roam are to
be vapor prW.
TEMPORARY POWER SUVIC&I Electrical Contractor shall install
temporary porter service for use on
Job* The General Oontraotor shall par for the electrical energy consumed
during oonstruotion4
WSATHMROOF CONVENISMS OUTLSTar Install approved weathe-zTroof re-
ceptacle rfters ird. oared on Mechanical
Plan.
UNQERGROITO iNTRANCESS The power service as noted above is
to be run underground from the building
to north eids of Louisiana Street as noted• Run conduit and conductors
lot above ground on pole at this point.
Tao (2; arptr ;." conduits for fire alarm circuits shall be carried from
the building to the same, point aoroes Louislana Street. Run up pole 101
and plug.
One empty conduit shall be enrried from the building to the same point aoroes;
Louisiana Street. This oordui.t is to be used for telephone servioeo Install
accordingly. Run up pole 141 and piugo
Bury the tUvelmentioned conduits 4' below surface of existing street
(Louisiana. Street).
Fire Station Specifications. Page 14.
ZLvLWBINj...
LAWS AND ORDINANCES+ Except as otherwise specirioally noted.
the Contractor shall install all Ymrk
described in these specifications and shown on the plans as plumbing and
gas work and in accordance with the Corpus Christi City Ordinances.
The Contractor shall be responsible for each and *very violation of the
public ordinanoess and in no aaee shoal the Owner ba liable for any damage
or expense arising herefrom.
No cutting to be done by the Plumber except as permitted by the Contractor
or Arohiteot.
All soile waste. vent and sewer pipes inside the building.shall be plugged
at the bottom, Std all pipes shall be filled to the top with water in the
presence of the Architect and examined.
All leaks are to be made tight and the test to be repeated until all work
is perfectly ti;'ht.
No work of any kind shall be oovercd up until inspected end approved by
the Inspeatcbe
Traps shall be placed for all fixtures.
All trope shall be vented as required by Ordinance.
The drawings are to be accurately followed{ preference being giveh to the
graphic dimensions over aoaler
MINGs All water supply shall be 1 *.galvanised
iron# run 1 /2e from supply to fixtureo
pas piping shoal be black iron pipe, 1 -1/80 supply reduced to size of fix-
ture as neoessaryi
us SUPPLYI Run 1 -1 /2e wrapped steel pipe Tram
property Jibe to meter loop( ks shown
on Mechanical Plan and Plot Plan] {trap and dope all joints to the eatis-
raotion of the Architect. Continue this 1 -1/2`n supply from meter to point
adjacent to heater in closet No. 10. supply all outlets from this point
with pipe sizoe.saoording to plumbing ordinanoeo
SEWER# Install waste lines and vents with cast
iron soil pipe according to City Plumb-
ing Ordinance. Run oast Iron waste to point 10' from building. Continue
to City Sewer with vitrified clay pipe with approved joint. Provide grease
trap in kitchen waste line at point shown on Plot Plan. This trap to be.a
Dickey, or equal, 840 diameter vitrified clay complete with vitrified cover.
Fire station specifications. Page 15,
HOT WATER HEATERs Install in Closet Not 10s as shown on
Mechanical Plani, a Crane Royal Sire
55 -70 gas fired water heater complete with a 4Basmor4 pressure relief valve.
Provide a return from kitchen and toilet in such a manner as to create a
olroulaM,ng system.
FLOOR DR4I,,)As 11here floor drains are indicated en
Mechanical Plant provide Grans Drain
No. 34552 with 20 outlet and 40 strainer.
SERVICE SIM provide service sink in garage roam.
This sink to-be a Crane 0- 21321 -B -
200 x 180 - Fixture 0 37880-11. Trap 0 81420 -4. Rim Guards 0 21500, This
is a well hung fixture. Proper supports shall be provided in mabonry wall
by plumbirg contraotor. Adjustable 'Woo oa trap to be removed.
LI.:T OF FINMRSSt
Mogetsr 0E -11661 Banton S.J6 Moset Combination complete as shown and
described.
