HomeMy WebLinkAboutC2010-011 - 1/12/2010 - ApprovedCHANGE ORDER
Department of Engineering Services
City of Corpus Christi, Texas
CHANGE ORDER NO: 1 FUNDING SOURCE: _ and 2008 CONTRACT TIME (CD): 180
Operating Department: Parks and Recreation
DATE: November 24, 2009
Name of Project: H.E.B. and AI Kruse Tennis Centers Court Improvements (Project No. 3391)
Contractor: Infinity Builders, Inc.
CHANGE ADD DEDUCT
ADD painting of 7 tennis courts at Al Kruse Tennis Center
(7 courts @ $6,743.00 each)
$47,201.00
Total $47,201.00 $0.00
TOTAL THIS CHANGE ORDER 547,201.00
Why was this change necessary? (If left off the plans and specifications, explain why?)
Painting of the 7 remaining courts at Al Kruse Tennis Center is necessary to repair deterioration of the court surfaces and improve usability.
How can similar changes be avoided in the future?
N/A
A. CONTRACT PRICE $ 249,000.00
B. TOTAL CHANGE ORDER (inc. current) $47,201.00
C. NEW CONTRACT PRICE $ 296,201.00
D. THIS CHANGE ORDER $47,201.00
E. PERCENT TOTAL CHANGE (B/A) 18.96%
F. PREVIOUS TIME AUTHORIZED 180
G. ADDN'L CONTRACT TIME THIS CHANGE ORDER 0
H. TOTAL ADDITIONAL TIME 0
I. TOTAL CONTRACT TIME 180
J. ORIGINAL COMPLETION DATE 5/1/2010
K. CURRENT COMPLETION DATE 5/1/2010
CITY OF CORPUS, TEXAS
By: ----
Director of Engineering Services
~~
/-(
roject Manager
calender days
calender days
calender days
calender days ~,, ~~-~_
CONTRACTOR
By:
Title:
r~ ~e@ w~~t.,o~w
APPROVED: ,~~ -C+ -G%~~ Operating Department Q o -QQ ~ AUTHOKIZt~
AP ~ ,~- ENTERED
2010_011 Dir. of Management & Budge COURC~L ~ ~ ~
M2010-006 DEC 2 ?009
01/12/10 -Legal Department
Infinity Builders, Inc. Page 1 ~~ORET ~RACT MANAGERS
INDEXED
Department of Engineering Services
Change Order Summary Sheet
January 12, 2010
PR07ECT: H.E.B. and AI Kruse Tennis Centers Court Improvements
Project No. 3391
APPROVED: City Council on 9/8/09 -Motion No. 2009-249
CONTRACTOR: Infinity Builders
6948 US Hwy 83 South
Laredo, TX 78046
SUMMARY: This Change Order will add the painting of 7 tennis courts at AI Kruse Tennis
Center in order to repair deterioration of the court surfaces and improve
usability.
TOTAL CONTRACT AMOUNT ............................ $249,000
25% Limit Amount ........................................ 62,250
Change Order No. 1 (Council 1/12/10) ............ 47,201
Total ........................................................... $47,201 = 18.96% < 25%