Liavatoriess 9E-754 -V 18 x 20 vitreous ohina lavatories complete as shown
and described.
Urlralas CE -17620 Santo wall urinal fitted with No„ 110 YO Flush Valve
complete.
Shower Valvess 0E -4265 1/26 galvanized iron concealed shower valve with
am and headi
Sinks CE -19566 16 x 24 Du ftoley F.R. sink fitted with CE -32751 galvanice3
iron faucets 0E -33878 galvanized iron sink atrainert CE -33976 1-ahe
blk. iron "P" trap.
No„ 330 Balmer 184 opal glass shelves with white ohins, braaketso
No. 324 Balmer 244 towel bars.
No. 610 Balmer 6 x 6 reason paper holder.
No. 387 Balmer 3 x 6 recess soap holder.
OERTIFICATIONs
1 hareby osrtify that I have read these specifications carefully and have
a olear understanding of their contents and do hereby agree to comply with
the iater:tn and purposes in said specifications in the furnishing of mater!_A7
and ;er`.brmina of work in a first class workmanlike manner.
CONTRACTOR
Fire Station Specifications. Page 16.
HSATINGi Install a Janitrol model ?.A-C, 180..14
am equal forced air heating unit, This
unit shall be gas fired with an output of approximately 1006000 B.T.U.
complete with automatic controls, thermostat and 110 volt A.C. motor. These
controls shall be Minneapolis Honeywell: or equal, meeting the approval
the Architeot. This unit will be installed in Closet Hod 10.
Grilles to be provided..
fupply grilles - -Three 14 x 4 Tuttle and Bailey multi - shutter flex air model
No. 68.
Return air grille --Ons le z 18 Tuttle and Bailey Airline No. 00.
Install a suspended unit heater In garage roan.. 65,000 B.T.0 output equal
to Model U" 65 -14 Janitrol with standard automatic controls with 110 volt
A.C. motor, This heater has 3/4 gas supply,
, r. `'z ii a i_,_� : ?, Peg3 I'l,,
SECTION 2. The fact that there is an urgent need for
enlarging the fire department of the City of Corpus Christi by
the construction of additional fire stations for the proper
protection of the City of Corpus Christi and its inhabitants and
their property creates a public emergency and an imperative public
necessity requiring the suspension of the Charter rule or require-
ment that no Ordinance or Resolution be passed finally on the date
of its introduction, and that said Ordinance or Resolution shall be
read at three several meetings of the City Council, and the Mayor,
in writing, having declared that said public emergency and impera-
tive necessity exist and having requested that such Charter rule
be suspended and that this Ordinance be passed finally on the
date of its introduction and take effect and be in full force and
effect from and after its passage, IT IS, ACCORDINGLY, SO ORDAINED.
PASSED AND APPROVED this, the A day of
A. D. 1944.
MAYOR, City of Corpus Christi,
Texas
ATTESTf
A� Y s.
city are
APPROVED AS TO LEGAL FORMS
Atto rney
CORPUS CHRISTI. TEAS
194 4(
TO THE MEMHERS OF THE CITY COUNCIL
OF THE CITY OF CORPUS CHRISTI
Corpus. Christi, Texas
Gentlemen:
For the reasons set forth in the emergency clause of
the foregoing ordinance, a public emergency and an imperative
necessity exist for the suspension of the Charter rule or require-
ment that no ordinance or resolution shall be passed finally on the
date it is introduced, and that such ordinance or resolution shall
be read at three several meetings of the City Council; 1, there-
fore, hereby request that you suspend said Charter rule or require-
ment and pass this ordinance finally oa the date it is introduced,
or at the present meeting of the City Council.
Respectfully
orpus s
Tease '
The Charter rule wets suspended by the following vote:
A. C. McCaughan
Jos. Mireur
Ed. P. 7H1liame
D. A. Segrest
B. G. Moffett
The above ordinance was passed he following vote:
A. -C. McCaughan
Jos. Mireur
Ed. P. Mlliams
D. A. Segrest
B. G. Moffett
-W